DAHUA INC - FORM 10-K - March 30, 2010

Attached files

file	filename
EX-31.1 - DAHUA INC	v179170_ex31-1.htm
EX-32.2 - DAHUA INC	v179170_ex32-2.htm
EX-32.1 - DAHUA INC	v179170_ex32-1.htm
EX-31.2 - DAHUA INC	v179170_ex31-2.htm

UNITED STATES

SECURITIES AND EXCHANGE COMMISSION

Washington, D.C. 20549

FORM 10-K

ANNUAL REPORT UNDER SECTION 13 OR 15(d)

OF THE SECURITIES EXCHANGE ACT OF 1934

For the fiscal year ended December 31, 2009

TRANSITION REPORT UNDER SECTION 13 OR 15(d)

OF THE SECURITIES EXCHANGE ACT OF 1934

For the transition period from __________ to __________

Commission file number: 0-49852

DAHUA INC.

(Exact Name of Registrant as Specified in its Charter)

Delaware	04-3616479
(State or other jurisdiction of incorporation or organization)	(I.R.S. Employer Identification No.)

8th Floor, Officer Tower 3, Henderson Center, 18# Jianguomennei Street

Dongcheng District, Beijing, China 100005

(Address of principal executive offices)

86-10-6480-1527

Registrant’s telephone number, including area code

Securities registered under Section 12(b) of the Exchange Act: None

Securities registered under Section 12(g) of the Exchange Act: Common Stock, Par Value $0.001 Per Share

Indicate by check mark if the registrant is a well-known seasoned issuer, as defined in Rule 405 of the Securities Act. Yes o No x

Indicate by check mark if the registrant is not required to file reports pursuant to Section 13 or 15(d) of the Act. Yes o No x

Indicate by check mark whether the issuer (1) filed all reports required to be filed by Section 13 or 15(d) of the Exchange Act during the past 12 months (or for such shorter period that the registrant was required to file such reports), and (2) has been subject to such filing requirements for the past 90 days. Yes x No o

Indicate by check mark if disclosure of delinquent filers pursuant to Item 405 of Regulation S-K (§229.405) is not contained herein, and will not be contained, to the best of registrant’s knowledge, in definitive proxy or information statements incorporated by reference in Part III of this Form 10-K or any amendment to this Form 10-K. Yes x No o

Indicate by check mark whether the registrant is a large accelerated filer, an accelerated filer, a non-accelerated filer or a smaller reporting company. See the definitions of “large accelerated filer,” and “smaller reporting company” in Rule 12b-2 of the Exchange Act.

(Check One): Large accelerated filer£, Accelerated filer£, Non-accelerated filer£, (Do not check if a smaller reporting company) Smaller reporting company x

Indicate by check mark whether the registrant is a shell company (as defined in Rule 12b-2 of the Exchange Act). Yes o No x

The aggregate market value of the voting and non-voting common equity held by non-affiliates computed by reference to the price at which the common equity was sold, or the average bid and asked price of such common equity as of a specified date within the past 60 days: Since there is no trading market for Registrant's securities, no estimate as to the market value can be given.

The number of shares outstanding of Registrant's common stock as of March 31, 2010 was 25,015,000.

DAHUA INC.

FORM 10-K

For the Year Ended December 31, 2009

PART I
Item 1. Description of Business		3
Item 2. Description of Property		10
Item 3. Legal Proceedings		11
Item 4. Submission of Matters to a Vote of Security Holders		11
PART II
Item 5. Market for Common Equity and Related Stockholder Matters		12
Item 6. Management's Discussion and Analysis or Plan of Operation…		13
Item 7. Financial Statements		23
Item 8. Changes In and Disagreements with Accountants on Accounting and Financial Disclosure		38
Item 9A(T). Controls and Procedures		38
Item 9B. Other Information		40
PART III
Item 10. Directors, Executive Officers, Promoters and Control Persons; Compliance with Section 16(a) of the Exchange Act		40
Item 11. Executive Compensation		42
Item 12. Security Ownership of Certain Beneficial Owners and Management and Related Stockholder Matters		43
Item 13 Certain Relationships and Related Transactions		45
Item 14. Exhibits		46
Item 15 Principal Accountant Fees and Services		48
Signatures		49

Item 1. Description of Business

Background

Dahua Inc. (the “Company”) was incorporated on March 8, 2002, in the State of Delaware under the name of Norton Industries Corp. ("Norton") as a blank check company for the purpose of either merging with or acquiring an operating company with operating history and assets. In June 2002, the Company filed a registration statement on Form 10-SB with the Securities and Exchange Commission ("SEC") in order to become a Section 12(g) registered company under the Securities Exchange Act of 1934, as amended. The registration statement became effective on or about August 10, 2002.

From March 8, 2002, to January 30, 2005, Norton conducted virtually no business other than organizational matters and filings of periodic reports with the SEC pursuant to the reporting requirements of Securities Exchange Act of 1934, as amended. The promoters, control persons and affiliates of Norton were Mr. Jianjun Zhang, Waywood Investments Ltd. ("Waywood"), Comp Hotel International Ltd. ("Comp Hotel"), and South Sea Petroleum Holdings Ltd. ("South Sea Petroleum"). Waywood is a small business consulting firm organized in the British Virgin Islands. Mr. Jianjun Zhang is the sole shareholder of Waywood. From Norton's inception in March 2002, to February 2003, Waywood owned 100% of Norton, and Mr. Jianjun Zhang, from March 2002 to January 2005, was the sole director and officer of Norton. On February 26, 2003, Waywood sold 85%, or 4,250,000 shares, of Norton's capital shares to Comp Hotel for $42,500 in cash. Comp Hotel is a travel-related service provider operating in Hong Kong, and is controlled by South Sea Petroleum, a Hong Kong corporation, whose principal business is the exploration and production of crude oil in Indonesia.

On January 30, 2005, Waywood and Comp Hotel entered into a Share Exchange Agreement with Bauer Invest Inc. for a reverse acquisition. Pursuant to the agreement, Waywood and Comp Hotel sold all of their capital stock, or 5,000,000 shares of common stock, to Bauer for retirement in exchange for $100,000 in cash and 5%, or 1,000,000 shares of Norton’s post-merger common stock. To effectuate the reverse acquisition, Norton issued 19,000,000 shares of its common shares to 108 shareholders of Bauer in exchange for 100% of shares in Bauer on a pro rata basis, i.e. the number of shares received by each shareholder is proportionate to the number of shares he/she had originally owned in Bauer. Following the transaction, on February 7, 2005, the name of Norton was changed to Dahua Inc.

Bauer is a holding company, which conducts its business through its 80% owned subsidiary Beijing Dahua Real Estate Development, Ltd., an operating company organized in the People's Republic of China (“Dahua Real Estate”). As a result of the reverse acquisition, Bauer became our wholly owned subsidiary, and the shareholders of Bauer became our controlling shareholders. This transaction was accounted for as a recapitalization, rather than a business combination. Under accounting principles generally accepted in the United States of America, after completion of this transaction, the Company files prior historical financial information of Bauer and its subsidiaries for the years prior to the acquisition on a stand-alone basis. The continuing operations of the Company will reflect the consolidated operations of Dahua and its subsidiaries.

On May 12, 2005, Dahua Real Estate increased its registered capital, in which the company increased its investment in Dahua Real Estate by $2,265,600 and the minority shareholder of Dahua Real Estate increased its investment by $566,265. Dahua Project Management Group ("Dahua Group") advanced the Company funds to allow for the increase in investment, which amount was recorded as short-term loans-related parties. On September 21, 2005, the Company issued, on a pro rata basis, an aggregate of 4,750,000 shares of its common stock to shareholders of Dahua Group in exchange for the conversion of the short-term loan ($2,265,600) to equity shares. In connection with issuance of additional shares, pursuant to a no-dilution clause of the Share Exchange Agreement dated January 30, 2005 the Company entered into with Comp Hotel and Waywood, on September 21, 2005, the Company issued 212,500 and 37,500 shares of our common stock to Comp Hotel and Waywood, respectively.

Bauer was incorporated on December 10, 2003, under the laws of the British Virgin Islands. On May 25, 2004, the shareholders of Dahua Group transferred to Bauer 80% of the capital stock of Dahua Real Estate in exchange for all the capital stock of Bauer. Dahua Group is a Beijing Municipal Government licensed construction project supervising business entity in Beijing, China. This transaction was accounted for as a recapitalization of Dahua Real Estate, rather than a business combination. Before the stock transfer, the shareholders of Dahua Group owned 80% of capital stock of Dahua Real Estate, and Beijing Dahua Bidding Agency owned the remaining 20%. Beijing Dahua Bidding Agency is a Chinese corporation servicing construction companies in biddings for major construction projects. After the transfer, the shareholders of Bauer replaced the shareholders of Dahua Group as holder of 80% of the capital stock of Dahua Real Estate, while Beijing Dahua Bidding Agency still owns the remaining 20%. Both Bauer and Dahua Group were owned by the same group of shareholders in the same proportions prior to the acquisition by Norton.

Prior to the acquisition, other than owning 80% of Dahua Real Estate's capital stock, Bauer had no operations. Dahua Real Estate was incorporated in China on September 24, 2001, to engage in the development, construction, and sale of luxury single-family housing units. Both Norton and Bauer were non-operating shell companies and incurred minimal costs to acquire Bauer or Dahua Real Estate, and therefore there was no need for adjustments for any costs incurred by Norton or Bauer to be “pushed down” in the accounts of Norton, Bauer or Dahua Real Estate. Dahua Real Estate did not incur any other costs which were required to be "pushed down" for the completion of the transaction.

The promoters, control persons and affiliates of Bauer Invest, Inc. and Dahua Real Estate are Mr. Yonglin Du and Dahua Group. Prior to the acquisition, a group of shareholders owned 100% of Dahua Group, and the same group of the shareholders owned 100% of Bauer in the same shareholding proportion as they owned Dahua Group. At present, the same group of shareholders own 95% of Dahua Inc. Yonglin Du, our CEO and President, also acts as president of Dahua Group and Bauer. In 2000, Mr. Du founded Dahua Group and has since been its Chairman of the Board of Directors and Chief Executive Officer. Dahua Group is a Beijing Municipal Government licensed construction project supervising business entity which is operating in Beijing, China. Since January 30, 2005, Mr. Du has been our Chairman of the Board of Directors and Chief Executive Officer.

The Company has not been involved in any bankruptcy, receivership or similar proceedings.

BUSINESS

The Company, through its 80% owned subsidiary Beijing Dahua Real Estate Development Ltd. ("Beijing Dahua Real Estate"), engages in the business of development, construction and sale of luxury single-family homes in Beijing and its circumjacent areas, in China.

Completed Projects

In July 2003, the Company began to develop its first real estate project. The project is called the first phase of Dahua Garden (the "First Phase"), which consists of 75 luxury residential housing units, all of which are single houses ranging from approximately 2,000 to 5,000 square feet, each with 3-4 bedrooms with built-in closets and adjacent bathrooms, an open eat-in kitchen, a family room, a living room, and an attic solarium for indoor sun bathing. Those homes are within reasonable driving distances from Beijing metropolitan areas. The project is located at the northern skirt of Beijing, China. The property being developed sits on a hot spring, spewing 10,000 cubic meters per day providing every house with hot spring water for baths. The water temperature at the mouth of the hot spring is over 60 degrees centigrade. The surplus hot spring water is discharged into the surrounding creeks and ponds, making them unfrozen all year round.

The construction began in July 2003 and was completed in December 2005. As of December 31, 2009, 67 units have been sold, 8 units were reserved with clients' deposits.

New projects in progress

We are currently in the process of applying with Beijing municipal and Changping district government agencies for the requisite licenses, permits, and approvals in order to start the Second Phase of Dahua Garden. But, in August 2006, the Chinese government issued a number of new rules and regulations for real estate developers, like us, in an attempt to push down rising house prices by cutting down luxury single family house constructions and favoring construction of apartment buildings. Under the government’s new policy, (i) no single family houses can be built, if the construction has not started, without special construction permits; (ii) All permits previously issued have to be re-reviewed and re-approved; and (iii) the land previously acquired for luxury housing construction has to be revalued and sold to the people who offer the most money for the land in an auction. Because of those new government policies, we have incurred a long delay for obtaining the consents and approvals to commence our construction for the second phase of Dahua Garden.

We, through our subsidiary Zhuolu Dahua Real Estate Development Ltd. (“Zhuolu Dahua Real Estate”) which was established on May 21, 2008 and was wholly-owned by Beijing Dahua Real Eatate, engage in the business of development, construction and sale of luxury residential single-family homes in Zhuolu county, Hebei province. The first phase of this project, known as Xuanyuan Lakefront, consists of 246 villas, all of which are single-family houses ranging from approximately 2,000 to 5,000 square feet, each with 3 – 4 bedrooms.

Zhuolu county, located 2 hours north of Beijing is said to be the birthplace of the Chinese nation. Historical records and explorations indicate that it is an ancient battlefield where three Emperors - Huang, Yan and Chiyou held a fight. Emperor Huang allied Yan, and defeated Chiyou. The winners merged their languages, customs, and living habits, to form the Huaxia people, predecessor of the Han people, the principal part of the Chinese nation. Today, most of Chinese people still call themselves "descendants of Emperor Huang and Yan ", and Zhuolu is the place where all these stories began. Therefore, every year it attracts numerous visitors from all over China, even the world, to come here for a "root-searching journey".

Besides its historical significance, summer in Zhuolu is delightfully cool due to its geological conditions, with temperatures ranging from 20℃ to 30℃. Each summer, many people from Beijing or nearby cities come here for recreation to escape from scorching heat and polluted air. A huge variety vegetable grows here, including tomatoes, peas, potatoes, cucumbers, eggplants, etc. Urban people can taste the freshest vegetable they ever had, along with mineral spring water locals have drunk for generations.

