UNITED STATES

SECURITIES AND EXCHANGE COMMISSION

Washington, D.C. 20549

Form 10-K

Commission file number: 1‑13011

Comfort Systems USA, Inc.

(Exact name of registrant as specified in its charter)

675 Bering Drive

Suite 400

Houston, Texas 77057

(713) 830‑9600

(Address and telephone number of Principal Executive Offices)

Securities registered pursuant to Section 12(b) of the Act:

Securities registered pursuant to Section 12(g) of the Act: None

Indicate by check mark if the registrant is a well‑known seasoned issuer, as defined in Rule 405 of the Securities Act. Yes ☒  No ☐

Indicate by check mark if the registrant is not required to file reports pursuant to Section 13 or 15(d) of the Act. Yes ☐  No ☒

Indicate by check mark whether the registrant (1) has filed all reports required to be filed by Section 13 or 15(d) of the Securities Exchange Act of 1934 during the preceding 12 months (or for such shorter period that the registrant was required to file such reports), and (2) has been subject to such filing requirements for the past 90 days. Yes ☒  No ☐

Indicate by check mark whether the registrant has submitted electronically and posted on its corporate Website, if any, every Interactive Data File required to be submitted and posted pursuant to Rule 405 of Regulation S‑T (§ 232.405 of this chapter) during the preceding 12 months (or for such shorter period that the registrant was required to submit and post such files). Yes ☒  No ☐

Indicate by check mark if disclosure of delinquent filers pursuant to Item 405 of Regulation SK is not contained herein, and will not be contained, to the best of the registrant’s knowledge, in definitive proxy or information statements incorporated by reference in Part III of this Form 10‑K or any amendment to this Form 10‑K. ☐

Indicate by check mark whether the registrant is a large accelerated filer, an accelerated filer, a non-accelerated filer, a smaller reporting company, or an emerging growth company. See the definitions of “large accelerated filer,” “accelerated filer,” “smaller reporting company,” and “emerging growth company” in Rule 12b-2 of the Exchange Act.

If an emerging growth company, indicate by check mark if the registrant has elected not to use the extended transition period for complying with any new or revised financial accounting standards provided pursuant to Section 13(a) of the Exchange Act. ☐

Indicate by check mark whether the registrant is a shell company (as defined in Exchange Act Rule 12b‑2). Yes ☐  No ☒

The aggregate market value of the voting stock held by non‑affiliates of the registrant at June 30, 2017 was approximately $1.35 billion, based on the $37.10 last sale price of the registrant’s common stock on the New York Stock Exchange on June 30, 2017.

As of February 15, 2018, 37,175,074 shares of the registrant’s common stock were outstanding (excluding treasury shares of 3,948,291).

DOCUMENTS INCORPORATED BY REFERENCE

The information required by Part III (other than the required information regarding executive officers) is incorporated by reference from the registrant’s definitive proxy statement, which will be filed with the Commission not later than 120 days following December 31, 2017.

TABLE OF CONTENTS

FORWARD‑LOOKING STATEMENTS

Certain statements and information in this Annual Report on Form 10‑K may constitute forward‑looking statements within the meaning of the Private Securities Litigation Reform Act of 1995. The words “believe,” “expect,” “anticipate,” “plan,” “intend,” “foresee,” “should,” “would,” “could,” or other similar expressions are intended to identify forward‑looking statements, which are generally not historic in nature. These forward‑looking statements are based on the current expectations and beliefs of Comfort Systems USA, Inc. and its subsidiaries (collectively, the “Company”) concerning future developments and their effect on the Company. While the Company’s management believes that these forward‑looking statements are reasonable as and when made, there can be no assurance that future developments affecting the Company will be those that it anticipates. All comments concerning the Company’s expectations for future revenue and operating results are based on the Company’s forecasts for its existing operations and do not include the potential impact of any future acquisitions. The Company’s forward‑looking statements involve significant risks and uncertainties (some of which are beyond the Company’s control) and assumptions that could cause actual future results to differ materially from the Company’s historical experience and its present expectations or projections. Known material factors that could cause the Company’s actual results to differ from those in the forward‑looking statements are those described in Part I, “Item 1A. Risk Factors.”

Readers are cautioned not to place undue reliance on forward‑looking statements, which speak only as of the date hereof. The Company undertakes no obligation to publicly update or revise any forward‑looking statements after the date they are made, whether as a result of new information, future events, or otherwise.

PART I

The terms “Comfort Systems,” “we,” “us,” or “the Company” refer to Comfort Systems USA, Inc. or Comfort Systems USA, Inc. and its consolidated subsidiaries, as appropriate in the context.

ITEM 1.  Business

Comfort Systems USA, Inc., a Delaware corporation, was established in 1997. We provide comprehensive mechanical contracting services, which principally includes heating, ventilation and air conditioning (“HVAC”), plumbing, piping and controls, as well as off‑site construction, electrical, monitoring and fire protection. We install, maintain, repair and replace products and systems throughout our 36 operating units with 115 locations in 102 cities throughout the United States.

We operate primarily in the commercial, industrial and institutional HVAC markets and perform most of our services in industrial, healthcare, education, office, technology, retail and government facilities. Approximately 99% of our consolidated 2017 revenue was derived from commercial, industrial and institutional customers and multi‑family residential projects. Approximately 38% of our revenue was attributable to installation services in newly constructed facilities and 62% was attributable to renovation, expansion, maintenance, repair and replacement services in existing buildings. Our consolidated 2017 revenue was derived from the following service activities, substantially all of which are in the mechanical services industry, the single industry segment we serve:

Industry Overview

We believe that the commercial, industrial, and institutional mechanical contracting generates annual revenue in the United States of approximately $100 billion. Mechanical systems are necessary to virtually all commercial, industrial and institutional buildings. Because most buildings are sealed, HVAC systems provide the primary method of circulating fresh air in such buildings. In many instances, replacing an aging building’s existing systems with modern, energy‑efficient systems significantly reduces a building’s operating costs while improving air quality and overall system effectiveness. Older commercial, industrial and institutional facilities often have poor air quality as well as inadequate air conditioning, and older HVAC systems result in significantly higher energy costs than do modern systems.

Many factors positively affect mechanical services industry growth, particularly (i) population growth, which increases the need for commercial, industrial and institutional space, (ii) an aging installed base of buildings and equipment, (iii) increasing sophistication, complexity and efficiency of mechanical systems, and (iv) growing emphasis on environmental and energy efficiency.

Our industry can be broadly divided into two categories:

Construction, Installation, Expansion and Renovation Services— Construction, installation, expansion and renovation services consist of “design and build” and “plan and spec” projects. In “design and build” projects, the commercial HVAC company is responsible for designing, engineering and installing a cost‑effective, energy‑efficient system customized to the specific needs of the building owner. Costs and other project terms are normally negotiated between the building owner or its representative and the contracting company. Companies that specialize in “design and

build” projects use a consultative approach with customers and tend to develop long‑term relationships with building owners and developers, general contractors, architects, consulting engineers and property managers. “Plan and spec” installation refers to projects in which a third‑party architect or consulting engineer designs the HVAC systems and the installation project is “put out for bid.” We believe that “plan and spec” projects usually take longer to complete than “design and build” projects because the system design and installation process are not integrated, thus resulting in more frequent adjustments to project specifications, work requirements and schedules.

