Attached files

file filename
EX-10 - DEMAND PROMISSORY NOTE - 12 Retech Corpex102.htm
EX-23 - CONSENT OF INDEPENDENT ACCOUNTANT - 12 Retech Corpex231.htm
EX-3 - ARTICLES OF INCORPORATION - 12 Retech Corpex311.htm
S-1/A - DEVAGO INC. - AMENDED REGISTRATION STATEMENT ON FORM S-1 A-1 - 12 Retech Corpdevagoincforms-1a1final.htm
 

Exhibit 10.1

 

Hotchek Mobile ApanPortaDevelopmenAgreement Between SoftAddicts.comInc. anCLIENT

 

 

 

CLIENT (referred  to herein as "CLIENT")  ha engaged  SoftAddicts.com Inc (referred  herein as "CONTRACTOR")  fo the  specifi purpose  o website developmen and/or  Interne related services. 

 

 

1.     SERVICES RENDERED.   CONTRACTOR agree to perform  following website developmen and/o Interne related services as outlined and agree to in attached  Statemen of Work.  Multiple Statements  o Wor can  be a par o thi agreement.  Each  Statemen o Work must refer  to  thi agreemen an signed by both  parties  to b legal

 

2.    PAYMENT.    All charge agreed upo and which may  accrue shall become  du and payable to CONTRACTOR as described in attached and signe Paymen Schedule. 

 

3.    ADDITIONAL SERVICES.   The  terms  and condition set  forth  i thi documen constitute the sole agreemen between CONTRACTOR and the  CLIENT regarding the website developmen and/o Interne related services.  Any  additional  work  no specified i thi contract or i the Statemen o Wor mus be  authorized in writing

 

4.  CONTRACTOR’s PERFORMANCE.   CONTRACTOR  agree to  perfor al task assigned to CONTRACTOR as set  forth  in thi Agreement Statemen o Work,  Paymen Schedule,  or  a Chang Order an to  provide all assistance and cooperatio to  CLIENT CONTRACTOR agree to begi the  developmen immediatel upon acceptance o thi Agreemen and deposit paymen by  the  CLIENT CLIEN shall hereb acknowledge and agree  that  CONTRACTOR  and its suppliers  will no be liabl for  an temporary  delay outages o interruption o the services.  Further CONTRACTOR  shall no be liabl for  an delay  or  failure t perfor its obligations unde thi Agreement,  where such delay  or  failure  result fro an act  o God or other cause beyond its reasonable control  (including without  limitation an mechanical, electronic,  communication o third-party  supplier  failure).    CONTRACTOR  i responsibl for  the performance  o the software  after  i ha been  installed If,  fo some  reason the CLIENT is at faul for  the  software  no performing the writte quote  from  CONTRACTOR will be submitted for approval  o the  work  required  to  fi the  software.    All other failures  du to  the software  will  be responsibility  o CONTRACTOR  to  repai bac to  acceptable performance

 

5.    CLIENT’s RESPONSIBILITIES.   CLIENT agree to perform  all task assigne to CLIENT as set forth in thi Agreement Statemen o Work Paymen Schedule,  or  a Chang Order,  and to provide all assistance  and cooperation  to CONTRACTOR.  CONTRACTOR shall no be deemed in breach  o thi Agreemen in the  even CONTRACTOR's  failure  to  mee its responsibilities and time  schedules is caused by  CLIENT' failure  to  mee (or  delay  in)  its responsibilities and time  schedules set forth in the  Statemen o Work,  Paymen Schedule,  a Chang Order o thi Agreement.  In  the even o an such  failure  o delay  by  CLIENT (i all of CONTRACTOR's  time  frames,  milestones,  and/o deadline shall be extended by the numbe of day of  CLIENT' failure  multiplied by two (2); an (ii CLIENT shall continue t mak timely payments  to CONTRACTOR as set  forth in thi Agreement,  the  Paymen Schedule,  an any Chang Order(s)  as i all time  frames,  schedules,  or  deadline ha been completed by CONTRACTOR In  the even o such  failure,  CONTRACTOR has right  to substitute  project developers  and CLIENT will have to cover  reasonable learning curve necessary

 

 

 

 


 
 

6.    SUBCONTRACTING.   CONTRACTOR reserves the  right  to assig other  developers  to  the projects.    In  such  even CONTRACTOR’ subcontractor  or  subcontractor must  be accessible to CLIENT durin normal  work  hours  by  E-mail and,  i requested  in writing IC or  an instant messag system and/or  by  phone.    CONTRACTOR is responsibl for  all subcontracting performance as  i i was thei own. 