Located in east of Zhuolu and 2 hours drive from Beijing center region by Highway, Xuanyuan Lakefront is near the Xuanyuan lake, a beautiful and tranquil lake. There is also a spring called Emperor Huang spring nearby. In legend, while fighting against Chiyou, Emperor Huang often bathed in the spring to recover his strength quickly and think out ways to deal with his enemy. The water from this spring is natural mineral water containing healthy minerals and trace elements. Morever, Xuanyuan Lakefront is next to an apricot orchard. During springtime the trees will be in full blossom and even air is full of sweet scent.

Since acquiring the land, we have been working on applying for construction permit approval necessary for development and already received the following permits from the local government.

National land use permit

Construction land planning permit

Construction engineering planning permit

Project construction permit

The company is now in the process of construction.

Home Construction

We act as the general contractor for our residential home developments and hire subcontractors for all construction activities. The use of subcontractors enables us to reduce our investment in direct labor costs, equipment and facilities. We generally price our housing only after we have entered into construction contracts with subcontractors, an approach which improves our ability to estimate costs accurately.

As the general contractor, we select our subcontractors for construction through a competitive bidding process. In addition to the bid price, our criteria include the bidders' experience, reputation, recommendations and references from other developers. The construction prices are capped and cover all materials and labor needed to complete the construction under the construction contract. The bid-winning subcontractor will make advance payments for all materials and labor. We make payments to the subcontractors over time upon completion and acceptance of certain phases of construction according to agreed-upon milestones specified in the construction contract.

As the general contractor, we are responsible for all planning, scheduling and budgeting operations. There is an on-site superintendent who oversees the subcontractors. We supervise the construction of our project, coordinate the activities of subcontractors and suppliers, subject their work to quality and cost controls and assure compliance with zoning and building codes.

Subcontractors typically are retained on a project-by-project basis to complete construction at a fixed price. Agreements with our subcontractors are generally entered into after competitive bidding on an individual basis. We generally obtain information from prospective subcontractors and suppliers with respect to their financial conditions and abilities to perform under their agreements prior to commencement of a formal bidding process. The services performed for us by subcontractors are generally readily available from a number of qualified subcontractors.

We use, to the extent feasible, standardized materials in our commercial construction and homebuilding operations in order to permit efficiencies in construction and material purchasing that can result in higher margins. Our subcontractors generally negotiate the purchase of major raw material components such as concrete, lumber and structural steel. They are responsible for what they purchase and for what they pay for. Raw materials used in our operations are generally readily available from a number of sources but prices of such raw materials may fluctuate due to various factors, including supply and demand.

As the general contractor, we are not subject to any bonding and/or insurance requirements under Chinese law and common practice in housing construction. We may suffer heavy or total losses in the event of fire, earthquake or other disasters.

To date, we have not encountered any problems that would affect the delivery date of our units, nor have we experienced a significant increase in prices of materials.

The units available for sale is subject to government inspections prior to transfer of title to buyers. The purpose of the inspection is to ensure that real estate developers adhere to government standards of quality and safety.

Other Government regulations that we must adhere to are:

Any structures being constructed must be for residential and commercial use;

All structures must be within certain dimensions;

Public infrastructures must be in place, such as electrical and telephone poles, underground pipe systems;

There must be various safety access routes in case of emergencies such as fire or earthquake;

Construction must not violate environmental laws in effect; and

Compliance with certain infrastructure standards.

To date we have not violated any of the above-noted regulations.

We typically obtain all necessary development approvals, complete a satisfactory environmental assessment of the site, secure any necessary financing and complete other due diligence deemed appropriate by us prior to becoming obligated to commence the construction.

Acquisition of Land-Use Rights

The residential home development process in China generally consists of three phases: (1) acquisition of land-use rights; (2) land development and construction; and (3) sale. The development cycles vary depending on the extent of the government approvals required, the size of the development, necessary site preparation, weather conditions and marketing results.

Sales and Marketing

Our sales and marketing activities are conducted principally through our sales employees. They are paid by base salary, plus sales commission, which is 0.3% of gross sales. We have no single customer that will account for any substantial portion of our sales revenues.

Our residential homes are targeted toward buyers who desire high quality property with many attractive features on which to build luxury homes for use as their primary residences, vacation retreats, retirement residences, or investments. Our target buyers include upper and middle class Chinese citizens and foreign nationals working in Beijing and the surrounding area, such as Shanxi and Hebei provinces, ranging from 30 to 60 years of age, including private entrepreneurs, senior executives, technology elites, college professors and self-employed professionals. The foreign nationals are expatriates of foreign companies based in China. Our strategy for remaining competitive in this market involves building on our reputation of offering quality homes; using our own sales offices and personnel; and offering properties with many appealing features, such as trails, water access, creeks, and attractive views.

We sell our homes through our sales representatives who typically work from sales offices located in the model homes at the development site. Sales representatives assist potential buyers by providing them with basic floor plans, price information, development and construction timetables, preview of model homes and the selection of options. Our sales representatives are trained by us and generally have had prior experience selling new homes in the local market. We also market our homes for sale through direct mailing to an identified population of prospective buyers and, to a lesser extent, through other media, including newspapers, television and radio advertising, airplane advertising, product tie-ins, billboards and other signage.

Homes are sometimes sold prior to or during construction using sales contracts which are accompanied by cash deposits. After receiving the Residential Housing Pre-sale Permit issued by the government, we, the developer, are permitted by government authorities to sell the residential units to be built to the public, which is common practice in China. Upon execution of a binding purchase contract between the developer and the buyer, a deposit, ranging from 10% to 20% of the sales price, is required to be made to the developer, which we use to construct our residential units. As of December 31, 2009, the balance of our customer deposits was $3,681,057.

Our sales are made pursuant to a standard sales contract. Subject to particular contract provisions, we generally permit purchasers to cancel their contractual obligations in the event mortgage approvals are unobtainable within a specified period of time and under certain other circumstances, including rescission rights which may be given under local law. Accordingly, there is possibility that home buyers, even though they have put down a certain amount of deposit, turn out choosing not to purchase our housing units which creates an uncertainty and risk to our results of operations. To date we have two contracts that have been cancelled.

To assist in the marketing of our homes and to limit our liability for certain construction defects, we sell our homes subject to a limited warranty that is provided by our subcontractors. We don't provide any kind of warranty to homebuyers. Our subcontractors are responsible for the cost to repair major structural defects, roofing, internal walls, heating, tiling problems, if any, for a certain period of time, from one to five years. The foregoing repair costs are limited by our subcontractors' policy to the repair, replacement or payment of the reasonable cost of repair or replacement of such warranted items not to exceed an aggregate amount equal to the final sales price of the home covered by the warranty. Once all homes have been constructed and sold, we do not have any post-sale obligations.

Home Buyer Financing and Deed Application

We do not provide financing to prospective homebuyers. Approximately 25% of homebuyers in China currently use their savings or funds from their relatives to pay for the houses they buy. We are permitted to sell our homes before they are built. It usually takes 18 to 20 months from ground breaking to completion, within which the homebuyers make installment payments to the developer. At the time of completion and delivery, the purchase price will have been paid in full. After viewing the model units, the potential buyer usually leaves 30,000 yuan, or $4,394, refundable deposit, upon receipt of which we will hold the unit for that buyer. The potential buyer may withdraw the commitment within two weeks and receive a full refund of said deposit. The parties may also enter into a binding contract, and the buyer is required to make a 10% to 20% down payment at the time of signing. Thereafter, the buyer makes installment payments every 2 to 3 months until the purchase price is paid in full. The actual payment terms vary on a case-by-case basis depending on negotiations.

The majority of homebuyers in China need to finance their homes with mortgage loans from banks. To facilitate their mortgage application, most developers in China, including us, are involved in the buyers' mortgage application process. We first initiate negotiations with two banks to obtain a blanket lending commitment which covers all potential buyers for the homes to be built by us. If a potential buyer needs financing, we conduct a preliminary screening of the buyer's creditworthiness. Then we forward the mortgage applications to the banks for further processing, which usually take 30 to 60 days. Upon approval of the mortgage extended to each buyer by the banks, the loan proceeds are transferred directly to our bank account, rather than the buyer's. We have not, and will not receive any finder's fees or referral fees from the banks.

It is customary in China that developers may, depending on the type of property, use up to 95% of the loan proceeds so obtained to meet their working capital needs. The banks require that 5% to 20% of the proceeds be set aside. On our balance sheets, such loan proceeds are treated as customer deposits. We have not taken any measure to safeguard customer deposits because currently Chinese law does not require that such deposits be placed in an escrow or trust account for safeguarding purpose.

The life of a mortgage loan in China can be up to 30 years. Because our project is considered luxury housing, the maximum life of mortgage loans is 20 years. The mortgage rates, which are flexible in nature, are dictated by the Chinese central government based on prime commercial lending rates from time to time. Due to competition among lending institutions, mortgage rates can be adjusted downward by up to 10%. The mortgage rates currently range from 5.51% to 5.94%, which are applied to primary residence and second home, respectively.

Unlike the United States, deeds for newly-built homes in China are applied for by the developer with the government, which owns the land. Upon issuance of the deeds, the developer distributes the deeds to individual homeowners. In order to obtain government approval of deeds, the developer must have obtained all requisite permits and licenses and paid all fees and taxes. Before the actual issuance of deeds, the ownership of the real property remains with the developer even if the homes have already been sold. Generally, the developer will wait until all homes are completed to apply for the deeds in a blanket application, which takes approximately 40 to 60 days. Before the issuance of deeds, the title to the homes legally remains with the developer.

Regulation

Real estate development is a highly regulated industry in China, and we are subject to extensive local, district, municipal and national rules and regulations regarding permitting, zoning, subdivision, utilities and water quality. Regulation is carried on by municipal, district, and national authorities, of which the municipal and district governments have the greatest regulatory impact. The City of Beijing, in and nearby which we operate, has been adopting increasingly restrictive regulations associated with development activities, including the adoption of more restrictive ordinances, greater emphasis on land use planning, pressure to increase the number of low density residential developments, and heightened public concern aimed at limiting development as a means to control growth. Such regulation may delay development of our properties and result in higher developmental and administrative costs.

To date, we are in material compliance with these laws and regulations.

Environmental Matters

We are subject to China's national and local environmental protection laws. These laws could hold us liable for the costs of removal and remedy of certain hazardous substances or wastes released on our property regardless of whether we were responsible for the presence of hazardous substances. The presence of hazardous substances, or the failure to properly remedy them, may have a material adverse effect on our results of operations and financial condition. As of December 31, 2009, we are not aware of any material noncompliance, liability or claim relating to hazardous or toxic substances in connection with our property and operations. To date, we have not incurred any costs in complying with environmental laws and regulations. We believe that we are in material compliance with these laws and regulations.

Patents and Trademarks

We do not own any patents or trademarks.

Product Research and Development

To date we have not conducted any product research and development. We do not plan to conduct any product research and development activities in the next twelve months.

Employees

As of December 31, 2009, we had 17 full-time employees. We expect that there will be no significant changes in the number of employees in the coming twelve months. None of our employees is represented by trade unions. We consider our employee relations to be satisfactory.

Item 2. Description of Property

Our executive offices moved from 19th Floor, Building C, Tianchuangshiyuan, Huizhongbeili, Chaoyang District, Beijing, China, 100012 to 8th Floor, Officer Tower 3, Henderson Center, 18# Jianguomennei Street Dongcheng District, Beijing, China 100005 which was newly bought by Dahua Group. We have contracted with Dahua Group to provide administrative and management services. Included in those services are the payment of officer salaries and provision of office space and other shared costs and services. We believe that these facilities are adequate for our current and anticipated needs.

We began our clubhouse construction in April 2007. The new building has four stories. The Company plans to use two stories for its office and administration, and give out the other two stories (lease free) to the home owner association. The home owner association will hire a third party to collect usage fee and maintain the facilities at their cost. The construction cost of clubhouse was allocated in account of construction in progress. As of December 31, 2009, the clubhouse has completed and half of the cost $1,213,063 was carried forward to the fixed assets. The other half was carried forward to the inventory and cost of goods sold for free usage of the clubhouse .

Investment Policies

At present we have no established policy with respect to investments on real estate or interests in real estate. However, we intend that substantially all of our investments will be residential luxurious single-family houses. The purpose of such investments will primarily be generating sales revenues. There are no limitations on the percentage of assets which may be invested in any one investment or type of investment. Our Board of Directors may set such policy without a vote of our shareholders. We will not invest in real estate mortgages, and we will not invest in securities of or interests in real estate investment trusts, partnership interests, or other persons primarily engaged in real estate activities.

We do not plan to limit the geographical area in which we may invest, but we expect that all of our investments will be made in metropolitan Beijing, China or circumjacent land. We have no current plans to form a joint venture or other arrangements with third parties to engage in real estate development.

We may finance our investments through both public and private secured and unsecured debt offerings, as well as public and private placements of our equity securities. The equity securities may include both common and preferred equity issues. There are currently no restrictions on the amount of debt that we may incur. Since inception, our operating activities have been mainly financed by equity capital, an unsecured line of credit provided by Dahua Group, our affiliate, and purchaser deposits received from our pre-sale of the First Phase units of Dahua Garden.

Description of Real Estate and Operating Data

One of our completed real estate projects is the First Phase of Dahua Garden, which is located in the northern suburban areas of Beijing, China, approximately 20 kilometers from the downtown of Beijing. It consists of 75 luxurious residential units, each ranging from 2,000 to 5,000 square feet in size with 3 to 4 bedrooms. The residential units are constructed on a piece of land of approximately 20,000 square meters. The construction of all of the units has been completed and they are being sold to the public. As the developer, we do not have title to the land, the use of which is licensed from the Chinese government for a period of 70 years expiring on April 27, 2073, but we own all the residential units constructed thereon until such units are sold. There are no material mortgages, liens or other encumbrances against the land or residential units. Upon conveyance of title to the residential units to the buyer, the land use rights will be passed to the buyer.