Maintenance, Repair and Replacement Services—These services include maintaining, repairing, replacing, reconfiguring and monitoring previously installed systems and building automation controls. The growth and aging of the installed base of HVAC and related systems, and the demand for more efficient and sophisticated systems and building automation controls have fueled growth in these services. The increasing complexity of these systems leads many commercial, industrial and institutional building owners and property managers to outsource maintenance and repair, often through service agreements with service providers. State‑of‑the‑art control and monitoring systems feature electronic sensors and microprocessors. These systems require specialized training to install, maintain and repair.

Strategy

We focus on strengthening operating competencies and on increasing profit margins. The key objectives of our strategy are to generate growth in our operations, improve the productivity of our workforce and to acquire complementary businesses. In order to accomplish our objectives we are currently focused on the following elements:

Achieve Excellence in Core Competencies—We have identified six core competencies that we believe are critical to attracting and retaining customers, increasing operating income and cash flow and maximizing the productivity of our increasingly valuable skilled labor force. The six core competencies are: (i) customer cultivation and rapport, (ii) design and build expertise, (iii) effective pre-construction processes, (iv) job and cost tracking, (v) safety, and (vi) service excellence.

Achieve Operating Efficiencies—We think we can achieve operating efficiencies and cost savings through purchasing economies, adopting “best practices” operating programs, and focusing on job management to deliver services in a cost‑effective and efficient manner. We emphasize improving the “job loop” at our locations—qualifying, estimating, pricing and executing projects effectively and efficiently, then promptly assessing project experience for applicability to current and future projects. We also use our combined spend to gain purchasing advantages on products and services such as HVAC components, raw materials, services, vehicles, bonding, insurance and employee benefits.

Attract, Retain and Invest in our Employees—We seek to attract and retain quality employees by providing them an enhanced career path from working for a larger company, the opportunity to realize a more stable income and attractive benefits packages. We continually invest in training, including programs for project managers, field superintendents, service managers, service technicians, sales managers, estimators, and leadership and development of key managers and leaders. We are also increasing our national and local focus on skills training for our hourly workers.

Focus on Commercial, Industrial and Institutional Markets—We focus on the commercial, industrial and institutional building markets, including construction, maintenance, repair and replacement services. We believe that these complex markets are attractive because of their growth opportunities, large and diverse customer base, attractive margins and potential for long‑term relationships with building owners, property managers, general contractors and architects. Approximately 99% of our consolidated 2017 revenue was derived from commercial, industrial and institutional customers and large multi‑family residential projects.

Leveraging Resources and Capabilities—We believe significant operating efficiencies can be achieved by leveraging resources among our operating locations. For example, we have shifted certain fabrication activities to centralized locations in order to increase asset utilization. We opportunistically allocate our engineering, field and supervisory labor from one operation to another to more fully use our employee base, meet our customers’ needs and share expertise. We believe we have realized scale benefits from coordinated purchasing, technical innovation, insurance, benefits, bonding and financing activities across our operations.

Maintain a Diverse Customer, Geographic and Project Base—We have a distribution of revenue across end‑use sectors that we believe reduces our exposure to negative developments in any given sector. We also have

significant geographical diversification across all regions of the United States, again reducing our exposure to negative developments in any given region. Our distribution of revenue in 2017 by end‑use sector was as follows:

Approximately 81% of our revenue is earned on a project basis for installation of systems in newly constructed or existing facilities. As of December 31, 2017, we had 4,690 projects in process with an aggregate contract value of approximately $2.36 billion. Our average project takes six to nine months to complete, with an average contract price of approximately $504,000. This average project size, when taken together with the approximately 19% of our revenue derived from maintenance and service, provides us with a broad base of work in the construction services sector. A stratification of projects in progress as of December 31, 2017, by contract price, is as follows:

Strategic Service Initiative.  Over the last several years we have made substantial incremental investments to expand our service and maintenance revenue by increasing the value we can offer to service and maintenance customers. We are actively concentrating existing and new managerial and sales resources on training and hiring experienced employees to sell and profitably perform service work. In many locations we have added or upgraded our capability, and we believe our investments and efforts have provided a compelling customer value offering that stimulates growth in all aspects of our businesses.

Seek Growth through Acquisitions—We believe that we can increase our cash flow and operating income by continuing to opportunistically enter new markets or service lines through acquisition. We have dedicated a significant portion of our cash flow on an ongoing basis to seeking opportunities to acquire businesses that have strong assembled workforces, attractive market positions and capabilities and other attractive operational, management, growth and geographic characteristics.

Operations and Services Provided

We provide a wide range of construction, renovation, expansion, maintenance, repair and replacement services for mechanical and related systems in commercial, industrial and institutional properties. Our local management teams maintain responsibility for day‑to‑day operating decisions. Local management is augmented by regional leadership that focuses on core business competencies, regional financial performance, cooperation and coordination between locations, implementing best practices and corporate initiatives. In addition to senior management, local personnel generally include design engineers, sales personnel, customer service personnel, installation and service technicians, sheet metal and prefabrication technicians, estimators and administrative personnel. We have centralized certain administrative functions such as insurance, employee benefits, training, safety programs, marketing and cash management to enable our

local operating management to focus on pursuing new business opportunities and improving operating efficiencies. We also combine certain back office and administrative functions at various locations.

Construction and Installation Services for New Buildings—Our installation business related to newly constructed facilities, which comprised approximately 38% of our consolidated 2017 revenue, involves the design, engineering, integration, installation and start‑up of mechanical and related systems. We provide “design and build” and “plan and spec” installation services for office buildings, retail centers, apartment complexes, manufacturing plants, healthcare, education and government facilities and other commercial, industrial and institutional facilities. In a “design and build” installation, working with the customer, we determine the needed capacity and energy efficiency of the HVAC system that best suits the proposed facility. The final design, terms, price and timing of the project are then negotiated with the customer or its representatives, after which any necessary modifications are made to the system plan. In “plan and spec” installation, we participate in a bid process to provide labor, equipment, materials and installation based on the end user’s plans and engineering specifications.

Once an agreement has been reached, we order the necessary materials and equipment for delivery to meet the project schedule. In many instances, we fabricate ductwork and piping and assemble certain components for the system based on the mechanical drawing specifications, eliminating the need to subcontract ductwork or piping fabrication. Finally, we install the system at the project site, working closely with the owner or general contractor. Our average project takes six to nine months to complete, with an average contract price of approximately $504,000. We also perform larger project work, with 469 contracts in progress at December 31, 2017 with contract prices in excess of $1 million. Our largest project in progress at December 31, 2017 had a contract price of $46.4 million. Project contracts typically provide for periodic billings to the customer as we meet progress milestones or incur cost on the project. Project contracts in our industry also frequently allow for a small portion of progress billings or contract price to be withheld by the customer until after we have completed the work. Amounts withheld under this practice are known as retention or retainage.

Renovation, Expansion, Maintenance, Repair and Replacement Services for Existing Buildings—Our renovation, expansion, maintenance, repair and replacement services in existing buildings comprised approximately 62% of our consolidated 2017 revenue and include the maintenance, repair, replacement, renovation, expansion, reconfiguration and monitoring of mechanical systems including HVAC systems and industrial process piping. Approximately 43% of our consolidated 2017 revenue was derived from renovation, expansion, replacement and reconfiguration of existing systems for commercial, industrial and institutional customers.