 

7.     NON-CONTRAVENTION.    Neithe party  shall directly  or  indirectly tak an action o do anything which has the  resul o reducing hindering impairing or eliminating the benefit to be derived fro thi agreemen o the  relationship created hereby.    Neithe part shall confer, negotiate, solici o try  t confer negotiate  or  solici with any contact,  CLIENT customer, supplier,  subcontracto o service provide o the  other  party  in orde to avoid or evade or reduce o eliminate  an obligations,  right o benefits  o thi agreement.    CONTRACTOR canno directl contract  customers  o the  CLIENT and CLIEN canno directl contrac or employ  employee or  subcontractor o the CONTRACTOR  for  an reason othe tha to perform  unde thi agreemen during the terms  o thi Agreemen an fo period o (three) years  upon termination o thi Agreement whethe because  o eithe party default upon completion,  or  an othe cause.    In  the even o an already  existing  direc business  between one o the  parties,  an the othe party protected  interest sectio 7 shall not  apply Each  party agree to ac i goo faith in carrying  ou the provision o thi Agreemen to  the bes o their abilities. 

 

8.    WARRANTIE AN LIABILITY CONTRACTOR does no warran that  the  function o the Software  Developmen and/or  Interne Related  Services will mee the CLIENT expectations  of resulting business

 

9.    TRADEMARKS & COPYRIGHTS.   The  CLIENT represents  to  CONTRACTOR and unconditionall guarantees tha an elements  o text,  code graphics,  photos,  designs, trademarks or  othe materia furnishe to  CONTRACTOR  for  inclusion in CLIENTS projects are owned by the CLIENT,  o tha the  CLIEN ha permission  fro the  rightful  owne to use each o these elements and will hold harmless protect,  and defend CONTRACTOR  fro any clai or  sui arising  fro the use o such  elements  furnished by the  CLIENT.   Copyright  to  the assembled wor o We pages  produce by  CONTRACTOR is owned by

CONTRACTOR.   Upo final paymen fo each Statemen o Work,  all right owned by CONTRACTOR  as  to  the design graphics,  text,  and programs mad fo tha Statemen o

Work,  transfer  to  the CLIENT

 

Thi doe no include source  code documentation,  and/or  application programs  tha were previousl written or developed by CONTRACTOR an modified to mee CLIENT' specific requirements.    CONTRACTOR  shall own all worldwide right title,  and interest  in and to  such content bu shall provide CLIENT (upon paymen i full o the  fee associated with the Statemen o Work)  a worldwide royalty-free non-exclusive,  transferable and perpetual right and license t use  such  content CONTRACTOR  agree tha i eithe owns or will own any rights  tha i claims  to  own and which CONTRACTOR assigns  to  CLIENT CONTRACTOR will assig an intellectual propert right to CLIENT tha are consisten with thi paragraph

 

 

10.    THIRD-PARTY PRODUCT AND SERVICES. Certain third-party  products  an services migh be  use as a par o the project Unless  specificall agree to by CLIENT and CONTRACTOR CONTRACTOR  shall no be  responsibl for  performance o such  products  and services.  Further all cost related  to  third-party  products  an services shall be responsibility  of the CLIENT. 

 

 

 

2


 
 

11.    LITIGATION.   An disputes arising fro thi contract  will be litigated or arbitrated  in Broward  County Florida.   Thi Agreemen shall b governed and construed in accordance with the law o the State  o Florida,  USA.

12.     CONFIDENTIALITYConfidentia Information shall mean all information identified by a party  ("Disclosing  Party")  to  the  othe party  ("Receiving  Party"),  which,  i i writing  labeled as confidential o i disclosed orally i reduced  to writing withi fiftee (15 days,  and labeled as confidential Confidential  Informatio shall remain the  sole property  o the  Disclosing  Party. Excep for  the  specifi rights  granted  by  thi Agreement the Receiving  Party  shall no use  any Confidential  Informatio o Disclosing Party  for  its  own benefi o for  the  benefi o others. Receiving  Party  shall no disclose Confidentia Information to an third  party without  the  written consen o Disclosin Party  (excep to  its  own developers  who are boun b a written agreemen with Receiving Part to  maintain confidentiality).  Confidentia Informatio shall exclude informatio (i available to the  publi other  than by a breach  o thi Agreement (ii) rightfull received  fro third  part no in breach  o an  obligatio o confidentiality (iii) independently  developed by Receiving  Part without  access  to Confidential  information (iv) known t Receiving  Part at  the  time o disclosure;  o (v produce in compliance with a court order Receiving  Party  shall give reasonable notice t Disclosing Part that  Confidential Information i being sough by  third  person so  as t afford  an opportunit to limi o prevent such disclosure Receiving Part agrees  to  cease  using all Confidentia Information an to promptl return such Confidential Informatio to  Disclosing  Party  upon request. 

 

13.     MARKETING.   CLIENT hereby grants  CONTRACTOR  the  righ to  use the name  and service marks  o CLIENT in its  marketing material or  othe oral electronic o written promotions,  which shall include namin CLIEN as a CLIENT o CONTRACTOR  and a brief scope o services provided.  Eithe party  may  elect  to issu a press  release  related  to  this Agreement.  In  doing so an release shall be approved by the othe part and such approval shall no be  unreasonably withheld. 