In the newly-publicized layout of Changping district the purpose of the land on which the Second Phase of Dahua Garden located has been recognized as residential land. We are now in the process of applying for the first-degree development right of this land. The Second Phase of Dahua Garden development will include 250 homes with community clubhouse, creeks, ponds, and professionally manicured gardens and landscape.

We, through our subsidiary Zhuolu Dahua Real Estate which was established on May 21, 2008 and was wholly-owned by Beijing Dahua Real Estate, are engaging in the business of development, construction and sale of luxury residential single-family homes in Zhuolu county, Hebei province which is about 140 kilometers faraway from Beijing. The first phase will consist of 246 luxury residential units, all of which are single-family houses ranging from approximately 2,000 to 5,000 square feet, each with 3 – 4 bedrooms. The residential units are constructed on a piece of land of approximately 31,200 square meters. We have got all the permits needed and are now in the process of construction. As the developer, we do not have title to the land, the use of which is licensed from the Chinese government for a period of 70 years expiring on March 25, 2078, but we own all the residential units constructed thereon until such units are sold. There are no material mortgages, liens or other encumbrances against the land or residential units. Upon conveyance of title to the residential units to the buyer, the land use rights will be passed to the buyer.

Item 3. Legal Proceedings

There are no legal actions pending against us nor are any legal actions contemplated by us.

Item 4. Submission of Matters to a Vote of Security Holders

No matters were submitted to a vote of security holders during the fourth quarter ended December 31, 2009.

PART II

Item 5. Market for Common Equity and Related Stockholder Matters

Market Information

Our common stock has been quoted on the OTC Bulletin Board under the symbol "DHUA.OB" since December 14, 2007. Trading in our common stock has been minimal with limited or sporadic quotations and there is no established public trading market for our shares.

Holders

As of December 31, 2009, there were 111 holders of record for our common shares. We have only one class of stock outstanding. For the help that Pacific Services provided in the company’s Form 211 reporting in the United States, the company issued 15,000 shares of the Company’s Common Stock, $0.0001 par value per share to Pacific Services Inc in January 2, 2008. The fair value of this share paid for services is $0.05.

Stock Options, Warrants and Convertible Securities

We have not granted any stock options or warrants to purchase shares of our common stock, and we have not issued and do not have any securities outstanding that may be converted into our common shares or have any rights convertible or exchangeable into shares of our common stock.

Dividends

We have not paid any dividends since our incorporation and do not anticipate paying dividends in the foreseeable future. We intend to retain future earnings, if any, to fund the expansion and growth of our business.

There are no restrictions in our Articles of Incorporation or Bylaws that prevent us from declaring dividends. The Delaware Revised Statutes, however, do prohibit us from declaring dividends, after giving effect to the distribution of the dividend if: (i) we would not be able to pay our debts as they become due in the usual course of business; or (ii) our total assets would be less than the sum of our total liabilities plus the amount that would be needed to satisfy the rights of shareholders who have preferential rights superior to those receiving the distribution.

Securities Authorized for Issuance under Equity Compensation Plans

We do not have any compensation plan under which equity securities are authorized for issuance.

Rule 144 Shares

As of December 31, 2009, there were 25,015,000 shares of common stock issued and outstanding, of which 17,452,000 are “restricted securities”, as that term is defined under Rule 144 of the Securities Act of 1933. Under Rule 144, such shares can be publicly sold, subject to volume restrictions and certain restrictions on the manner of sale, commencing one year after their acquisition.

In general, under Rule 144 as currently in effect, any of our affiliates and any person or persons whose sales are aggregated who has beneficially owned his or her restricted shares for at least one year, may be entitled to sell in the open market within any three-month period a number of shares of common stock that does not exceed the greater of (i) 1% of the then outstanding shares of our common stock, or (ii) the average weekly trading volume in the common stock during the four calendar weeks preceding such sale. Sales under Rule 144 are also affected by limitations on manner of sale, notice requirements, and availability of current public information about us. Non-affiliates, who have held their restricted shares for one year may be entitled to sell their shares under Rule 144 without regard to any of the above limitations, provided they have not been affiliates for the three months preceding such sale.

Item 6. Management's Discussion and Analysis or Plan of Operation

We were incorporated on March 8, 2002 in the State of Delaware under the name of Norton Industries Corp. ("Norton") as a blank check company for the purpose of either merging with or acquiring an operating company with operating history and assets. From March 8, 2002 to January 30, 2005, Norton had conducted virtually no business other than organizational matters and the filings of periodic reports with the SEC pursuant to the reporting requirements of the Securities Exchange Act of 1934, as amended.

On January 30, 2005, Norton entered into a share exchange agreement, by which Norton acquired all of the capital shares of Bauer Invest Inc. Bauer is a holding company, which conducts its business through its 80% owned subsidiary Beijing Dahua Real Estate Development, Ltd., an operating company organized in China ("Beijing Dahua Real Estate"). As a result of this transaction, Bauer became our wholly owned subsidiary. This transaction was accounted for as a recapitalization, rather than a business combination. Under accounting principles generally accepted in the United States of America, after completion of this transaction, we filed prior historical financial information of Bauer and its subsidiaries, on a stand-alone basis, for two years prior to the acquisition. Our continuing operations reflect the consolidated operations of Dahua and its subsidiaries.

We, through our subsidiary Beijing Dahua Real Estate Development Ltd., are engaged in the business of development, construction and sale of luxury residential single-family homes in Beijing, China. In July 2003, we began to develop our first real estate project, Dahua Garden (the "First Phase"), which consists of 75 luxury residential units, all of which are single-family houses ranging from approximately 2,000 to 5,000 square feet, each with 3 – 4 bedrooms. The construction site is located at the northern skirt of Beijing, China. The construction began in July 2003 and was completed in December 2005. As of December 31, 2009, out of 75 luxury residential units, 67 units have been sold, 8 units were reserved with clients' deposits.

On May 21, 2008 we established Zhuolu Dahua Real Estate Development Ltd which was wholly-owned by Beijing Dahua Real Estate Development Ltd. and engage in the business of development, construction and sale of luxury residential single-family homes in Zhuolu county, Hebei province which is about 140 kilometers faraway from Beijing. The first phase of the project which known as Xuanyuan Lakefront will consist of 246 luxury residential units, all of which are single-family houses ranging from approximately 2,000 to 5,000 square feet, each with 3 – 4 bedrooms. We have got all the permits needed and are now in the process of construction. The company wants to create a demonstration base of ecological buildings circumjacent to Beijing.

We are also applying for the permits of the Second Phase of Dahua Garden. In the newly-publicized layout of Changping district the purpose of the land on which the Second Phase of Dahua Garden located has been recognized as residential land. We are now in the process of applying for the first-degree development right of this land.

Results of Operations

Years Ended December 31, 2009 and 2008

Revenues

We began our First Phase of Dahua Garden construction, which consists of 75 luxury residential units, in July 2003. The construction was substantially completed in December 2005. As of December 31, 2009, we have sold 67 units out of 75 units. We recognized sales revenues of $2,545,171 and $1,268,627 from the sale of our housing units, for the years ended December 31, 2009 and 2008, respectively.

Cost of Good Sold

Cost of good sold consists primarily of land acquisition and development costs, engineering, infrastructure, capitalized interest, and construction costs. For the years ended December 31, 2009 and 2008, our cost of goods sold was $3,499,839 and $1,020,978 respectively. We made a provision of $27,443 for houses which will be sold below cost. As of December 31, 2009, we didn’t recognize the sales revenues of such houses, because they didn’t meet the requirement of revenue recognition. However, the sales prices of such houses were predetermined. Since the cost per square meter increased in 2009, it is estimated that the revenues will be lower than the costs when the revenues are recognized.

Construction in progress has completed on December 31, 2009 and for the reason that two stories of which was used as clubhouse for the homeowners part of the cost of construction in progress was carried forward to cost of goods sold. As of December 31, 2009, the balance which was carried forward to cost of goods sold was $1,149,871.

Operating Expenses

For the year ended December 31, 2009, our operating expenses decreased by $165,343, or 23%, to $554,649 from $719,992 in the prior year, mainly due to the decrease of the advertising expense, which decreased $70,950. The payroll expense increased $50,409, or 55.8%. Other general and administrative expenses decreased $135,955, or 30.8%.

Net Income

For the year ended December 31, 2009, we had net loss of $902,327 or $ 0.04 per share, as compared with net loss of $247,371, or $0.01 per share, for the year of 2008.

Liquidity and Capital Resources

Since inception, our operations have been primarily funded by equity capital, unsecured short-term loans from Dahua Project Management Group ("Dahua Group"), our affiliate, and customer deposits that we received from our pre-sale of housing units.

After receiving the Residential Housing Pre-sale Permit issued by the government, we are permitted to sell the residential units to be built to the public, which is common practice in China. Upon execution of a binding purchase contract between the developer and a homebuyer, a deposit and installment payments are required to be made to the developer, which we use to construct our residential housing units. As of December 31, 2009, our customer deposit balance was $3,681,057.

We also borrow from time to time based on a verbal line of credit agreement from Dahua Group, our affiliate. There was no written line of credit agreement until June 20, 2005, to recapture the credit arrangement. The funds so borrowed are unsecured and there is no upper limit on the amount of money that we can borrow as long as there are funds available and we need it for our operation. The money we borrow under this arrangement bears interest at an annual rate of 6%, repayable within 30 days upon demand by the lender. As of December 31, 2009, the short-term loans due to related parties had balance of $1,912,796, including accrued interest of $229,373.

On May 12, 2005, Beijing Dahua Real Estate Development, Ltd, our operating subsidiary, increased its registered capital, in which Dahua increased its investment by $2,265,600 and the minority shareholder increased its investment by $566,265. Dahua Group advanced funds to us to allow for the increase in investment. On September 21, 2005, we issued 4,750,000 shares to Dahua Group at the price of $0.477 per share in exchange for the short-term loans Dahua Group provided. At the same time, according to the Shares Exchange Agreement signed on January 30, 2005, it is our responsibility to maintain the ownership percentage held by Comp Hotel International Ltd. ("Comp Hotel") and Waywood Investments Ltd. ("Waywood"). In this regard, we issued 212,500 shares and 37,500 shares to Comp Hotel and Waywood, respectively. There was no cash inflow from this issuance. After the capital increase, the subsidiary's registered capital is $4,036,145, of which we, through Bauer, hold 80% of the shares of Dahua Real Estate.

As of December 31, 2009, we had cash and cash equivalent balance of $65,801. For the year ended December 31, 2009, our operating activities used $969,469 of net cash, largely due to decrease of customer deposits which were 1,759,647 as of December 31, 2009. For the year ended December 31, 2009, the investing activities provided $23,377 of net cash, mainly due to other receivables receipts. For the same period, the financing activities provided $834,840 of net cash, which was due to net proceeds from loans payable to related parties.

As of December 31, 2005, our First Phase of Dahua Garden was completed. We are currently applying with Beijing municipal and Changping district governmental agencies for all the requisite licenses, permits, and approvals to start our Second Phase of Dahua Garden. It is estimated that approximately $60.5 million is needed to complete the Second Phase.

We are also now in the process of construction of the project in Zhuolu through our subsidiary Zhuolu Dahua Real Estate Development Ltd. The first phase of Xuanyuan Lakefront will consist of 246 luxury residential units. It is estimated that approximately $17.5 million is needed to complete the Second Phase.

In addition to customer deposits, and short-term loans (line of credit) from Dahua Group, the proceeds generated from sale of the First Phase of Dahua Garden will also be used to finance projects development. There are no material commitments for capital expenditures.

While there can be no assurance that we will have sufficient funds over the next twelve months, we believe that funds generated from the sale of our First Phase of Dahua Garden housing units, purchaser deposits from pre-sale contracts, and the line of credit provided by our affiliate, Dahua Group, will be adequate to meet our anticipated operating expenses, capital expenditure and debt obligations for at least the next twelve months. Nevertheless, our continuing operating and investing activities may require us to obtain additional sources of financing. In that case, we may seek financing from institutional investors, banks, or other sources of financing. There can be no assurance that any necessary additional financing will be available to us on commercially reasonable terms, if at all.

Off-balance sheet arrangements

We entered into an agreement with a bank that extended mortgage loans to our home buyers, whereby we agreed to provide a certain limited guarantee, which covers the risk before the conveyance of title upon closing. Upon initiating the loan on behalf of the buyer for the down payment, the bank has withheld a percentage ranging from 5% to 20% of the loan and deposited such funds into a segregated account in the bank. At December 31, 2009, the balance of this separate account was $734,317. Since the Company does not recognize revenue when its receivables are subject to future subordination, the entire amount that could become payable to the bank under the limited guarantee is recorded as a liability on the balance sheet and is included in customer deposits. Please see Note 6 and Note 7 of Notes to the Consolidated Financial Statements for details.

Critical Accounting Policies and Estimates

Our financial statements have been prepared in accordance with accounting principles generally accepted in the United States. The preparation of these financial statements requires us to make estimates and judgments that affect the reported amounts of assets, liabilities, revenue and expenses, and related disclosure of contingent assets and liabilities. On an on-going basis, we evaluate our estimates, which are based on our historical experience and on various other assumptions that are believed to be reasonable under the circumstances, the results of which form the basis for making judgments about the carrying values of assets and liabilities that are not readily apparent from other sources. Actual results may differ from these estimates under different assumptions or conditions. We believe that revenue recognition is one of our more significant judgments and estimates used in the preparation of our financial statements.