Maintenance and repair services are provided either in response to service calls or under a service agreement. Service calls are coordinated by customer service representatives or dispatchers that use computer and communication technology to process orders, arrange service calls, dispatch technicians and communicate with and invoice customers. Service technicians work from service vehicles equipped with commonly used parts, supplies and tools to complete a variety of jobs. Commercial, industrial and institutional service agreements usually have terms of one or more years, with automatic annual renewals, and frequently include thirty‑ to sixty‑day cancellation notice periods. We also provide remote monitoring of temperature, pressure, humidity and air flow for HVAC systems.

Sources of Supply

The raw materials and components we use include HVAC system components, ductwork, steel, sheet metal and copper tubing and piping. These raw materials and components are generally available from a variety of domestic or foreign suppliers at competitive prices. Delivery times are typically short for most raw materials and standard components, but during periods of peak demand, may extend to one month or more. We estimate that direct purchase of commodities and finished products comprises between 10% and 15% of our average project cost. We have procedures to reduce commodity cost exposure such as; purchasing commodities early for particular projects, as well as frequently using time or market based escalation and escape provisions in bids and contracts.

Chillers for large units typically have the longest delivery time and generally have lead times of up to six months. The major components of commercial HVAC systems are compressors and chillers that are manufactured primarily by Carrier, Lennox, McQuay, Trane and York. The major suppliers of building automation control systems are Schneider, Honeywell, Johnson Controls, Siemens, Trane, York, Automated Logic, Delta, Distech, Rockwell and Novar. We do not have any significant contracts guaranteeing us a supply of raw materials or components.

Cyclicality and Seasonality

Historically, the construction industry has been highly cyclical. As a result, our volume of business, particularly in new construction projects and renovation, may be adversely affected by declines in new installation and replacement projects in various geographic regions of the United States during periods of economic weakness.

The HVAC industry is subject to seasonal variations. The demand for new installation and replacement is generally lower during the winter months (the first quarter of the year) due to reduced construction activity during inclement weather and less use of air conditioning during the colder months. Demand for HVAC services is generally higher in the second and third calendar quarters due to increased construction activity and increased use of air conditioning during the warmer months. Accordingly, we expect our revenue and operating results generally will be lower in the first calendar quarter.

Sales and Marketing

We have a diverse customer base, with no single customer accounting for more than 2% of consolidated 2017 revenue, and our largest customer often changes from year to year. Management and a dedicated sales force are responsible for developing and maintaining successful long‑term relationships with key customers. Customers generally include building owners and developers and property managers, as well as general contractors, architects and consulting engineers. We intend to continue our emphasis on developing and maintaining long‑term relationships with our customers by providing superior, high‑quality service in a professional manner. We believe we can continue to leverage the diverse technical and marketing strengths at individual locations to expand the services offered in other local markets. With respect to multi‑location service opportunities, we maintain a national sales force in our national accounts group.

Employees

As of December 31, 2017, we had approximately 8,700 employees. We have collective bargaining agreements covering less than ten employees. We have not experienced and do not expect any significant strikes or work stoppages and believe our relations with employees covered by collective bargaining agreements are good.

Recruiting, Training and Safety

Our continued success depends, in part, on our ability to continue to attract, retain and motivate qualified engineers, service technicians, field supervisors and project managers. We believe our success in retaining qualified employees will be based on the quality of our recruiting, training, compensation, employee benefits programs and opportunities for advancement. We provide numerous training programs for management, sales and leadership, as well as on‑the‑job training, technical training, apprenticeship programs, attractive benefit packages and career advancement opportunities within our company.

We have established comprehensive safety programs throughout our operations to ensure that all technicians comply with safety standards we have established and that are established under federal, state and local laws and regulations. Additionally, we have implemented a “best practices” safety program throughout our operations, which provides employees with incentives to improve safety performance and decrease workplace accidents. Safety leadership establishes safety programs and benchmarking to improve safety across the Company. Finally, our employment screening process seeks to determine that prospective employees have requisite skills, sufficient background references and acceptable driving records, if applicable. Our rate of incidents recordable under the standards of the Occupational Safety and Health Administration (“OSHA”) per one hundred employees per year, also known as the OSHA recordable rate, was 1.67 during 2017. This level was 2% better than the most recently published OSHA rate for our industry.

Insurance and Litigation

The primary insured risks in our operations are bodily injury, property damage and workers’ compensation injuries. We retain the risk for workers’ compensation, employer’s liability, auto liability, general liability and employee group health claims resulting from uninsured deductibles per-incident or occurrence. Because we have very large deductibles, the vast majority of our claims are paid by us, so as a practical matter we self‑insure the great majority of these risks. Losses up to such per‑incident deductible amounts are estimated and accrued based upon known facts, historical trends and industry averages using the assistance of an actuary to project the extent of these obligations.

We are subject to certain claims and lawsuits arising in the normal course of business. We maintain various insurance coverages to minimize financial risk associated with these claims. We have estimated and provided accruals for probable losses and related legal fees associated with certain litigation in our consolidated financial statements. While we cannot predict the outcome of these proceedings, in our opinion and based on reports of counsel, any liability arising from these matters individually and in the aggregate will not have a material effect on our operating results, cash flows or financial condition, after giving effect to provisions already recorded.

We typically warrant labor for the first year after installation on new HVAC systems and pass through to the customer manufacturers’ warranties on equipment. We generally warrant labor for thirty days after servicing existing HVAC systems. We do not expect warranty claims to have a material adverse effect on our financial position or results of operations.

Competition

The HVAC industry is highly competitive and consists of thousands of local and regional companies. We believe that purchasing decisions in the commercial, industrial and institutional markets are based on (i) competitive price, (ii) relationships, (iii) quality, timeliness and reliability, (iv) tenure, financial strength and access to bonding, (v) range of capabilities, and (vi) scale of operation. To improve our competitive position, we focus on both the consultative “design and build” installation market and the maintenance, repair and replacement market in order to develop and strengthen customer relationships. In addition, we believe our ability to provide multi‑location coverage and a broad range of services gives us a strategic advantage over smaller competitors who may have more limited resources and capabilities.

We believe that we are larger than most of our competitors, which are generally small, owner‑operated companies in a specific area. However, there are divisions of larger contracting companies, utilities and HVAC equipment manufacturers that provide HVAC services in some of the same service lines and geographic areas we serve. Some of these competitors and potential competitors have greater financial resources than we do to finance development opportunities and support their operations. We believe our smaller competitors generally compete with us based on price and their long‑term relationships with local customers. Our larger competitors compete with us on those factors but may also provide attractive financing and comprehensive service and product packages.

Vehicles

We operate a fleet of various owned or leased service trucks, vans and support vehicles. We believe these vehicles generally are well maintained and sufficient for our current operations.

Governmental Regulation and Environmental Matters

Our operations are subject to various federal, state and local laws and regulations, including: (i) licensing requirements applicable to engineering, construction and service technicians, (ii) building and HVAC codes and zoning ordinances, (iii) regulations relating to consumer protection, including those governing residential service agreements, (iv) special bidding and procurement requirements on government projects, (v) wage and hour regulations, and (vi) regulations relating to worker safety and protection of the environment. For example, our operations are subject to the requirements of the Occupational Safety and Health Act, or OSHA, and comparable state laws directed towards protection of employees. We believe we have all required licenses to conduct our operations and are in substantial compliance with applicable regulatory requirements. If we fail to comply with applicable regulations, we could be subject to substantial fines or revocation of our operating licenses.