 

14.     TERMINATION

 

Termination  fo Convenience.    CLIENT shall have the right  a an time  to  terminate  this Agreemen upon  fiftee (15 days’ notice  by  giving written notice o termination to CONTRACTOR In  the even o such  termination CLIENT's  entire  financial obligatio to CONTRACTOR  shall be for  the accrued payments  du unde Paymen schedule,  plus  the prorated portion o the nex payment,  i any du with respec to items  being worked  on bu not yet  delivered at the  time  o termination

CONTRACTOR  shall have the right  to  terminate  thi Agreemen upo fifteen (15 days’ notice by giving  written notice o termination  to CLIENT.  In  the even o such  termination

CONTRACTOR’ entire  obligation shal be  to  complete  all outstanding Statements  o Work. 

 

Automatic Termination.   Thi Agreemen will be terminated  automatically without  notice (i) upon the institution by or  against  eithe o the  parties t thi Agreemen o insolvency, receivership,  or  bankruptcy  proceeding or  an othe proceeding for  the  settlemen o their debts; (ii upon  the makin an  assignmen fo the benefi o creditors o (iii upon  their dissolution. 

 

 

 

 

 

 

 

3

 


 
 

15.     ENTIR AGREEMENT Thi Agreement,  including the attached  Statement  o Wor and Paymen Schedule which are incorporated  herein by reference  as  thoug full set  out,  contains the entire understanding  and agreemen o the  parties with respect  to  the  subject  matter contained herein supersedes all prio oral o written understanding an agreements  relating thereto excep as expressl otherwise provided,  and may  no be  altered modified o waived in whole or in part excep in writing signed by dul authorized representatives o the  parties. 

 

16.     FORCE MAJEURE Neithe party  shall be held responsibl fo damages  caused  by  any delay  or  defaul du to any  contingency  beyond it control  preventing or interferin with performance  hereunder. 

 

17.     SEVERABILITY.    I an provision o thi Agreemen shall be held by a court  o competent jurisdiction  to  be contrary  to  an law the remaining provision shall remai i ful force  and effec as  i said provision  never  existed

 

18.     WAIVE AN AMENDMENTSNo waiver,  amendment o modification o an provision o thi Agreemen shall be effective unless consented  to by both  parties in writing N failure  or delay  by  eithe party  in exercising  an rights power, or remed unde thi Agreemen shall operate  as a waiver  o any  such right power, or remedy

 

19.     AGENCY.    The  parties are  separate and independent  legal  entities.  Nothing contained in thi Agreemen shall be deemed  to constitute eithe Agen or  CLIENT a representative,  partner, joint  venture o employee o the  othe party  for  any  purpose.  Neithe part ha the  authority  to bind the othe or  to  incu an liability  on behal o the other,  no to  direc the employee o the other

 

20.     SUCCESSORS.   All rights  an obligations  o the parties  unde thi Agreemen would be transferred  to eithe part successor  as i i was the original party  to  thi Agreement. 

 

21.     CONTAC INFORMATION OF THE PARTIES

 

CLIEN Information 

DEVAGO  INC. 

Address Call Dr.  Heribert Nune #11,  Edifici Samadh Apto  104 Santo  Domingo,  RD Phone 809994444

Email jose@devagoinc.co

 

CONTRACTOR Information 

SoftAddicts.com Inc

Address 100 NE  12  Ave,  Suite  707 Hallandal Beach,  FL  3300

Phone 954-536-011 Email vlad@softaddicts.com 

 

 

 

4


 
 

IN WITNESS WHEREOF the parties  hereto have executed  thi Agreement  as  o the  date indicated below

 

 

 

 

 

CLIENT.     /s/ Jose Acosta                                          Title:  President,  CE

 

 

 

Date  FEB 5 2015 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

5


 
 

 

 

 

 

 

SoftAddicts.com,  Inc.                                     Title:         CEO               

 

/s/ V. Shaunders

 

Date  FEB 5 2015 

 

 

 

 

 

 

STATEMEN OF WOR (as  a part  o HotChe Mobile App and Portal  Developmen Agreement between SoftAddicts.com,  Inc and CLIENT.) 

 

 

 

Phase 1.

 

 

 

CLIENT agree to  provide SoftAddicts  statemen o wor an detail specification o the chang requests  to  be added to thi agreemen by March  1,  2015

 

 

 

 

 

CLIEN/s/ Jose Acosta 

 

 

 

 

 

CONTRACTOR    /s/ V. Shaunders

 

6


 
 

DATE    FEB 5 2015

 

 

PAYMEN SCHEDULE  (as a par o Hotche Mobile App an We Portal  Development Agreemen between SoftAddicts.com,  Inc and CLIENT.) 

 

 

 

Phase 1.

 

 

 

 

 

 

Additional  work  an future maintenance will be performed  at  $45/hour. 

 

 

 

 

 

 

CLIENT /s/ Jose Acosta 

 

 

 

 

 

CONTRACTOR     /s/ V. Shaunders

 

 

 

 

 

 

DATE FEB 5 2015 

 

 

 

 

 

 

7