Revenue Recognition

The Company recognizes revenue on the sale of a house when the consummation of a sale is evidenced by: 1) a contractual arrangement that is binding to both parties; 2) the exchange of all consideration (i.e. the seller has transferred to the buyer the usual risks and rewards of ownership and the buyer has made payment in full to the seller); 3) the arrangement of all permanent financing for which the seller is responsible and; 4) the performance of all conditions precedent to closing. No revenue is recognized when the Company’s receivable is subject to future subordination, as is the case when the Company guarantees a bank loan for the period prior to the certification of title transfer.

Inventory Valuation and Related Prepaid Construction Costs

The inventories are valued at cost based on the level of completion using the weighted-average method. The company made a provision of $27,443 for houses which will be sold below cost. As of December 31, 2009, the company didn’t recognize the sales revenue of such houses, because they didn’t meet the requirement of revenue recognition. However the sales prices of such houses were predetermined. Since the cost per square meter increased in 2009, it is estimated that the revenues will be lower than the costs when the revenues are recognized.

Construction in progress has completed on December 31, 2009 and half of the cost of construction in progress was carried forward to cost of goods sold and inventory for the reason that two stories of which was used as clubhouse for the homeowners. As of December 31, 2009, the balance which was carried forward to cost of goods sold and inventory was $1,149,871 and $147,517.

Prepaid construction costs consist of payment to our subcontractors before they provide us services. Prepaid construction costs were converted into inventory when the subcontractors finished their work.

At each balance sheet date, we review the carrying amounts of our tangible and intangible assets to determine whether there is any indication that those assets have suffered an impairment loss. If any such indication exists, the recoverable amount of the asset is estimated in order to determine the extent of the impairment loss (if any). Where it is not possible to estimate the recoverable amount of an individual asset, the company estimates the recoverable amount of the cash-generating unit to which the asset belongs.

Recoverable amount is the greater of net selling price and value in use. In assessing value in use, the estimated future cash flows are discounted to their present value using a pre-tax discount rate that reflects current market assessments of the time value of money and the risks specific to the asset.

If the recoverable amount of an asset (or cash-generating units) is estimated to be less than its carrying amount, the carrying amount of the asset (cash- generating unit) is reduced to its recoverable amount. An impairment loss is recognized as an expense immediately.

RISK FACTORS

Investing in shares of our common stock involves a high degree of risk. You should carefully consider the following risk factors, in addition to the other information set forth in this report, before you purchase these shares. The risks and uncertainties described below are those we have identified as material. If any of the events contemplated by the following discussion of risks should occur, our business, financial condition and results of operations may suffer. As a result, the trading price of our common stock could decline and you could lose part or all of your investment in our common stock.

Risks Related to Our Business

WE LACK AN OPERATING HISTORY UPON WHICH AN EVALUATION OF OUR FUTURE SUCCESS OR FAILURE CAN BE MADE.

We were incorporated in March 2002 as a blank check company for the purpose of seeking to complete a merger or business acquisition. We conducted virtually no business until January 30, 2005, when we acquired Bauer Invest Ltd. Bauer is a holding company, which conducts its business through its 80% owned subsidiary Beijing Dahua Real Estate Development, Ltd., a private company operating in the People's Republic of China (“Beijing Dahua Real Estate”). Dahua Real Estate was incorporated on September 24, 2001, to engage in the development and sale of luxury single-family houses in Beijing, China. The acquisition of Bauer was accounted for as a recapitalization, rather than a business combination. Accordingly, the historical operations of Bauer and its subsidiaries were represented as our historical operations. Our limited operating history makes it difficult for you to evaluate our business and future prospects.

WE WILL NEED ADDITIONAL FINANCING TO CARRY OUT OUR SECOND PHASE PROJECT AND THE PROJECT IN ZHUOLU. IF WE ARE UNABLE TO OBTAIN ADDITIONAL FINANCING, WE MAY HAVE TO DELAY THE IMPLEMENTATION OF OUR PROJECTS, AND OUR ABILITY TO INCREASE REVENUE WILL BE MATERIALLY IMPAIRED.

Since inception, we have been dependent on short-term loans and customer deposits to meet our cash requirements. As of December 31, 2005 we completed the construction of our First Phase of Dahua Garden project consisting of 75 luxury single-family houses. Of 75 units, 67 houses were sold and 8 houses were reserved with clients’ deposits at December 31, 2009. We are currently applying with Beijing municipal and Changping district governmental agencies for the first-degree development right of the Second Phase of Dahua Garden. To date we have not received any licenses, permits or approvals from governmental authorities to commence our Second Phase construction. It is estimated that we need approximately $60.5 million in order to complete our Second Phase project. We are also in the process of construction of Xuanyuan Lakefront in Zhuolu county in Hebei province through our subsidiary Zhuolu Dahua Real Estate. It is estimated that we needed approximately $17.5 in order to complete the project. We intend to use (i) our proceeds from sales of our First Phase housing units, (ii) customer deposits from our pre-sale of the housing units in the Second Phase, and (iii) short-term borrowings from Dahua Group, our affiliate, to finance our projects. At present we do not have any arrangements for additional financing. If we are unable to obtain additional financing on terms acceptable to us, we may have to delay or curtail our Second Phase project, and our ability to increase revenue will be materially impaired.

IF WE RAISE ADDITIONAL CAPITAL THE VALUE OF YOUR INVESTMENT MAY DECREASE.

If we need to raise additional capital to implement or continue operations, we will likely issue additional equity or convertible debt securities. If we issue equity or convertible debt securities, the net tangible book value per share may decrease, the percentage ownership of our current stockholders may be diluted and such equity securities may have rights, preferences or privileges senior to or more advantageous than our common stockholders.

WE NEED PERMITS, LICENSES OR APPROVALS FROM GOVERNMENT AUTHORITIES TO BEGIN OUR CONSTRUCTION OF THE SECOND PHASE PROJECT. IF WE FAIL TO OBTAIN ALL REQUIRED LICENSES, PERMITS, OR APPROVALS, OUR OPERATION WILL BE MATERIALLY IMPAIRED

Before we can develop a property, we must obtain a variety of approvals from local and municipal governments with respect to such matters as zoning, density, subdivision, traffic considerations, site planning and environmental issues. Although there are currently no unfavorable rulings that would have a significant adverse effect on the development of our proposed Second Phase of Dahua Garden, there is no assurance that we will be able to obtain all required licenses, permits, or approvals from government authorities. If we fail to obtain all required licenses, permits, or approvals, our operation will be materially impaired.

RECENT PRC REGULATIONS RELATING TO CUTTING DOWN LUXURY SINGLE FAMILY HOUSE CONSTRUCTIONS MAY LIMIT OUR ABILITY TO IMPLEMENT OUR BUSINESS PLAN. IF NO CONSENTS AND APPROVALS ARE OBTAINED, WE MAY HAVE TO CEASE OUR SECOND PHASE OF SINGLE LUXURY FAMILY HOUSE OPERATIONS, AND CHANGE OUR BUSINESS PLAN TO BUILD APARTMENT BUILDINGS.

In August 2006, the Chinese government issued a series of rules and regulations in an attempt to push down rising house prices in China by cutting down luxury single family house constructions and supporting construction of apartment buildings. Under the government’s new policy, (i) no single family houses can be built, if the construction has not started, without special construction permits. All permits issued previously have to be re-reviewed and re-approved; and (2) the land previously acquired for luxury housing construction have to be revalued and sold to the people who offer the most money for the land. Because of those new government policies, we have incurred a long delay for obtaining the consents and approvals to commence our construction for the second phase of Dahua Garden. As of the date of this report, we don’t have any current plan or arrangements for development of apartment buildings.

WE ACT AS GENERAL CONTRACTOR ON OUR CONSTRUCTION PROJECTS, AND IF ANY OF OUR SUBCONTRACTORS SHOULD FAIL TO COMPLETE THEIR JOBS ON TIME, OUR BUSINESS COULD BE DISRUPTED.

We act as general contractor on our construction projects. We hire unaffiliated subcontractors to do work for us. In the event that any of our subcontractors should fail to complete their jobs on time, our business could be disrupted, which will have an adverse effect on our results of operation and our financial condition.

WE DEPEND ON KEY PERSONNEL FOR THE SUCCESS OF OUR BUSINESS. OUR BUSINESS MAY BE SEVERELY DISRUPTED IF WE LOSE THE SERVICES OF OUR CEO OR FAIL TO SUCCESSFULLY RECRUIT QUALIFIED MANAGERIAL PERSONNEL HAVING EXPERIENCE IN BUSINESS.

Our success is heavily dependent upon the continued service of Yonglin Du, our chief executive officer. Mr. Du has valuable personal relationships with government agencies and executive officers in the industry. A good personal relationship is sometimes crucial for doing business in China. If Mr. Du is unable or unwilling to continue in his position, we may not be able to easily replace him. Loss of his services could delay our applications for construction permit and land acquisition, and our business may be severely disrupted. We do not maintain key-man insurance on the life of Mr. Du. In addition, in order to successfully implement and manage our business plan, we will be dependent upon, among other things, successfully recruiting qualified managerial personnel having experience in business. Competition for qualified individuals is intense. There can be no assurance that we will be able to retain existing employees or that we will be able to find, attract and retain qualified personnel on acceptable terms.

OUR OFFICERS AND DIRECTORS ARE SUBJECT TO CONFLICTS OF INTEREST, AND THERE IS A RISK THAT THEY MAY PLACE THEIR INTERESTS AHEAD OF YOURS.

We believe that our officers and directors will be subject to conflicts of interest. The conflicts arise from their relationships with our affiliate. Yonglin Du, our chief executive officer, also serves as president and a director of Dahua Project Management Group Co. Ltd. (“Dahua Group”), a Beijing Municipal Government licensed construction project supervising business entity. Hua Meng, our chief financial officer, and Qinna Zeng, our corporate secretary, are also employed by Dahua Group. They may have conflicts of interest in allocating time, services, and functions between us and Dahua Group, in which any of them are or may become involved. Mr. Du anticipates devoting a minimum of twenty to thirty-two hours per week of his business hours, and each of Ms. Meng and Ms. Zeng fifteen to twenty hours of their business hours to our business activities. If and when the business operations increase and a more extensive time commitment is needed, they are prepared to devote more time to our affairs, in the event that becomes necessary.

To ensure that potential conflicts of interest are avoided or declared to us and to comply with the requirements of the Sarbanes-Oxley Act of 2002, our Board of Directors, on January 30, 2005, adopted a Code of Business Conduct and Ethics, among other things, to reduce potential conflicts of interest. Conflicts of interest must, to the extent possible, be avoided, and any material transaction or relationship involving a potential conflict of interest must be reviewed and approved in advance by a majority of the board of directors, or, if required by law, a majority of disinterested stockholders. No personal loans will be made to executive officers and directors.

All our transactions with affiliates have been and will be made on terms no less favorable to us than could have been obtained from unaffiliated third parties. Our policy is to require that a majority of board members approve all transactions between us and our officers, directors, principal stockholders and their affiliates.

WE HAVE NOT CARRIED PROPERTY OR CASUALTY INSURANCE. ANY BUSINESS

DISRUPTION, LITIGATION OR NATURAL DISASTER MIGHT RESULT IN SUBSTANTIAL COSTS AND DIVERSION OF RESOURCES.

The insurance industry in China is still at an early stage of development. Insurance companies in China offer limited business insurance products, and do not, to our knowledge, offer business liability insurance. As a result, we do not have any business liability insurance coverage for our operations. Any business property loss, natural disaster or litigation might result in substantial costs and diversion of resources.

OUR QUARTERLY OPERATING RESULTS, REVENUES AND EXPENSES MAY FLUCTUATE SIGNIFICANTLY, WHICH COULD HAVE AN ADVERSE EFFECT ON THE MARKET PRICE OF OUR COMMON STOCK.

Our operating results, revenues and expenses may fluctuate significantly from quarter to quarter due to a variety of factors including:

The timing, size and execution of sales contracts and home deliveries;

Lengthy and unpredictable sales cycles;

Changes in our operating expenses; and

Fluctuations in general economic conditions.

We believe that period-to-period comparisons of our results of operations are not a good indication of future performance. It is possible that our operating results will be below your expectations. In that event, the trading price of our common stock may fall.

MANY OF OUR COMPETITORS ARE SIGNIFICANTLY LARGER THAN WE ARE, AND THEY HAVE GREATER FINANCIAL RESOURCES AND HAVE MORE EXPERIENCED MANAGERS THAN WE DO.

We are a small company and have little market share in our target market. The market of residential housing development in Beijing, China, is highly competitive. We compete with numerous entities, many of which are significantly larger than we are, and have greater financial resources and have more experienced managers than we do. As a result, they may be able to respond more quickly to new or emerging house plans or construction materials and changes in customer demands or to devote greater resources to the development, promotion and sale of their products or services than we can. If we cannot compete effectively, we may never become profitable. Although no one of our competitors currently dominates or significantly influences the market, they could adversely affect us.

THE RESIDENTIAL REAL ESTATE DEVELOPMENT INDUSTRY IS A HIGH RISK INDUSTRY. IF MARKET CONDITIONS CHANGE DRAMATICALLY UNFAVORABLY TO US, WE MAY GO OUT OF BUSINESS.

The real estate development industry in general, and the residential luxury real estate development industry in particular, is a high risk industry, subject to changes in general economic conditions, fluctuating interest rates, and changing demand for the types of developments being considered. Volatility in local and regional land use demands, as well as changing supply and demand for the specific uses for which the real property is being developed, are also factors in assessing the relative risks of the business. The demand for residential real estate development is particularly sensitive to changing interest rates and shifting demographics. Both of these factors affecting the demand for residential housing are highly unpredictable over both the short-and long-term. If market conditions change dramatically and unfavorably to us, we may go out of business.