Many state and local regulations governing the HVAC services trades require individuals to hold permits and licenses. In some cases, a required permit or license held by a single individual may be sufficient to authorize specified activities for all of our service technicians who work in the state or county that issued the permit or license. We seek to ensure that, where possible, we have two employees who hold any such permits or licenses that may be material to our operations in a particular geographic region.

Our operations are subject to the federal Clean Air Act, as amended, which governs air emissions and imposes specific requirements on the use and handling of ozone‑depleting refrigerants generally classified as chlorofluorocarbons (CFCs) or hydrochlorofluorocarbons (HCFCs). Clean Air Act regulations promulgated by the United States Environmental Protection Agency (USEPA) require the certification of service technicians involved in the service or

repair of equipment containing these refrigerants and also regulate the containment and recycling of these refrigerants. These requirements have increased our training expenses and expenditures for containment and recycling equipment. The Clean Air Act is intended ultimately to eliminate the use of ozone‑depleting substances such as CFCs and HCFCs in the United States and to require alternative refrigerants to be used in replacement HVAC systems. Some replacement refrigerants, already in use, and classified as hydrofluorocarbons (HFCs) are not ozone‑depleting substances. HFCs are considered by USEPA to have high global warming potential. USEPA may at some point require the phase‑out of HFCs and expand existing technician certification requirements to cover the handling of HFCs. We do not believe the existing regulations governing technician certification requirements for the handling of ozone‑depleting substances or possible future regulations applicable to HFCs will materially affect our business on the whole because, although they require us to incur modest ongoing training costs, our competitors also incur such costs, and such regulations may encourage or require our customers to update their HVAC systems.

Additional Information

Our Internet address is www.comfortsystemsusa.com. We make available free of charge on or through our website our annual report on Form 10‑K, quarterly reports on Form 10‑Q, current reports on Form 8‑K, and amendments to those reports filed or furnished pursuant to Section 13(a) or 15(d) of the Exchange Act as soon as reasonably practicable after we electronically file such material with, or furnish it to, the Securities and Exchange Commission. Our website also includes our code of ethics, titled “Corporate Compliance Policy: Standards and Procedures Regarding Business Practices,” together with other governance materials including our corporate governance standards and our Board committee charters. Printed versions of our code of ethics and our corporate governance standards may be obtained upon written request to our Corporate Compliance Officer at our headquarters address.

You may read and copy any materials filed with the Securities and Exchange Commission at the Securities and Exchange Commission’s Public Reference Room at 100 F Street, NE, Washington, DC 20549. You may obtain information on the operation of the Public Reference Room by calling the Securities and Exchange Commission at 1-800-SEC-0330. This information is also available at www.sec.gov. The reference to these website addresses does not constitute incorporation by reference of the information contained on the websites and should not be considered part of this document.

ITEM 1A.  Risk Factors

Our business is subject to a variety of risks. You should carefully consider the risks described below, together with all the information included in this report. Our business, financial condition and results of operations could be adversely affected by the occurrence of any of these events, which could cause actual results to differ materially from expected and historical results, and the trading price of our common stock could decline.

Many of the markets we do work in are currently experiencing an economic downturn or might in the future experience an economic downturn that may materially and adversely affect our business because our business is dependent on levels of construction activity.

The demand for our services is dependent upon the existence of construction projects and service requirements within the markets in which we operate. Any period of economic recession affecting a market or industry in which we transact business is likely to adversely impact our business. Many of the projects we work on have long lifecycles from conception to completion, and the bulk of our performance generally occurs late in a construction project’s lifecycle. We experience the results of economic trends well after an economic cycle begins, and therefore will continue to experience the results of an economic recession well after conditions in the general economy have improved.

The industries and markets we operate in have always been and will continue to be vulnerable to macroeconomic downturns because they are cyclical in nature. When there is a reduction in demand, it often leads to greater price competition as well as decreased revenue and profit. The lasting effects of a recession can also increase economic instability with our vendors, subcontractors, developers, and general contractors, which can cause us greater liability exposure and can result in us not being paid on some projects, as well as decreasing our revenue and profit. Further, to the extent some of our vendors, subcontractors, developers, or general contractors seek bankruptcy protection, the bankruptcy will likely force us to incur additional costs in attorneys’ fees, as well as other professional consultants, and will result in decreased revenue and profit. Additionally, a reduction in federal, state, or local government spending in our industries and markets could result in decreased revenue and profit for us.

Because we bear the risk of cost overruns in most of our contracts, we may experience reduced profits or, in some cases, losses under these contracts if costs increase above our estimates.

Our contract prices are established largely upon estimates and assumptions of our projected costs, including assumptions about: future economic conditions; prices, including commodities prices; availability of labor, including the costs of providing labor, equipment, and materials; and other factors outside our control. If our estimates or assumptions prove to be inaccurate, if circumstances change in a way that renders our assumptions and estimates inaccurate or we fail to successfully execute the work, cost overruns may occur and we could experience reduced profits or a loss for affected projects. For instance, unanticipated technical problems may arise, we could have difficulty obtaining permits or approvals, local laws, labor costs or labor conditions could change, bad weather could delay construction, raw materials prices could increase, our suppliers or subcontractors may fail to perform as expected or site conditions may be different than we expected. We are also exposed to increases in energy prices, particularly as they relate to gasoline prices. Additionally, in certain circumstances, we guarantee project completion or the achievement of certain acceptance and performance testing levels by a scheduled date. Failure to meet schedule or performance requirements typically results in additional costs to us, and in some cases we may also create liability for consequential and liquidated damages. Performance problems for existing and future projects could cause our actual results of operations to differ materially from those we anticipate and could damage our reputation within our industry and our customer base.

Our backlog is subject to unexpected adjustments and cancellations, which means that amounts included in our backlog may not result in actual revenue or translate into profits.

The revenue projected from our backlog may not be realized, or, if realized, may not result in profits. Projects may remain in our backlog for an extended period of time, or project cancellations or scope adjustments may occur with respect to contracts reflected in our backlog.

Intense competition in our industry could reduce our market share and our profit.

The markets we serve are highly fragmented and competitive. Our industry is characterized by many small companies whose activities are geographically concentrated. We compete on the basis of our technical expertise and experience, financial and operational resources, nationwide presence, industry reputation and dependability. While we believe our customers consider a number of these factors in awarding available contracts, a large portion of our work is awarded through a bid process. Consequently, price is often the principal factor in determining which contractor is selected, especially on smaller, less complex projects. Smaller competitors are sometimes able to win bids for these projects based on price alone due to their lower cost and financial return requirements. We expect competition to intensify in our industry, presenting us with significant challenges in our ability to maintain strong growth rates and acceptable profit margins. We also expect increased competition from in‑house service providers, because some of our customers have employees who perform service work similar to the services we provide. Vertical consolidation is also expected to intensify competition in our industry. If we are unable to meet these competitive challenges, we will lose market share to our competitors and experience an overall reduction in our profits. In addition, our profitability would be impaired if we have to reduce our prices to remain competitive.

If we are unable to attract and retain qualified managers and employees, we will be unable to operate efficiently, which could reduce our profitability.

Our business is labor intensive, and many of our operations experience a high rate of employment turnover. At times of low unemployment rates in the United States, it will be more difficult for us to find qualified personnel at low cost in some geographic areas where we operate. Additionally, our business is managed by a small number of key executive and operational officers. We may be unable to hire and retain the sufficient skilled labor force necessary to operate efficiently and to support our growth strategy. Our labor expenses may increase as a result of a shortage in the supply of skilled personnel. Labor shortages, increased labor costs or the loss of key personnel could reduce our profitability and negatively impact our business. Further, our relationship with some customers could suffer if we are unable to retain the employees with whom those customers primarily work and have established relationships.

Our recent and future acquisitions may not be successful.

We expect to continue pursuing selective acquisitions of businesses. We cannot assure that we will be able to locate acquisitions or that we will be able to consummate transactions on terms and conditions acceptable to us, or that

acquired businesses will be profitable. Acquisitions may expose us to additional business risks different than those we have traditionally experienced. We also may encounter difficulties integrating acquired businesses and successfully managing the growth we expect to experience from these acquisitions.

We may choose to finance future acquisitions with debt, equity, cash or a combination of the three. Future acquisitions could dilute earnings or disrupt the payment of a stockholder dividend. To the extent we succeed in making acquisitions, a number of risks will result, including:

The failure to successfully integrate acquisitions could have an adverse effect on our business, financial condition and results of operations.

Information technology system failures, network disruptions or cyber security breaches could adversely affect our business.

We use sophisticated information technology systems, networks, and infrastructure in conducting some of our day‑to‑day operations and providing services to certain customers. Information technology system failures, including suppliers’ or vendors’ system failures, could disrupt our operations by causing transaction errors, processing inefficiencies, the loss of customers, other business disruptions or the loss of employee personal information. In addition, these systems, networks, and infrastructure may be vulnerable to deliberate cyber‑attacks that interfere with their functionality or the confidentiality of our information or our customers’ data. These events could impact our customers, employees and reputation and lead to financial losses from remediation actions, loss of business or potential liability or an increase in expense, all of which may have a material adverse effect on our business.

Third parties contribute significantly to our completion of many projects.

We hire third‑party subcontractors to perform work and depend on third‑party suppliers to provide equipment and materials necessary to complete our projects. If we are unable to retain qualified subcontractors or suppliers, or if our subcontractors or suppliers do not perform as anticipated for any reason, our execution and profitability could be harmed.

Earnings for future periods may be impacted by impairment charges for goodwill and intangible assets.

We carry a significant amount of goodwill and identifiable intangible assets on our consolidated balance sheets. Goodwill is the excess of purchase price over the fair value of the net assets of acquired businesses. We assess goodwill for impairment each year, and more frequently if circumstances suggest an impairment may have occurred. We have determined in the past and may again determine in the future that a significant impairment has occurred in the value of our unamortized intangible assets or fixed assets, which could require us to write off a portion of our assets and could adversely affect our financial condition or our reported results of operations.

Actual and potential claims, lawsuits and proceedings could ultimately reduce our profitability and liquidity and weaken our financial condition.

We are likely to continue to be named as a defendant in legal proceedings claiming damages from us in connection with the operation of our business. These actions and proceedings may involve claims for, among other things, compensation for alleged personal injury, workers’ compensation, employment discrimination, breach of contract or property damage. In addition, we may be subject to class action lawsuits involving allegations of violations of the Fair Labor Standards Act and state wage and hour laws. Due to the inherent uncertainties of litigation, we cannot accurately predict the ultimate outcome of any such actions or proceedings. We also are, and are likely to continue to be, from time to time a plaintiff in legal proceedings against customers, in which we seek to recover payment of contractual amounts we are owed as well as claims for increased costs we incur. When appropriate, we establish provisions against possible exposures, and we adjust these provisions from time to time according to ongoing exposure. If our assumptions and estimates related to these exposures prove to be inadequate or inaccurate, we could experience a reduction in our profitability and liquidity and a weakening of our financial condition. In addition, claims, lawsuits and proceedings may harm our reputation or divert management resources away from operating our business.

We typically warrant the services we provide, guaranteeing the work performed against defects in workmanship and the material we supply. Historically, warranty claims have not been material as our customers evaluate much of the work we perform for defects shortly after work is completed. However, if warranty claims occur, we could be required to repair or replace warrantied items at our cost. In addition, our customers may elect to repair or replace the warrantied item by using the services of another provider and require us to pay for the cost of the repair or replacement. Costs incurred as a result of warranty claims could adversely affect our operating results and financial condition.

Our use of the percentage‑of‑completion method of accounting could result in a reduction or reversal of previously recorded revenue or profits.

A material portion of our revenue is recognized using the percentage‑of‑completion method of accounting, which results in our recognizing contract revenue and earnings ratably over the contract term in the proportion that our actual costs bear to our estimated contract costs. The earnings or losses recognized on individual contracts are based on estimates of contract revenue, costs and profitability. We review our estimates of contract revenue, costs and profitability on an ongoing basis. Prior to contract completion, we may adjust our estimates on one or more occasions as a result of change orders to the original contract, collection disputes with the customer on amounts invoiced or claims against the customer for increased costs incurred by us due to customer‑induced delays and other factors. Contract losses are recognized in the fiscal period when the loss is determined. Contract profit estimates are also adjusted in the fiscal period in which it is determined that an adjustment is required. As a result of the requirements of the percentage‑of‑completion method of accounting, the possibility exists, for example, that we could have estimated and reported a profit on a contract over several periods and later determined, usually near contract completion, that all or a portion of such previously estimated and reported profits were overstated. If this occurs, the full aggregate amount of the overstatement will be reported for the period in which such determination is made, thereby eliminating all or a portion of any profits from other contracts that would have otherwise been reported in such period or even resulting in a loss being reported for such period. On a historical basis, we believe that we have made reasonably reliable estimates of the progress towards completion on our long‑term contracts. However, given the uncertainties associated with these types of contracts, it is possible for actual costs to vary from estimates previously made, which may result in reductions or reversals of previously recorded revenue and profits.

A significant portion of our business depends on our ability to provide surety bonds. Any difficulties in the financial and surety markets may adversely affect our bonding capacity and availability.

In the past we have expanded, and it is possible we will continue to expand, the number and percentage of total contract dollars that require an underlying bond. Historically surety market conditions have experienced times of difficulty as a result of significant losses incurred by many surety companies and the results of macroeconomic trends outside of our control. Consequently, during times when less overall bonding capacity is available in the market, surety terms have become more expensive and more restrictive. As such, we cannot guarantee our ability to maintain a sufficient level of bonding capacity in the future, which could preclude our ability to bid for certain contracts or successfully contract with some customers. Additionally, even if we continue to be able to access bonding capacity to sufficiently bond future work, we may be required to post collateral to secure bonds, which would decrease the liquidity we would have available for other purposes. Our surety providers are under no commitment to guarantee our access to

new bonds in the future; thus, our ability to access or increase bonding capacity is at the sole discretion of our surety providers. If our surety companies were to limit or eliminate our access to bonds, our alternatives would include seeking bonding capacity from other surety companies, increasing business with clients that do not require bonds and posting other forms of collateral for project performance, such as letters of credit or cash. We may be unable to secure these alternatives in a timely manner, on acceptable terms, or at all. As such, if we were to experience an interruption or reduction in the availability of bonding capacity, it is likely we would be unable to compete for or work on certain projects.

We are a decentralized company and place significant decision making powers with our subsidiaries’ management, which presents certain risks.

We believe that our practice of placing significant decision making powers with local management is important to our successful growth and allows us to be responsive to opportunities and to our customers’ needs. However, this practice presents certain risks, including the risk that we may be slower or less effective in our attempts to identify or react to problems affecting an important business than we would under a more centralized structure or that we would be slower to identify a misalignment between a subsidiary’s and the Company’s overall business strategy. Further, if a subsidiary location fails to follow the Company’s compliance policies, we could be made party to a contract, arrangement or situation that requires the assumption of large liabilities or has less advantageous terms than is typically found in the market.