Risks Related to Doing Business in China

POLITICAL AND ECONOMIC POLICIES IN CHINA COULD AFFECT OUR BUSINESS IN UNPREDICTABLE WAYS.

Substantially all of our assets are located in China and substantially all of our revenues are expected to derive from our operations in China. Therefore, our results of operations and prospects are subject, to a significant degree, to economic and political developments in China. The economy of China differs from the economies of most developed countries in many respects, including:

The extent of government involvement;

Level of development; and

Allocation of resources.

The economy of China has been in transition from a planned economy to a more market-oriented economy. Although in recent years the Chinese government has implemented measures emphasizing the utilization of market forces and the reduction of state ownership of productive assets, a substantial portion of productive assets in China is still owned by the Chinese government, which continues to play a significant role in regulating China's economic development, setting monetary policy and providing preferential treatment to particular industries or companies. Political and economic policies in China could affect our business in unpredictable ways. If there are any unfavorable changes in government policies, such as government control over capital expenditures, changes in monetary policy, or changes in planning and zoning policy, we may experience delays or other problems in obtaining government permits or licenses to start or complete our projects.

OUR ASSETS, OFFICERS AND DIRECTORS ARE LOCATED OUTSIDE OF THE U.S. IT IS DIFFICULT TO EFFECT SERVICE OF PROCESS AND ENFORCEMENT OF LEGAL JUDGMENTS UPON US AND OUR OFFICERS AND DIRECTORS.

Our assets, officers and directors are located in China. As a result, it may be difficult to effect service of process within the United States and enforce judgment of the US courts obtained against us and our executive officers and directors. Particularly, our shareholders may not be able to:

Effect service of process within the United States on us or any of our executive officers and directors;

Enforce judgments obtained in U.S. courts against us based upon the civil liability provisions of the U.S. federal securities laws;

Enforce, in a court in China, judgments of U.S. courts based on the civil liability provisions of the U.S. federal securities laws; and

Bring an original action in a court in China to enforce liabilities against us or any of our executive officers and directors based upon the U.S. federal securities laws.

GOVERNMENT CONTROL OF CURRENCY CONVERSION MAY AFFECT OUR ABILITY TO PAY DIVIDENDS DECLARED, IF ANY, IN FOREIGN CURRENCIES.

It is expected that a substantial portion of our revenues, if any, will be in “yuan”, the national currency of China, which is currently not a freely convertible currency. A portion of our revenues may have to be converted into US dollars to make payment of dividends declared, if any, in respect of our common shares. Under China's existing foreign exchange regulations, we will be able to pay dividends in foreign currencies without prior approval from the State Administration of Foreign Exchange of China by complying with certain procedural requirements. However, the Chinese government may take measures at its discretion in the future to restrict access to foreign currencies if foreign currencies become scarce in China. We may not be able to pay dividends in foreign currencies to our shareholders if the Chinese government restricts access to foreign currencies for current account transactions.

FLUCTUATIONS IN THE EXCHANGE RATE BETWEEN THE CHINESE CURRENCY AND THE UNITED STATES DOLLAR MAY BRING DOWN OUR OPERATING INCOME.

The functional currency of our operations in China is "Yuan." Results of our operations are translated at average exchange rates into United States dollars for purposes of reporting results. As a result, fluctuations in exchange rates may adversely affect our expenses and results of operations as well as the value of our assets and liabilities. On July 21, 2005, the Chinese government changed its decade-old policy of pegging the value of yuan to the U.S. dollar. Under the new policy, Yuan is permitted to fluctuate within a narrow and managed band against a basket of certain foreign currencies. This change in policy has resulted in an approximately 17.6% appreciation of the yuan against the U.S. dollar between July 21, 2005 and December 31, 2009. Our revenues and costs are denominated in yuan, and our financial assets are also denominated in yuan. Any significant fluctuations in the exchange rate between the yuan and the United States dollar may bring down our operating income and lower our stock price. We have no current plans to undertake any hedging activity to minimize exchange rate fluctuations.

Risks Related to Investment in Our Securities

OUR COMMON STOCK IS QUOTED ON THE OVER-THE-COUNTER BULLETIN BOARD WHICH MAY MAKE IT MORE DIFFICULT FOR STOCKHOLDERS TO SELL THEIR SHARES AND MAY CAUSE THE MARKET PRICE OF OUR COMMON STOCK TO DECREASE.

Because our common stock is quoted on the OTC Bulletin Board, the liquidity of our common stock is impaired, not only in the number of shares that are bought and sold, but also through delays in the timing of transactions, and limited coverage by security analysts and the news media of us. As a result, prices for shares of our common stock may be lower than might otherwise prevail if our common stock was traded on NASDAQ or a national securities exchange, like the American Stock Exchange.

THERE HAS BEEN LOW VOLUME AND THEREFORE AN INACTIVE MARKET FOR OUR COMMON STOCK, OUR STOCK PRICE MAY BE VOLATILE OR MAY DECLINE REGARDLESS OF OUR OPERATING PERFORMANCE, AND YOU MAY NOT BE ABLE TO RESELL YOUR SHARES AT OR ABOVE YOUR STOCK PURCHASE PRICE.

If you purchase shares of our common stock, you may not be able to resell those shares at or above your original purchase price. An active or liquid market in our common stock may not develop or, if it does develop, it may not be sustainable. The market price of our common stock may fluctuate significantly in response to numerous factors, many of which are beyond our control.

OUR COMMON STOCK IS DEEMED A PENNY STOCK. AS A RESULT, TRADING OF OUR SHARES IS SUBJECT TO SPECIAL REQUIREMENTS THAT COULD IMPEDE OUR SHAREHOLDERS' ABILITY TO RESELL THEIR SHARES.

The shares offered by this prospectus constitute penny stock under the Securities Exchange Act of 1934 (the “Exchange Act”). The shares will remain penny stock for the foreseeable future. As defined in Rule 3a51-1 of the Exchange Act, penny stocks generally are equity securities with a price of less than $5.00, other than securities registered on certain national securities exchanges or quoted on the NASDAQ system, provided that current price and volume information with respect to transactions in such securities is provided by the exchange or system.

Section 15(g) of the Exchange Act and Rule 15g-2 of the Exchange Act require broker-dealers dealing in penny stocks to provide potential investors with a document disclosing the risks of penny stocks and to obtain a manually signed and dated written receipt of the document before effecting any transaction in a penny stock for the investor's account. Moreover, Rule 15g-9 of the Exchange Act requires broker-dealers in penny stocks to approve the account of any investor for transactions in such stocks before selling any penny stock to that investor. This procedure requires the broker-dealer to:

Obtain from the investor information concerning his or her financial situation, investment experience and investment objectives;

Reasonably determine, based on that information, that transactions in penny stocks are suitable for the investor and that the investor has significant knowledge and experience to be reasonably capable of evaluating the risks of penny stock transactions;

Provide the investor with a written statement setting forth the basis on which the broker-dealer made the determination in (ii) above; and

Receive a signed and dated copy of such statement from such investor, confirming that it accurately reflects the investor's financial situation, investment experience and investment objectives.

Compliance with these requirements may make it more difficult for investors in our common stock to resell the shares to third parties or to otherwise dispose of them.

Item 7. Financial Statements

The following report of independent registered public accounting firm and the consolidated financial statements of the Company are included below:

Report of Independent Registered Public Accounting Firm		26
Consolidated Balance Sheets		27
Consolidated Statements of Operations and Comprehensive Income		28
Consolidated Statements of Cash Flows		29
Consolidated Statements of Changes in Equity		30
Notes to Consolidated Financial Statements		31

Dahua, Inc.

Consolidated Financial Statements

For the Years Ended December 31, 2009 and 2008

DAHUA, INC.

CONSOLIDATED BALANCE SHEETS

	December 31, 2009			December 31, 2008
ASSETS
Current assets:
Cash and cash equivalents	$	65,801		$	176,935
Inventory-short-term		3,651,644			7,756,324
Prepaid expenses		42,603			10,061
Deferred taxes - current		480,700			104,473
Total Current Assets		4,204,748			8,047,793

Property, plant and equipment, net of accumulated depreciation		1,574,567			465,220

Construction in progress		-			2,152,604
Inventory-long-term		3,278,726			-
Net other receivables		4			161,489
Due from related parties		-			658
Prepaid tax		569,340			716,638
Restricted cash		734,317			731,238
Total Assets	$	10,361,702		$	12,275,640

LIABILITIES AND EQUITY
Current liabilities:
Accounts payable	$	423,940		$	337,601
Customer deposits		3,681,057			5,436,356
Short-term loans - related parties		1,683,423			847,435
Accrued interest - short-term loans, related parties		229,373			190,087
Other accruals		225,593			222,368
Total Current Liabilities		6,243,386			7,033,847

Dahua Inc. stockholders' equity:
Preferred stock: par value $0.0001; 20,000,000 shares authorized;
none issued and outstanding		-			-
Common stock: par value $0.0001; 80,000,000 shares authorized;
25,015,000 shares issued and outstanding		2,502			2,502
Additional paid-in capital		3,131,200			3,131,200
Retained earnings (deficit)		(560,814	)		341,513
Accumulated other comprehensive income		788,324			784,778
Total Dahua Inc. stockholders' equity		3,361,212			4,259,993

Non-controlling interest		757,104			981,800
Total Equity		4,118,316			5,241,793
Total Liabilities and Equity	$	10,361,702		$	12,275,640

See accompanying notes to consolidated financial statements

DAHUA, INC.

CONSOLIDATED STATEMENTS OF OPERATIONS AND

COMPREHENSIVE INCOME

	Year ended December 31,
	2009			2008
Revenues:
Sales revenues	$	2,545,171		$	1,268,627
Cost of goods sold		3,499,839			1,020,978
Gross profit		(954,668	)		247,649
Expenses:
Advertising		-			70,950
Bad-debts		797			7,196
Depreciation		107,262			109,710
Payroll expense		140,801			90,392
Other general and administrative		305,789			441,744

Total expenses		554,649			719,992
Income (loss) from operations		(1,509,317	)		(472,343	)

Other income (expense)
Other income		-			1,651
Interest income		5,438			58,907
Total other income (expense)		5,438			60,558

Income before income taxes		(1,503,879	)		(411,785	)

Income tax expense (benefit)		(375,970	)		(102,759	)

Net income (loss)		(1,127,909	)		(309,026	)
Less: Net income (loss) attributable to the non-controlling interest		(225,582	)		(61,655	)
Net income (loss) attributable to Dahua Inc.	$	(902,327	)	$	(247,371	)

Earnings per share - basic and diluted:
Net income (loss) attributable to Dahua Inc. common stockholders	$	(0.04	)	$	(0.01	)

Weighted -average shares outstanding, basic and diluted		25,015,000			25,014,959

Dahua Inc. Comprehensive Income (loss)
Net income (loss)	$	(1,127,909	)	$	(309,026	)

Other comprehensive income (loss), net of tax
Foreign currency translation adjustment		4,432			352,517
Comprehensive income (loss)	$	(1,123,477	)	$	43,491

Comprehensive loss (income) attributable to the non-controlling interest		224,696			(9,024	)
Comprehensive income (loss) attributable to Dahua Inc.	$	(898,781	)	$	34,244

See accompanying notes to consolidated financial statements

DAHUA, INC.

CONSOLIDATED STATEMENTS OF CASH FLOWS

	Year ended December 31,
	2009			2008
Cash Flows from Operating Activities:
Net loss	$	(1,127,909	)	$	(309,026	)
Adjustments to reconcile net income to net cash
Provided by operating activities:
Depreciation		107,262			109,710
Stock issued for services		-			750
Provision for bad-debts		-			7,196
Changes in operating assets and liabilities:
Inventory		1,945,709			(794,854	)
Deferred taxes - current		(375,970	)		(102,759	)
Prepaid tax		133,466			(458,253	)
Prepaid expenses		(17,880	)		145,866
Accounts payable		114,608			83,593
Customer deposits		(1,759,647	)		96,422
Accrued interest		39,091			27,763
Restricted cash		(2,393	)		(4,537	)
Other accruals		(25,806	)		30,055

Net cash used in operating activities:		(969,469	)		(1,168,074	)

Cash Flows from Investing Activities:
Property, plant & equipment		(138,850	)		(16,982	)
Construction in progress		-			(1,287,974	)
Other receivables receipts		161,568			149,391
Due from related parties		659			(648	)

Net cash provided by (used in) investing activities:		23,377			(1,156,213	)

Cash Flows from Financing Activities:
Net proceeds from loans payable - related parties		834,840			507,676
Net proceeds from other receivable					-

Net cash provided financing activities:		834,840			507,676

Effect of rate chages on cash		118			99,920

Increase (decrease) in cash and cash equivalents		(111,134	)		(1,716,691	)

Cash and cash equivalents, beginning of period		176,935			1,893,626

Cash and cash equivalents, end of period	$	65,801		$	176,935

Supplemental disclosure of cash flow information:
Interest paid in cash	$	-		$	-
Sales tax paid in cash	$	4,634		$	359,613
Income taxes paid in cash	$	14,645		$	183,671
Non-cash activities
Stock issued for services		-			750

See accompany notes to consolidated financial statements

DAHUA

CONSOLIDATED STATEMENTS OF CHANGES IN EQUITY

	Common Share		Common Stock		Additional Paid in Capital		Retained Earnings			Accumulated other comprehensive Income		Non-controlling Interest 20%			Total Equity
Balance January 1, 2008		25,000,000	$	2,500	$	3,130,452	$	588,884		$	502,940	$	972,776		$	5,197,552
Net Income (loss)								(247,371	)				(61,655	)		(309,026	)
Foreign currency translation											281,838		70,679			352,517
Stock issued for services $0.05 per share		15,000		2		748										750

Balance December 31, 2008		25,015,000	$	2,502	$	3,131,200	$	341,513		$	784,778	$	981,800		$	5,241,793

Net Income (loss)								(902,327	)				(225,582	)		(1,127,909	)
Foreign currency translation											3,546		886			4,432

Balance December 31, 2009		25,015,000	$	2,502	$	3,131,200	$	(560,814	)	$	788,324	$	757,104		$	4,118,316

See accompany notes to consolidated financial statements

DAHUA INC.