Our insurance policies against many potential liabilities require high deductibles, and our risk management policies and procedures may leave us exposed to unidentified or unanticipated risks. Additionally, difficulties in the insurance markets may adversely affect our ability to obtain necessary insurance.

Although we maintain insurance policies with respect to our related exposures, these policies are subject to high deductibles; as such, we are, in effect, self‑insured for substantially all of our typical claims. We hire an actuary to determine any liabilities for unpaid claims and associated expenses for the three major lines of coverage (workers’ compensation, general liability and auto liability). The determination of these claims and expenses and the appropriateness of the estimated liability are reviewed and updated quarterly. However, insurance liabilities are difficult to assess and estimate due to the many relevant factors, the effects of which are often unknown, including the severity of an injury, the determination of our liability in proportion to other parties, the number of incidents that have occurred but are not reported and the effectiveness of our safety program. Our accruals are based on known facts, historical trends (both internal trends and industry averages) and our reasonable estimate of our future expenses. We believe our accruals are adequate. However, our risk management strategies and techniques may not be fully effective in mitigating our risk exposure in all market environments or against all types of risk. If any of the variety of instruments, processes or strategies we use to manage our exposure to various types of risk are not effective, we may incur losses that are not covered by our insurance policies or that exceed our accruals or coverage limits.

Additionally, we typically are contractually required to provide proof of insurance on projects we work on. Historically insurance market conditions become more difficult for insurance consumers during periods when insurance companies suffer significant investment losses as well as casualty losses. Consequently, it is possible that insurance markets will become more expensive and restrictive. Also, our prior casualty loss history might adversely affect our ability to procure insurance within commercially reasonable ranges. As such, we may not be able to maintain commercially reasonable levels of insurance coverage in the future, which could preclude our ability to work on many projects. Our insurance providers are under no commitment to renew our existing insurance policies in the future; therefore, our ability to obtain necessary levels or kinds of insurance coverage is subject to market forces outside our control. If we were unable to obtain necessary levels of insurance, it is likely we would be unable to compete for or work on most projects.

Failure to remain in compliance with covenants under our credit agreement, service our indebtedness, or fund our other liquidity needs could adversely impact our business.

Our credit agreement and related restrictive and financial covenants are more fully described in Note 8 of “Notes to the Consolidated Financial Statements.” Our failure to comply with any of these covenants, or to pay principal, interest or other amounts when due thereunder, would constitute an event of default under the credit agreement. Default under our credit agreement could result in (1) us no longer being entitled to borrow under the agreement; (2) termination of the agreement; (3) acceleration of the maturity of outstanding indebtedness under the agreement; and/or

(4) foreclosure on any collateral securing the obligations under the agreement. If we are unable to service our debt obligations or fund our other liquidity needs, we could be forced to curtail our operations, reorganize our capital structure (including through bankruptcy proceedings) or liquidate some or all of our assets in a manner that could cause holders of our securities to experience a partial or total loss of their investment in us.

If we experience delays and/or defaults in customer payments, we could be unable to recover all expenditures.

Because of the nature of our contracts, at times we commit resources to projects prior to receiving payments from the customer in amounts sufficient to cover expenditures on projects as they are incurred. Delays in customer payments may require us to make a working capital investment. If a customer defaults in making their payments on a project to which we have devoted resources, it could have a material negative effect on our results of operations.

Our inability to properly utilize our workforce could have a negative impact on our profitability.

The extent to which we utilize our workforce affects our profitability. Underutilizing our workforce could result in lower gross margins and, consequently, a decrease in short‑term profitability. On the other hand, overutilization of our workforce could negatively impact safety, employee satisfactions and project execution, leading to a potential decline in future project awards. The utilization of our workforce is impacted by numerous factors, including:

Misconduct by our employees, subcontractors or partners or our overall failure to comply with laws or regulations could harm our reputation, damage our relationships with customers, reduce our revenue and profits, and subject us to criminal and civil enforcement actions.

Misconduct, fraud, non‑compliance with applicable laws and regulations, or other improper activities by one or more of our employees, subcontractors or partners could have a significant negative impact on our business and reputation. Examples of such misconduct include employee or subcontractor theft, the failure to comply with safety standards, laws and regulations, customer requirements, environmental laws and any other applicable laws or regulations. While we take precautions to prevent and detect these activities, such precautions may not be effective and are subject to inherent limitations, including human error and fraud. Our failure to comply with applicable laws or regulations or acts of misconduct could subject us to fines and penalties, harm our reputation, damage our relationships with customers, reduce our revenue and profits and subject us to criminal and civil enforcement actions.

Failure or circumvention of our disclosure controls and procedures or internal controls over financial reporting could seriously harm our financial condition, results of operations, and our business.

We plan to continue to maintain and strengthen internal controls and procedures to enhance the effectiveness of our disclosure controls and internal controls over financial reporting. Any system of controls, however well designed and operated, is based in part on certain assumptions and can provide only reasonable, and not absolute, assurances that the objectives of the system are met. Any failure of our disclosure controls and procedures or internal controls over financial reporting could harm our financial condition and results of operations.

We have subsidiary operations through the United States and are exposed to multiple state and local regulations, as well as federal laws and requirements applicable to government contractors. Changes in law, regulations or requirements, or a material failure of any of our subsidiaries or us to comply with any of them, could increase our costs and have other negative impacts on our business.

Our 115 locations are located in 27 states, which exposes us to a variety of different state and local laws and regulations, particularly those pertaining to contractor licensing requirements. These laws and regulations govern many aspects of our business, and there are often different standards and requirements in different locations. In addition, our subsidiaries that perform work for federal government entities are subject to additional federal laws and regulatory and contractual requirements. Changes in any of these laws, or any of our subsidiaries’ material failure to comply with them,

can adversely impact our operations by, among other things, increasing costs, distracting management’s time and attention from other items, and harming our reputation.

As government contractors, our subsidiaries are subject to a number of rules and regulations, and their contracts with government entities are subject to audit. Violations of the applicable rules and regulations could result in a subsidiary being barred from future government contracts.

Government contractors must comply with many regulations and other requirements that relate to the award, administration and performance of government contracts. A violation of these laws and regulations could result in imposition of fines and penalties, the termination of a government contract or debarment from bidding on government contracts in the future. Further, despite our decentralized nature, a violation at one of our locations could impact other locations’ ability to bid on and perform government contracts; additionally, because of our decentralized nature, we face risks in maintaining compliance with all local, state and federal government contracting requirements. Prohibition against bidding on future government contracts could have an adverse effect on our financial condition and results of operations.

Past and future environmental, safety and health regulations could impose significant additional costs on us that reduce our profits.

HVAC systems are subject to various environmental statutes and regulations, including the Clean Air Act and those regulating the production, servicing and disposal of certain ozone‑depleting refrigerants used in HVAC systems. There can be no assurance that the regulatory environment in which we operate will not change significantly in the future. Various local, state and federal laws and regulations impose licensing standards on technicians who install and service HVAC systems. And additional laws, regulations and standards apply to contractors who perform work that is being funded by public money, particularly federal public funding. Our failure to comply with these laws and regulations could subject us to substantial fines, the loss of our licenses or potentially debarment from future publicly funded work. It is impossible to predict the full nature and effect of judicial, legislative or regulatory developments relating to health and safety regulations and environmental protection regulations applicable to our operations.