NOTES TO CONSOLIDATED FINANCIAL STATEMENTS

1. Nature of operations

Dahua, Inc. (“Dahua”) was incorporated on March 8, 2002 in the State of Delaware as Norton Industries Corp. (“Norton”). The name was changed to Dahua, Inc. on February 7, 2005 as result of a reverse acquisition in which Norton acquired all capital shares of Bauer Invest Inc. ("Bauer"). Incident to the reverse acquisition the Company paid $100,000 to the previous shareholders of Norton for shares of stock that were canceled. The acquisition was accounted for as a reverse merger, as the post acquisition owners and control persons of Dahua are substantially the same as the pre acquisition owners and control persons of Bauer and the $100,000 paid to purchase and cancel the previous shares was treated as an adjustment to paid in capital.

Bauer Invest Inc. was incorporated on December 10, 2003, under the laws of the Territory of the British Virgin Islands (“BVI”). Bauer has had no operations other than the acquisition of 80% of Beijing Dahua Real Estate Development, Ltd. (“Beijing Dahua”) on May 25, 2004. The Subsidiary is a corporation established on September 24, 2001 in the People’s Republic of China (“PRC”). The acquisition was accounted for as a reverse merger, as the post acquisition owners and control persons of Bauer are substantially the same as the pre- acquisition owners and control persons of the subsidiary.

Zhuolu Dahua Real Estate Development, Ltd. (“Zhuolu Dahua”) was established on May 21, 2008 in the People’s Republic of China (“PRC”). It is the wholly-owned subsidiary of Beijing Dahua Real Estate Development, Ltd.

These financial statements are essentially those of Beijing Dahua and Zhuolu Dahua with a recapitalization to show the effects due to the reverse mergers. The consolidated entity is hereafter referred to as ‘the Company’.

The Company engages in the development of real estate and the sale of commodity housing. The Company has completed the construction of the First Phase of Dahua Garden and all of the houses are sold or available for sale. The Company is now engaging in the development of real estate and the sale of commodity housing in Zhuolu county in Hebei province. The company has got all the permits needed and is now in the process of construction.

2. Basis of Presentation

The consolidated financial statements include the accounts of Dahua, Inc., Bauer Invest, Inc., Beijing Dahua Real Estate Development Ltd and Zhuolu Dahua Real Estate Development Ltd. All inter-company accounts and transactions have been eliminated in consolidation. The Company records minority interest, which reflects the 20% portion of the earnings of Beijing Dahua Real Estate Development, Ltd. allocable to holders of the minority interest.

The accompanying consolidated financial statements are prepared in accordance with accounting principles generally accepted in the United States of America (“US GAAP”). This basis differs from that used in the statutory accounts of the Company, which were prepared in accordance with the accounting principles and relevant financial regulations applicable to enterprises in the PRC. All necessary adjustments have been made to present the financial statements in accordance with US GAAP.

3. Summary of Significant Accounting Policies

Economic and Political Risks

The Company faces a number of risks and challenges as a result of having primary operations and markets in the PRC. Changing political climates in the PRC could have a significant effect on the Company’s business.

Cash and Cash Equivalents

For purposes of the statements of cash flows, cash and cash equivalents includes cash on hand and demand deposits held by banks. Deposits held in financial institutions in the PRC are not insured by any government entity or agency.

Trade Accounts Receivable

Trade accounts receivable are recognized and carried at original invoice amount less an allowance for any uncollectible amounts. An estimate for doubtful accounts is made when collection of the full amount becomes questionable. The Company had no trade accounts receivable at December 31, 2009.

Inventory

Inventories consist primarily of land acquisition and development costs, engineering, infrastructure, capitalized interest, and construction costs. The inventories are valued at cost based on the level of completion using the weighted-average method. The company made a provision of $27,455 for houses which will be sold below cost which is included in cost of goods sold. As of December 31, 2009 the company didn’t recognize the sales revenue of such houses, because they didn’t meet the requirement of revenue recognition. However the sales prices of such houses were predetermined. Since the cost per square meter increased in 2009, it is estimated that the revenues will be lower than the costs when the revenues are recognized.

Property, plant & equipment

Property, plant & equipment are carried at cost less accumulated depreciation, which is computed using the straight-line method over the useful lives of the assets. Upon disposal of assets, the cost and related accumulated depreciation are removed from the accounts and any gain or loss is included in income. Equipment is depreciated over their estimated useful lives as follows:

Computer equipment		3 years
Office equipment		7 years
Vehicles		7 years

Depreciation expense for the years ended December 31 2009 and 2008 was $107,262 and $109,710, respectively.

Long-term assets of the Company are reviewed annually to assess whether the carrying value has become impaired, according to the guidelines established in the Accounting Standards Codification (“ASC Topic”) 360. The Company also evaluates the periods of amortization to determine whether subsequent events and circumstances warrant revised estimates of useful lives. No impairment of long –term assets was recorded in the periods reported.

Revenue Recognition

Advertising Expenses

Advertising costs are expensed as incurred. Advertising expense amounted to $0 and $70,950 for the years ended December 31, 2009 and 2008, respectively.

Foreign Currency and Comprehensive Income

The accompanying consolidated financial statements are presented in United States (“US”) dollars. The functional currency is the Yuan Renminbi (“RMB”) of the PRC. The consolidated financial statements are translated into US dollars from RMB at period-end exchange rates for assets and liabilities, and weighted average exchange rates for revenues and expenses. Capital accounts are translated at their historical exchange rates when the capital transactions occurred.

During July 2005, China changed its foreign currency exchange policy from a fixed RMB/US dollar exchange rate into a flexible rate under the control of China’s government. We used the Closing Rate Method in translation of the financial statements.

RMB is not freely convertible into the currency of other nations. All such exchange transactions must take place through authorized institutions. There is no guarantee the RMB amounts could have been, or could be, converted into US dollars at rates used in translation.

Taxes

Deferred tax assets and liabilities are recognized for the future tax consequences attributable to differences between the financial statement carrying amounts of existing assets and liabilities and their respective tax bases. Deferred tax assets and liabilities are measured using enacted tax rates expected to apply to taxable income in the years in which those temporary differences are expected to reverse. The effect on deferred tax assets and liabilities of a change in tax rates is recognized in the statement of operations in the period that includes the enactment date. A valuation allowance is provided for deferred tax assets if it is more likely than not these items will either expire before the Company is able to realize their benefits, or that future deductibility is uncertain.

Estimates

The preparation of consolidated financial statements in conformity with generally accepted accounting principles requires management to make estimates and assumptions that affect the reported amounts of assets and liabilities and disclosures of contingent assets and liabilities at the date of the consolidated financial statements and the reported amounts of income and expenses during the reporting period. Actual results could differ from those estimates.

Earnings per Share

Basic earnings per common share ("EPS") are calculated by dividing net income by the weighted average number of common shares outstanding during the year. Diluted EPS is calculated by adjusting the weighted average outstanding shares, assuming conversion of all potentially dilutive securities, such as stock options and warrants. The numerators and denominators used in the computations of basic and diluted EPS are presented in the following table:

	2009			2008
NUMERATOR FOR BASIC AND DILUTED EPS
Net income to common stockholders	$	(902,327	)	$	(247,371	)

DENOMINATORS FOR BASIC AND DILUTED EPS
Weighted average shares of common stock outstanding		25,015,000			25,014,959
Add: dilutive equity securities outstanding		-			-
Denominator for diluted EPS		25,015,000			25,014,959

EPS – Basic	$	(0.04	)	$	(0.01	)

EPS – Diluted	$	(0.04	)	$	(0.01	)

The Company had no potentially dilutive securities outstanding at December 31, 2009 and 2008.

4．Inventory

Inventories consist primarily of compulsory land acquisition and removal compensation costs, prophase engineering cost, infrastructure cost, capitalized interest, indirect development costs, auxiliary public establishment costs and construction and installation project costs, etc in Zhuolu Dahua and Dahua Phase II. It also represents completed houses available for sale at December 31, 2009 in Beijing Dahua. During 2005, the Company completed its housing construction of the First Phase of Dahua Garden. As of December 31, 2009, 67 units were sold, 8 units were reserved with clients’ deposits.

As of December 31, 2009, inventory in Beijing Dahua and project in Zhuolu was as follows:

	Inventory in Beijing Dahua		Inventory in Zhuolu Dahua		Inventory in Beijing Dahua
	Phase I				Phase II
December 31, 2009	$	3,615,644	$	2,186,142	$	1,092,584
		3,615,644		2,186,142		1,092,584

5. Property, plant and equipment

Property, plant & equipment are carried at cost less accumulated depreciation, which is computed using the straight-line method over the useful lives of the assets.

Land and buildings represent the cost carried forward from construction in progress as the company has completed the construction of the clubhouse on December 31, 2009. Half cost was carried forward to Land and Buildings and the other half was carried to the inventory and cost of goods sold for the reason that two stories of which was used as clubhouse to the home owner association. As of December 31, 2009, the balance of Land and Buildings was $1,213,063.

6. Related Party Transactions

Short-term loans due to related parties had balances of $1,912,796 and $1,037,522 (including accrued interest) at December 31, 2009 and 2008 respectively. The loans carry an annual interest rate of 6 percent and are due on demand. Interest accrued on the loans was $229,373 and $190,087 for the years ended December 31, 2009 and 2008 respectively.

7．Customer deposits

Customer deposits consist of down payments received on sales contracts for houses. When all of the conditions set forth in the Company’s revenue recognition policy are met, the Company will recognize the down payments as revenue. The aggregate of the customers’ deposits was $3,681,057 and $5,436,356 at December 31, 2009 and 2008 respectively. Of the 8 units reserved, one unit’s deposits are money received from bank arrangements (see note 8) in the amounts of $515,509. Accordingly, the bank has liens against this unit.

8. Off-Balance Sheet Arrangements

The Company entered into an agreement with two banks that extended mortgage loans to its home buyers, where the Company agrees to provide a certain limited guarantee, which covers the risk before the conveyance of title upon closing. Upon initiating the loan on behalf of the buyer for the down payment, the Bank has withheld a percentage ranging from 5% to 20% of the loan and deposited such funds into a segregated account in each bank. At December 31, 2009 and 2008, the balance of this separate account was $734,317 and $731,238 respectively. Since the Company does not recognize revenue when its receivables are subject to future subordination, the entire amount that could become payable to the bank under the limited guarantee is recorded as a liability on the balance sheet and is included in customer deposits, as is explained in note 7.

9. Tax

The Company made a provision for sales tax, which totaled $152,775 and $75,725 respectively for the year ended December 31, 2009 and 2008. The sales tax is calculated on the basis of sales revenues. The provision for sales tax is included as part of cost of goods sold.

Income tax expense (benefit) consists of the following:

	Year Ended December 31,
Current:	2009			2008
Foreign	$	-		$	-
		-			-
Deferred:
Foreign		(375,970	)		(102,759	)
		(375,970	)		(102,759	)
Income tax expense (benefit)	$	(375,970	)	$	(102,759	)

A reconciliation of income tax expense (benefit) to the amount computed using statutory rates is as follow

	Year Ended December 31,
	2009			2008
Tax at statutory rate	$	(375,970	)	$	(102,759	)
Non-deductibe expenses		-			-
	$	(375,970	)	$	(102,759	)

The Company has implemented ASC Topic 740, which provides for a liability approach to accounting for income taxes. Total deferred tax assets and liabilities as of December 31, 2009 are as follows:

	Year Ended December 31,
	2009		2008
Deferred tax assets - Tax NOL	$	480,700	$	104,473
Deferred tax liabilities		-		-
Net deferred tax asset (liability) - current	$	480,700	$	104,473

Deferred income taxes result from the effect of transactions that are recognized in different periods for financial and tax reporting purposes.

Deferred income taxes are recognized for the tax consequences of temporary differences by applying statutory tax rates to differences between the financial reporting and the tax bases of existing assets and liabilities. These temporary differences related primarily to bad debt provisions and losses on the sale of property.

The company has a net operating loss caryforward of approximately $1,922,800 expiring in 2029. The tax benefit of these net operating loss carryforwards, based on an effective tax rate of 25% is approximately $480,700.

The Company paid sales tax in cash, which totaled $4,634 for the year ended December 31, 2009. The company paid sales tax and income tax in cash, which totaled $359,613 and $183,671 respectively, for the year ended December 31, 2008.

10. Stock

The Company is authorized to issue up to 80,000,000 shares of common stock, $.0001 par value, and 20,000,000 shares of preferred stock, $.0001 par value per share. For the help that Pacific Services provided in the company’s Form 211 reporting in the United States, the company issued 15,000 shares of the Company’s Common Stock, $0.0001 par value per share to Pacific Services Inc on January 2, 2008. The fair value of this share paid for services is $0.05. As of December 31, 2009, there were 25,015,000 shares of common stock issued and outstanding, and no shares of preferred stock were issued and outstanding.

11. Contingencies

The Company has not, historically, carried any property or casualty insurance. No amounts have been accrued for any liability that could arise from the lack of insurance. Management feels the chances of such an obligation arising are remote.

Deposits in banks in the PRC are not insured by any government entity or agency, and are consequently exposed to risk of loss. Management believes the probability of a bank failure, causing loss to the Company, is remote.

12. Others receivable

Others receivable primarily represent loans due from outside parties. As of December 31, 2009, the balance of others receivable was $7,327. The company made a provision of 7,323 for bad-debts for other receivable for the reason that collection of the full amount becoming questionable.

13. Leases

The Company leased in 1997 a pond and filled it and leveled up for land exploitation from an outside party for approximately $ 32,500.00 per year which will end in 2047. This lease is for an initial term of 50 years and requires fixed annual payments. In the year ended December 31, 2009 the Company paid approximately $38,061 for the lease payment. These leases contain renewal and right of first refusal options and require the adherence to certain covenants and conditions. Rental expense is recognized on the straight-line basis, although rental payments vary over the lease terms. Future minimum lease payments are as follows:

Year ending December 31,

2010	$	32,500
2011	$	32,500
2012	$	32,500
2013	$	32,500
2014	$	32,500
Thereafter	$	1,072,500
	$	1,235,000

14. Recent Accounting Pronouncements

Effective April 1, 2009, the Company adopted FASB ASC 820-10-65, Fair Value Measurements and Disclosures – Overall – Transition and Open Effective Date Information (“ASC 820-10-65”). ASC 820-10-65 provides additional guidance for estimating fair value in accordance with ASC 820-10 when the volume and level of activity for an asset or liability have significantly decreased. ASC 820-10-65 also includes guidance on identifying circumstances that indicate a transaction is not orderly. The adoption of ASC 820-10-65 did not have an impact on the Company’s consolidated results of operations or financial condition.

Effective April 1, 2009, the Company adopted FASB ASC 825-10-65, Financial Instruments – Overall – Transition and Open Effective Date Information (“ASC 825-10-65”). ASC 825-10-65 amends ASC 825-10 to require disclosures about fair value of financial instruments in interim financial statements as well as in annual financial statements and also amends ASC 270-10 to require those disclosures in all interim financial statements. The adoption of ASC 825-10-65 did not have a material impact on the Company’s consolidated results of operations or financial condition.

In October 2009, the FASB issued ASU 2009-13, Multiple-Deliverable Revenue Arrangements, (amendments to FASB ASC Topic 605, Revenue Recognition) (“ASU 2009-13”) and ASU 2009-14, Certain Arrangements That Include Software Elements, (amendments to FASB ASC Topic 985, Software) (“ASU 2009-14”). ASU 2009-13 requires entities to allocate revenue in an arrangement using estimated selling prices of the delivered goods and services based on a selling price hierarchy. The amendments eliminate the residual method of revenue allocation and require revenue to be allocated using the relative selling price method. ASU 2009-14 removes tangible products from the scope of software revenue guidance and provides guidance on determining whether software deliverables in an arrangement that includes a tangible product are covered by the scope of the software revenue guidance. ASU 2009-13 and ASU 2009-14 should be applied on a prospective basis for revenue arrangements entered into or materially modified in fiscal years beginning on or after June 15, 2010, with early adoption permitted. The Company does not expect adoption of ASU 2009-13 or ASU 2009-14 to have a material impact on the Company’s consolidated results of operations or financial condition.

In January 2010, the FASB issued Accounting Standards Update 2010-02, Consolidation (Topic 810): Accounting and Reporting for Decreases in Ownership of a Subsidiary. This amendment to Topic 810clarifies, but does not change, the scope of current US GAAP. It clarifies the decrease in ownership provisions of Subtopic 810-10 and removes the potential conflict between guidance in that Subtopic and asset derecognition and gain or loss recognition guidance that may exist in other US GAAP. An entity will be required to follow the amended guidance beginning in the period that it first adopts FAS 160 (now included in Subtopic 810-10). For those entities that have already adopted FAS 160, the amendments are effective at the beginning of the first interim or annual reporting period ending on or after December 15, 2009. The amendments should be applied retrospectively to the first period that an entity adopted FAS 160. Adoption of ASU 2010-02 did not have a material impact on the Company’s consolidated results of operations or financial condition.

In January 2010, the FASB issued Accounting Standards Update 2010-01, Equity (Topic 505): Accounting for Distributions to Shareholders with Components of Stock and Cash (A Consensus of the FASB Emerging Issues Task Force). This amendment to Topic 505 clarifies the stock portion of a distribution to shareholders that allows them to elect to receive cash or stock with a limit on the amount of cash that will be distributed is not a stock dividend for purposes of applying Topics 505 and 260. Effective for interim and annual periods ending on or after December 15, 2009, and would be applied on a retrospective basis. Adoption of ASU 2010-01 did not have a material impact on the Company’s consolidated results of operations or financial condition.

15. Subsequent Events

The Company has evaluated all subsequent events through the date these financial statements were issued.

Item 8. Changes In and Disagreements with Accountants on Accounting and Financial Disclosure

There are no changes in and disagreements with accountants on accounting and financial disclosure.

Item 9A (T). Controls and Procedures

(a) Evaluation of disclosure controls and procedures.

In connection with the preparation of this annual report, an evaluation was carried out by the Registrant’s management, with the participation of the principal executive officer and the principal financial officer, of the effectiveness of the Registrant’s disclosure controls and procedures (as defined in Rules 13a-15(e) and 15d-15(e) under the Securities Exchange Act of 1934 (“Exchange Act”)) as of December 31, 2009. Disclosure controls and procedures are designed to ensure that information required to be disclosed in reports filed or submitted under the Exchange Act is recorded, processed, summarized, and reported within the time periods specified in the Commission’s rules and forms, and that such information is accumulated and communicated to management, including the chief executive officer and the chief financial officer, to allow timely decisions regarding required disclosures.

The Company’s management, with the participation of its chief executive officer and chief financial officer, evaluated the effectiveness of its disclosure controls and procedures. The term “disclosure controls and procedures,” as defined in Rules 13a-15(e) and 15d-15(e) under the Exchange Act, means controls and other procedures of a company that are designed to ensure that information required to be disclosed by a company in the reports, that it files or submits under the Exchange Act is recorded, processed, summarized and reported, within the time periods specified in the SEC’s rules and forms. Disclosure controls and procedures include, without limitation, controls and procedures designed to ensure that information required to be disclosed by a company in the reports that it files or submits under the Exchange Act is accumulated and communicated to the company’s management, including its principal executive and principal financial officers, as appropriate to allow timely decisions regarding required disclosure. Based on that evaluation, Company’s management concluded that because of the existence of certain related party loans in violation of Section 402 of the Sarbanes-Oxley Act of 2002 contributed to in part by a lack of review and approval of these related party loans by independent directors constituting a significant deficiency in internal control over financial reporting, the Company’s disclosure controls and procedures were not effective as of December 31, 2009. As of December 31, 2009, the Company advanced money to two related parties with a total outstanding amount in excess of $48,522.

(b) Management’s Report on Internal Control over Financial Reporting

The management of the Registrant is responsible for establishing and maintaining adequate internal control over financial reporting. The Registrant’s internal control over financial reporting is a process, under the supervision of the principal executive officer and the principal financial officer, designed to provide reasonable assurance regarding the reliability of financial reporting and the preparation of the Registrant’s financial statements for external purposes in accordance with United States generally accepted accounting principles (GAAP). Internal control over financial reporting includes those policies and procedures that:

●

Pertain to the maintenance of records that in reasonable detail accurately and fairly reflect the transactions and dispositions of the Registrant’s assets;

●

Provide reasonable assurance that transactions are recorded as necessary to permit preparation of the financial statements in accordance with generally accepted accounting principles, and that receipts and expenditures are being made only in accordance with authorizations of management and the board of directors; and

●

Provide reasonable assurance regarding prevention or timely detection of unauthorized acquisition, use, or disposition of the Registrant’s assets that could have a material effect on the financial statements.

Because of its inherent limitations, internal control over financial reporting may not prevent or detect misstatements. Also, projections of any evaluation of effectiveness to future periods are subject to the risk that controls may become inadequate because of changes in conditions or that the degree of compliance with the policies or procedures may deteriorate.

The Registrant’s management conducted an assessment of the effectiveness of our internal control over financial reporting as of December 31, 2009, based on criteria established in Internal Control – Integrated Framework issued by the Committee of Sponsoring Organizations of the Tread way Commission. Our management has concluded that our internal control over financial reporting is effective based on these criteria.

During the fourth quarter ended on December 31, 2009, there has been no change in internal control over financial reporting that has materially affected, or is reasonably likely to materially affect our internal control over financial reporting.

(d) Attestation Report of the Registered Public Accounting Firm

This annual report does not include an attestation report of our independent registered public accounting firm regarding internal control over financial reporting. We were not required to have, nor have we, engaged our independent registered public accounting firm to perform an audit of internal control over financial reporting pursuant to the rules of the Commission that permit us to provide only management’s report in this annual report..

Item 9B. Other Information

There were no events requiring disclosure that had not been made under Form 8K in the fourth quarter of our fiscal year.

PART III

Item 10. Directors, Executive Officers, Promoters and Control Persons; Compliance with Section 16(a) of the Exchange Act

Directors and Executive Officers

Each of our directors is elected by the shareholders to a term of one year and serves until his or her successor is elected and qualified, or until he or she resigns or is removed from office. Each of our officers is elected by the board of directors to a term of one year and serves until his or her successor is duly elected and qualified, or until he or she resigns or is removed from office. The board of directors has no nominating or compensation committees. The board of directors does not have an audit committee financial expert.

The name, age and position of our officers and directors are set forth below:

Name	Age		Position Held
Du Yonglin		68	President, Chief Executive Officer and Director
Wang Wulong		70	Director
Meng Hua		34	Chief Financial Officer
Zeng Qinna		32	Corporate Secretary

The following is a brief description of business experience of each of our directors and executive officers during the past five years.

Mr. Yonglin Du has been our Chairman, Chief Executive Officer and President since January 30, 2005. From 1982 to 2003, Mr. Du held various positions in China's petroleum and petrochemical industries, including Deputy Director of the Research Institute of Daqing Oilfield, Head of Petroleum and Petrochemical Division of the State Planning Commission, Deputy Director of the Energy Institute of the State Planning Commission, President of Shanghai Petroleum and Natural Gas Company. In 2000, he founded Dahua Project Management Group Co. Ltd. ("Dahua Group"), of which he has been serving as its Chairman of the Board of Directors and Chief Executive Officer. Dahua Group is a Beijing Municipal Government licensed construction project supervising business entity located in Beijing, China.

Mr. Wulong Wang has been our Director since January 30, 2005. A graduate of Beijing Post and Telecommunication University, Mr. Wang is a senior engineer and China's registered Consulting Engineer. He joined China's State Planning Commission in 1979, and served as its Deputy Chief of Investment Bureau from 1988 to 1992, Chief of Key Construction Bureau from 1992 to 1994, Chief of Investment Bureau from 1994 to 1995. From 1995 to 2002, Mr. Wang served as the President of China International Engineering Consulting Co. Limited, and from 2002 to the present as a member of the Expert Committee of China Engineering Consulting Co. Limited, as well as a member of the Economic Commission of Chinese National People's Political Consultative Conference.

Ms. Hua Meng has been our Chief Financial Officer since January 30, 2005. She graduated from the Central University of Finance and Economics of China in July 2003 with a master degree in accounting. Ms. Meng is a Certified Public Accountant in China. From July 1999 to May 2000, she was employed at Beijing Baisheng Light Industry Development Co. Ltd. as an accountant. From July 2003 to the present, Ms. Meng has also been chief financial officer of Dahua Project Management Group Co., Ltd., a Beijing Municipal Government licensed construction project supervising business entity in Beijing, China.

Ms. Qinna Zeng has been our Corporate Secretary since January 30, 2005. She graduated from the Central University of Finance and Economics in China in July 2003 with a master degree in finance. From July 1999 to August 2000, Ms. Zeng worked for the Lichuan Branch of People's Bank of China as a statistician. From July 2003 to the present, Ms. Zeng has also been corporate secretary of Dahua Project Management Group Co. Ltd., a Beijing Municipal Government licensed construction project supervising business entity in Beijing, China.

None of our directors and officers has ever held any position in a reporting company.

Significant Employees

There are no significant employees other than our executive officers.

Family Relationships

There are no family relationships among directors or officers.

Involvement in Certain Legal Proceedings

During the past five years, none of our officers, directors, promoters or control persons has had any involvement in any of the following events:

Any bankruptcy petition filed by or against any business of which such person was a general partner or executive officer either at the time of the bankruptcy or within two years prior to that time;

Any conviction in a criminal proceeding or being subject to a pending criminal proceeding, excluding traffic violations and other minor offenses;

Being subject to any order, judgment or decree, not substantially reversed, suspended or vacated, of any court of competent jurisdiction, permanently enjoining, barring, suspending or otherwise limiting his involvement in any type of business, securities or banking business; and/or

Being found by a court of competent jurisdiction, in a civil action, the Securities and Exchange Commission or the Commodity Futures Trading Commission to have violated a federal or state securities or commodities law, and the judgment has not been reversed, suspended or vacated.

Code of Ethics

We had adopted a code of ethics that applies to its principal executive officer, principal financial officer, principal accounting officer or controller, or persons performing similar functions. A copy of the code of ethics may be obtained by any person, without charge, who sends a written request to Dahua Inc. c/o Corporate Secretary, 8th Floor, Officer Tower 3, Henderson Center, 18# Jianguomennei Street Dongcheng District, Beijing, China 100005

Section 16(a) Beneficial Ownership Reporting Compliance

Section 16(a) of the Securities Exchange Act of 1934, as amended, requires our officers and directors, and persons who own more than 10% of a registered class of our equity securities, to file reports of ownership and changes in ownership of our equity securities with the Securities and Exchange Commission. Officers, directors and greater than 10% shareholders are required by the Securities and Exchange Commission regulations to furnish us with copies of all Section 16(a) filings. To our knowledge, for the year ended December 31, 2009, based solely on a review of the copies of such reports furnished to us and representations by these individuals that no other reports were required during the year ended December 31, 2009, all Section 16(a) filing requirements applicable to our directors, officers and greater than 10% beneficial owners have been timely filed.