Unsatisfactory safety performance may subject us to penalties, affect customer relationships, result in higher operating costs, negatively impact employee morale and result in higher employee turnover.

Our projects are conducted at a variety of sites including construction sites and industrial facilities. Each location is subject to numerous safety risks, including electrocutions, fires, explosions, mechanical failures, weather‑related incidents, transportation accidents and damage to equipment. These hazards can cause personal injury and loss of life, severe damage to or destruction of property and equipment and other consequential damages and could lead to suspension of operations, large damage claims and, in extreme cases, criminal liability. While we have taken what we believe are appropriate precautions to minimize safety risks, we have experienced serious accidents, including fatalities, in the past and may experience additional accidents in the future. Serious accidents may subject us to penalties, civil litigation or criminal prosecution. Claims for damages to persons, including claims for bodily injury or loss of life, could result in significant costs and liabilities, which could adversely affect our financial condition and results of operations. Poor safety performance could also jeopardize our relationships with our customers and harm our reputation.

If we do not effectively manage the size and cost of our operations, our existing infrastructure may become either strained or over‑burdensome, and we may be unable to increase revenue growth.

The growth that we have experienced in the past, and that we may experience in the future, may provide challenges to our organization, requiring us to expand our personnel and our operations. Future growth may strain our infrastructure, operations and other managerial and operating resources. We have also experienced in the past severe constriction in the markets in which we operate and, as a result, in our operating requirements. Failing to maintain the appropriate cost structure for a particular economic cycle may result in our incurring costs that affect our profitability. If our business resources become strained or over‑burdensome, our earnings may be adversely affected and we may be unable to increase revenue growth. Further, we may undertake contractual commitments that exceed our labor resources, which could also adversely affect our earnings and our ability to increase revenue growth.

We are susceptible to adverse weather conditions, which may harm our business and financial results.

Our business may be adversely affected by severe weather in areas where we have significant operations. Repercussions of severe weather conditions may include:

Future climate change could adversely affect us.

Climate change may create physical and financial risk. Physical risks from climate change could, among other things, include an increase in extreme weather events (such as floods or hurricanes), rising sea levels and limitations on water availability and quality. Such extreme weather conditions may limit the availability of resources, increasing the costs of our projects, or may cause projects to be delayed or cancelled.

Legislation, nationwide protocols, regulation or other restrictions related to climate change could negatively impact our operations or our customers’ operations. Such legislation or restrictions could increase the costs of projects for our customers or, in some cases, prevent a project from going forward, which could in turn have an adverse effect on our financial condition and results of operations.

Force majeure events, including natural disasters and terrorists’ actions, could negatively impact our business, which may affect our financial condition, results of operations or cash flows.

Force majeure or extraordinary events beyond the control of the contracting parties, such as natural and man‑made disasters, as well as terrorist actions, could negatively impact us. We typically negotiate contract language where we are allowed certain relief from force majeure events in private client contracts and review and attempt to mitigate force majeure events in both public and private client contracts. We remain obligated to perform our services after most extraordinary events subject to relief that may be available pursuant to a force majeure clause. If we are not able to react quickly to force majeure events, our operations may be affected significantly, which would have a negative impact on our financial position, results of operations, cash flows and liquidity.

Deliberate, malicious acts, including terrorism and sabotage, could damage our facilities, disrupt our operations or injure employees, contractors, customers or the public and result in liability to us.

Intentional acts of destruction could damage or destroy our facilities, reducing our operational production capacity and requiring us to repair or replace our facilities at substantial cost. Additionally, employees, contractors and the public could suffer substantial physical injury from acts of terrorism for which we could be liable. Governmental authorities may also impose security or other requirements that could make our operations more difficult or costly. The consequences of any such actions could adversely affect our financial condition and results of operations.

Our common stock, which is listed on the New York Stock Exchange, has from time to time experienced significant price and volume fluctuations. These fluctuations are likely to continue in the future, and our stockholders may suffer losses.

The market price of our common stock may change significantly in response to various factors and events beyond our control. A variety of events may cause the market price of our common stock to fluctuate significantly, including the following: (i) the risk factors described in this Report on Form 10‑K; (ii) a shortfall in operating revenue or net income from that expected by securities analysts and investors; (iii) quarterly fluctuations in our operating results; (iv) changes in securities analysts’ estimates of our financial performance or that of our competitors or companies in our industry generally; (v) general conditions in our customers’ industries; (vi) general conditions in the securities markets; (vii) our announcements of significant contracts, milestones, acquisitions; (viii) our relationship with other companies; (ix) our investors’ view of the sectors and markets in which we operate; and (x) additions or departures of key personnel. Some companies that have volatile market prices for their securities have been subject to security class action suits filed against them. If a suit were to be filed against us, regardless of the outcome, it could result in substantial costs and a diversion of our management’s attention and resources. This could have a material adverse effect on our business, results of operations and financial condition.

We are required to assess and report on our internal controls each year. Findings of inadequate internal controls could reduce investor confidence in the reliability of our financial information.

As directed by the Sarbanes‑Oxley Act, the SEC adopted rules generally requiring public companies, including us, to include in their annual reports on Form 10‑K a report of management that contains an assessment by management of the effectiveness of our internal control over financial reporting. In addition, the independent registered public accounting firm auditing our financial statements must report on the effectiveness of our internal control over financial reporting. A company’s internal control over financial reporting is a process designed by, or under the supervision of, the company’s principal executive and principal financial officers, or persons performing similar functions, and effected by the company’s board of directors, management, and other personnel to provide reasonable assurance regarding the reliability of financial reporting and the preparation of financial statements for external purposes in accordance with generally accepted accounting principles. A company’s internal control over financial reporting includes those policies and procedures that (1) pertain to the maintenance of records that, in reasonable detail, accurately and fairly reflect the transactions and dispositions of the assets of the company; (2) provide reasonable assurance that transactions are recorded as necessary to permit preparation of financial statements in accordance with generally accepted accounting principles and that receipts and expenditures of the company are being made only in accordance with authorizations of management and records of the company; and (3) provide reasonable assurance regarding prevention or timely detection of unauthorized acquisition, use, or disposition of the company’s assets that could have a material effect on the financial statements.

We may discover in the future that we have deficiencies in the design and operation of our internal controls. If any of the deficiencies in our internal control, either by itself or in combination with other deficiencies, becomes a “material weakness”, such that there is a reasonable possibility that a material misstatement of the annual or interim financial statements will not be prevented or detected on a timely basis, we may be unable to conclude that we have effective internal control over financial reporting. In such event, investors could lose confidence in the reliability of our financial statements, which may significantly harm our business and cause our stock price to decline. In addition, the failure to maintain effective internal controls could also result in unauthorized transactions.

Future sales of our common stock may depress our stock price.

Sales of a substantial number of shares of our common stock in the public market or otherwise, either by us, a member of management or a major stockholder, or the perception that these sales could occur, could depress the market price of our common stock and impair our ability to raise capital through the sale of additional equity securities.

Increases and uncertainty in our health insurance costs could adversely impact our results of operations and cash flows.