Item 11. Executive Compensation

Summary Compensation Table

SUMMARY COMPENSATION TABLE

Name and Principal Position	Year	Salary ($)		Bonus ($)		Stock Awards ($)		Option Awards ($)		Non- Equity Incentive Plan Compensation ($)		Nonquali- fied Deferred Compensation Earnings ($)		All Other Compensation ($)		Total ($)
Yonglin Du	2009	29,290		-		-		-			-		-		-		29,290
CEO and	2008		29,262		-		-		-		-		-		-		29,262
President

Hua Meng	2009		8,787		-		-		-		-		-		-		8,787
CFO	2008		8,779		-		-		-		-		-		-		8,779

(i)	The annual salaries paid Mr. Du were 200,000 yuan, or approximately $29,290, and Ms. Meng 60,000 yuan, or approximately $8,787, respectively.

At the end of the last completed fiscal year, there were no “most highly compensated executive officers” as that term is defined in Item 402(m) (2) of Regulation S-K, and there were no additional individuals for whom disclosure would have been made in this table but for the fact that the individual was not serving as our executive officer.

Outstanding Equity Awards at Fiscal Year-End Table

We do not have any equity incentive plans. No option or stock awards have been granted to any of our executive officers or directors since our inception. Pursuant to Item 402(m)(5) of Regulation S-K, the Outstanding Equity Awards at Fiscal Year-End Table is omitted because there has been no compensation awarded to, earned by, or paid to any of the named executive officers or directors required to be reported in that table.

Compensation of Directors

The members of the Board of Directors are not compensated by us for their service as members of the Board of Directors, but may be reimbursed for reasonable expenses incurred in connection with attendance of meetings of the board of directors. There are no arrangements pursuant to which directors are or will be compensated in the future for any services provided as a director.

Employment Contracts, Termination of Employment, Change-in-Control Arrangements

We have not entered employment agreements with our executive officers. There are no compensatory plans or arrangements, including payments to be received from us, with respect to a named executive officer, if such plan or arrangement would result from the resignation, retirement or any other termination of such executive officer's employment with us or form a change-in-control of us or a change in the named executive officer's responsibilities following a change-in-control.

Item 12. Security Ownership of Certain Beneficial Owners and Management and Related Stockholder Matters

Security Ownership of Certain Beneficial Owners

The following table sets forth certain information regarding the beneficial ownership of our common stock as of March 28, 2010, each person who is known by us to own beneficially more than 5% of our outstanding common stock. We have only one class of securities outstanding. Except as otherwise indicated, we believe that the beneficial owners of the common stock listed below, based on information furnished by such owners, have sole investment and voting power with respect to such shares, subject to community property laws where applicable.

Title of Class		Name and Address of Beneficial Owner		Amount & Nature of Beneficial Owner		Percent of Class
Common Stock		Yonglin Du 8th Floor, Officer Tower 3, Henderson Center, 18# Jianguomennei Street Dongcheng District, Beijing, China 100005		1,900,000 shares			7.60	%

Security Ownership of Management

The following table sets forth certain information, as of March 31, 2010, as to each class of our equity securities beneficially owned by all of our directors and nominees, each of the named executive officers, and our directors and executive officers as a group.

Title of Class	Name and Address of Beneficial Owner(1)	Amount & Nature of Beneficial Owner	Percent of Class
Common Stock	Yonglin Du(2) 8th Floor, Officer Tower 3, Henderson Center, 18# Jianguomennei Street Dongcheng District, Beijing, China 100005	1,900,000 shares		7.60	%

Common Stock	Qinna Zeng (3) #1712, Courtyard 5, Beiyuan Road, Chaoyang District, Beijing	72,500 shares		*	(4)

Common Stock	Hua Meng (5) # 8104, Courtyard 11, Anning Zhuang, Xisanqi, Haidian District, Beijing	15,000 shares		*

Common Stock	Wang Wulong c/o Dahua Inc. 8th Floor, Officer Tower 3, Henderson Center, 18# Jianguomennei Street Dongcheng District, Beijing, China 100005	Nil	Nil

	All officers and directors as a group	1,987,500 shares		7.95	%

(1)	The persons named above do not have any specified rights to acquire, within 60 days of the date of this registration statement any options, warrants or rights and no conversion privileges or other similar obligations exist.

(2)	Yonglin Du is our CEO, President and a director.

(3)	Qinna Zeng is our Corporate Secretary.

(4)	Less than one percent of the total number of shares outstanding.

(5)	Hua Meng is our Chief Financial Officer.

We do not have any securities that are convertible into common stock.

Changes in Control

There are no arrangements that the management is aware of that may result in changes in control as that term is defined by the provisions of Item 403(c) of Regulation S-K. There are no provisions within our Articles or Bylaws that would delay or prevent a change of control.

Item 13 Certain Relationships and Related Transactions

(a) Transactions with Related Persons

None.

(b) Parents

None.

(c)Promoters and Control Persons

Prior to the reverse merger on January 30, 2005, Comp Hotel International Ltd. ("Comp Hotel") and Waywood Investment Ltd. ("Waywood") collectively owned 100% of capital stock of our predecessor, Norton Industries Corp. On January 30, 2005, Comp Hotel and Waywood entered into a share exchange agreement with Bauer Invest Inc., a British Virgin Islands corporation ("Bauer"), pursuant to which Comp Hotel and Waywood sold all outstanding capital shares, or 5,000,000 shares of common stock of Norton, to Bauer in exchange for $100,000 in cash and 5% of the post-acquisition shares. As a result, Waywood and Comp Hotel received 150,000 and 850,000 shares, respectively, of our common stock. The numbers of shares they received were proportionate to the respective numbers of shares they originally owned in Norton Industries Corp.

Waywood Investment Ltd. ("Waywood") is the sole promoter of our predecessor, Norton Industries Corp ("Norton"). Waywood is a small business consulting firm incorporated in the British Virgin Islands. Jianjun Zhang is the sole shareholder of Waywood. From inception of Norton until the reverse merger of Norton on January 30, 2005, Mr. Zhang was the sole director and executive officer of Norton. On February 26, 2003, Waywood entered into a stock purchase agreement with Comp Hotel International Ltd., a British Virgin Islands corporation ("Comp Hotel"), pursuant to which Comp Hotel acquired 4,250,000 shares, or 85%, of Norton's common stock from Waywood in exchange for $42,500 in cash. Comp Hotel is a travel-related service provider operating in Hong Kong, and is controlled by South Sea Petroleum Holdings Limited, a Hong Kong corporation, whose principal business is the exploration and production of crude oil in Indonesia. Immediately prior to the date of reverse merger between Bauer Invest and Norton Industries Corp., Comp Hotel, owned 85%, and Waywood owned 15%, of Norton's issued and outstanding shares, respectively.

In connection with issuance of additional common shares as a result of capital increase in our subsidiary, pursuant to a no-dilution clause of the Share Exchange Agreement dated January 30, 2005, on September 21, 2005, we issued 212,500 and 37,500 shares of our common stock to Comp Hotel and Waywood, respectively.

Related Party Loans

Set forth below is a chart of all related party loans (lines of credit) extended to us as of December 31, 2009:

Party	Current Loan Balance		Date
Dahua Project Management Group	$	758,238	October 2001
Donghui Du		7,772	December 2001
Dahua Weiye Investment Co.		764,283	February 2009
Dahua Farming		153,130	October 2001
Total	$	1,683,423

All the related parties set forth above are parties in which Mr. Yonglin Du, our president and CEO, holds an executive position. Donghui Du is Mr. Yongling Du’s son.

We entered a written loan agreement with Dahua Project Management Group. Please see Exhibit 10. 6. All other loans or lines of credit are extended based on verbal agreements. All the loans so borrowed are unsecured. The money we borrow from them bear’s interest at an annual rate of 6%, then prevailing market rate, repayable within 30 days upon demand by lender.

Item 14. Exhibits

(a) The following exhibits are filed as part of this report.

Exhibit Number		Description
2.1		Share Exchange Agreement dated January 30, 2005 between Norton Industries Corp. and Bauer Invest, Inc. (Incorporated by reference to Current Report on Form 8-K filed on February 1, 2005, Commission File No. 0-49852).

2.2		Share Exchange Agreement dated January 26, 2003 between Norton Industries Corp. and Comp Hotel International Ltd. (Incorporated by reference to Registration Statement on Form SB-2/A filed on November 14, 2005, Commission File No. 333-122622).

2.3		Share Transfer Agreement dated May 25, 2004 between Bauer Invest, Inc. and Dahua Project Management Group Co., Ltd. (Incorporated by reference to Registration Statement on Form SB-2/A filed on November 14, 2005, Commission File 333-122622).

3.1		Articles of Incorporation (Incorporated by reference to Registration Statement on Form 10- SB filed on June 10, 2002, Commission File No. 0-49852).

3.2		Certificate of Amendment of Articles of Incorporation (Incorporated by reference to Registration Statement on Form SB-2 filed on February 8, 2005, Commission File No. 333- 122622).

3.3		Bylaws (Incorporated by reference to Registration Statement on Form 10-SB filed on June 10, 2002 Commission File No. 0-49852).

4.1		Specimen Stock Certificate (Incorporated by reference to Registration Statement on Form 10-SB/A filed on July 29, 2002, Commission File No. 0-49852).

10.1		Land Use Rights Transfer Agreement (Incorporated by reference to Registration Statement on Form SB-2/A filed on November 14, 2005, Commission File No. 333-122622)

10.2		Agreement dated September 24, 2003, between Beijing Dahua Real Estate and Aocheng Construction Management Ltd. (Incorporated by reference to Registration Statement on Form SB-2/A filed on November 14, 2005, Commission File No. 333-122622)

10.3		National Land Use Permit issued on October 20, 2003 (Incorporated by reference to Registration Statement on Form SB-2/A filed on November 14, 2005, Commission File No. 333-122622)

10.4		Development Planning Permit issued on September 4, 2003 (Incorporated by reference to Registration Statement on Form SB-2/A filed on November 14, 2005, Commission File No. 333-122622)

10.5		Development Construction Permit issued on September 28, 2003 (Incorporated by reference to Registration Statement on Form SB-2/A filed on November 14, 2005, Commission File No. 333-122622).

10.6		Line of Credit Agreement between Beijing Dahua Real Estate and Dahua Project Management Group (Incorporated by reference to Registration Statement on Form SB-2/A filed on November 14, 2005, Commission File No. 333-122622).

10.7		Agreement between Beijing Dahua Real Estate Development Ltd. and Beijing Dahua Gonghong Economic Research Center dated June 18, 2003 (Incorporated by reference to Registration Statement on Form SB-2/A filed on March 8, 2006, Commission File No. 333- 122622).

10.8		Agreement between Beijing Dahua Real Estate Development Ltd. and Beijing Dahua Gonghong Economic Research Center dated June 2004 (Incorporated by reference to Registration Statement on Form SB-2/A filed on March 8, 2006, Commission File No. 333- 122622).

14.1		Code of Business Conduct and Ethics (Incorporated by reference to Registration Statement on Form SB-2 filed on February 8, 2005, Commission File No. 333-122622).

21		Subsidiaries of the Registrant (Incorporated by reference to Registration Statement on Form SB-2/A filed on November 14, 2005, Commission File No. 333-122622).

31.1		Section 302 Certification by CEO.

31.2		Section 302 Certification by CFO.

32.1		Section 906 Certification by CEO

32.2		Section 906 Certification by CFO.

Item 15 Principal Accountant Fees and Services

The following is a summary of the fees billed to us by our principal accountants during the fiscal years ended December 31, 2009 and 2008:

Fee category	2009		2008
Audit fees	$	42,000	$	42,000
Audit-related fees		-		-
Tax fees		-		3,850
All other fees		-		-
Total fees	$	42,000	$	45,850

Audit Fees consists of fees for professional services rendered by our principal accountants for the audit of our annual financial statements or services that are normally provided by our principal accountants in connection with statutory and regulatory filings or engagements.

As of December 31, 2009, we did not have an audit committee. Our Board of Directors reviewed and pre-approved all audit and non-audit services provided by Child, Van Wagoner & Bradshaw, PLLC and has determined that the firm's provision of such services to us during fiscal 2009 is compatible with and did not impair the independence of Child, Van Wagoner & Bradshaw, PLLC. It is the practice of our Board of Directors to consider and approve in advance all auditing and non-auditing services provided to us by our independent auditors in accordance with the applicable requirements of the Securities and Exchange Commission.

SIGNATURES

In accordance with Section 13 or 15(d) of the Exchange Act, the registrant has duly caused this report to be signed on its behalf by the undersigned, thereunto duly authorized.

DAHUA, INC.

Date: March 31, 2010

By:	/s/
Yonglin Du, President and
Chief Executive Officer
(Principal Executive Officer)

In accordance with the Exchange Act, this report has been signed below by the following persons on behalf of the registrant and in the capacities and on the dates indicated:

/s/		March 31, 2010
Yonglin Du, President, Chief Executive Officer and Director		Date
(Principal Executive Officer)


/s/		March 31, 2010
Hua Meng, Chief Financial Officer		Date
(Principal Financial Officer and Principal Accounting Officer)


/s/		March 31, 2010
Wulong Wang, Director		Date

Attached files

DAHUA INC Reports

Also read