The costs of employee health insurance have been increasing in recent years due to rising health care costs, legislative changes, and general economic conditions. Additionally, we may incur additional costs as a result of the Patient Protection and Affordable Care Act (the “Affordable Care Act”) that was signed into law in March 2010. Future

legislation could also have an impact on our business. For example, Government officials have made statements that suggest the current White House administration supports the repeal of all or portions of the Affordable Care Act, and Congress has introduced, and may introduce and pass in the future, new legislation to repeal or replace portions of the Affordable Care Act. Because of the continued uncertainty about the implementation of the Affordable Care Act, including the potential for further legal challenges or repeal of that legislation, it is unclear what the impact of the Affordable Care Act or its potential repeal will have on our financial position or results of operations.

Rising inflation and/or interest rates could have an adverse effect on our business, financial condition and results of operations.

Economic factors, including inflation and fluctuations in interest rates, could have a negative impact on our business. If our costs were to become subject to significant inflationary pressures or interest rate increases, we may not be able to fully offset such higher costs through price increases. Our inability or failure to do so could harm our financial position and results of operations.

Tax matters, including changes in corporate tax rates and disagreements with taxing authorities, could impact our results of operations and financial condition.

We conduct business across the United States and file income taxes in various tax jurisdictions. Our effective tax rates could be affected by many factors, some of which are outside of our control, including changes in tax laws and regulations in the various tax jurisdictions in which we file income taxes. For instance, the Tax Cuts and Jobs Act was enacted into law in December 2017. While certain portions of the law may have a positive impact on the Company’s results of operations, the overall impact of the new federal tax law is uncertain and our business and financial condition could be adversely affected. It is also unknown if and to what extent various states will conform to the newly enacted federal tax law. 

Issues relating to tax audits or examinations and any related interest or penalties and uncertainty in obtaining deductions or credits claimed in various jurisdictions could also impact our effective tax rates. Our results of operations are reported based on our determination of the amount of taxes we owe in various tax jurisdictions. Significant judgment is required in determining our provision for income taxes and our determination of tax liability is always subject to review or examination by tax authorities in applicable tax jurisdictions. An adverse outcome of such a review of examination could adversely affect our operating results and financial condition. Further, the results of tax examinations and audits could have a negative impact on our financial results and cash flows where the results differ from the liabilities recorded in our financial statements.

Our charter contains certain anti‑takeover provisions that may inhibit or delay a change in control.

Our certificate of incorporation authorizes our board of directors to issue, without stockholder approval, one or more series of preferred stock having such preferences, powers and relative, participating, optional and other rights (including preferences over the common stock respecting dividends and distributions and voting rights) as the board of directors may determine. The issuance of this “blank‑check” preferred stock could render more difficult or discourage an attempt to obtain control by means of a tender offer, merger, proxy contest or otherwise. Additionally, certain provisions of the Delaware General Corporation Law may also discourage takeover attempts that have not been approved by the Board of Directors.

ITEM 1B.  Unresolved Staff Comments

None.

ITEM 2.  Properties

As of December 31, 2017, we owned five properties. Other than these owned properties, we lease the real property and buildings from which we operate. Our facilities are located in 27 states and consist of offices, shops and fabrication, maintenance and warehouse facilities. Generally, leases range from three to ten years and are on terms we believe to be commercially reasonable. A majority of these premises are leased from individuals or entities with whom we have no other business relationship. In certain instances these leases are with current or former employees. To the extent we renew, enter into leases or otherwise change leases with current or former employees, we enter into such

agreements on terms that reflect a fair market valuation for the properties. Leased premises range in size from approximately 1,000 square feet to 110,000 square feet. To maximize available capital, we generally intend to continue to lease our properties, but may consider further purchases of property where we believe ownership would be more economical. We believe that our facilities are sufficient for our current needs.

We lease our executive and administrative offices in Houston, Texas.

ITEM 3.  Legal Proceedings

We are subject to certain claims and lawsuits arising in the normal course of business. We maintain various insurance coverages to minimize financial risk associated with these claims. We have estimated and provided accruals for probable losses and related legal fees associated with certain litigation in our consolidated financial statements. While we cannot predict the outcome of these proceedings, in our opinion and based on reports of counsel, any liability arising from these matters individually and in the aggregate will not have a material effect on our operating results, cash flows or financial condition, after giving effect to provisions already recorded.

ITEM 4.  Mine Safety Disclosures

Not applicable.

ITEM 4A.  Executive Officers of the Registrant

Executive officers are appointed by our Board of Directors and hold office until their successors are elected and duly qualified. The following persons serve as executive officers of the Company.

Brian Lane, age 60, has served as our Chief Executive Officer and President since December 2011 and as a director since November 2010. Mr. Lane served as our President and Chief Operating Officer from March 2010 until December 2011. Mr. Lane joined the Company in October 2003 and served as Vice President and then Senior Vice President for Region One of the Company until he was named Executive Vice President and Chief Operating Officer in January 2009. Prior to joining the Company, Mr. Lane spent fifteen years at Halliburton, the global service and equipment company devoted to energy, industrial, and government customers. During his tenure at Halliburton, he held various positions in business development, strategy, and project initiatives. He departed as the Regional Director of Europe and Africa. Mr. Lane’s additional experience included serving as a Regional Director of Capstone Turbine Corporation, a distributed power manufacturer. He also was a Vice President of Kvaerner, an international engineering and construction company where he focused on the chemical industry.

William George, age 53, has served as our Executive Vice President and Chief Financial Officer since May 2005, was our Senior Vice President, General Counsel and Secretary from May 1998 to May 2005, and was our Vice President, General Counsel and Secretary from March 1997 to April 1998. From October 1995 to February 1997, Mr. George was Vice President and General Counsel of American Medical Response, Inc., a publicly‑traded healthcare transportation company. From September 1992 to September 1995, Mr. George practiced corporate and antitrust law at Ropes & Gray, a Boston, Massachusetts law firm.

Julie S. Shaeff, age 52, has served as our Senior Vice President and Chief Accounting Officer since May 2005, was our Vice President and Corporate Controller from March 2002 to May 2005, and was our Assistant Corporate Controller from September 1999 to February 2002. From 1996 to August 1999, Ms. Shaeff was Financial Accounting Manager—Corporate Controllers Group for Browning‑Ferris Industries, Inc., a publicly‑traded waste services company. From 1987 to 1995, she held various positions with Arthur Andersen LLP. Ms. Shaeff is a Certified Public Accountant.

Trent T. McKenna, age 45, has served as our Senior Vice President, General Counsel and Secretary since August 2013, was our Vice President, General Counsel and Secretary from May 2005 to August 2013, and was our Associate General Counsel from August 2004 to May 2005. From February 1999 to August 2004, Mr. McKenna was a practicing attorney in the area of complex commercial litigation in the Houston, Texas office of Akin Gump Strauss Hauer & Feld LLP, an international law firm.

PART II

ITEM 5.  Market for Registrant’s Common Equity, Related Stockholder Matters and Issuer Purchases of Equity Securities

The following table sets forth the reported high and low sales prices of our Common Stock for the quarters indicated as traded at the New York Stock Exchange. Our Common Stock is traded under the symbol FIX:

As of February 15, 2018 there were approximately 364 stockholders of record of our Common Stock, and the last reported sale price on that date was $41.45 per share.

We expect to continue paying cash dividends quarterly, although there is no assurance as to future dividends because they depend on future earnings, capital requirements, and financial condition. In addition, our revolving credit agreement may limit the amount of dividends we can pay at any time that our Net Leverage Ratio exceeds 1.0.

The following Corporate Performance Graph and related information shall not be deemed “soliciting material” or to be “filed” with the SEC, nor shall such information be incorporated by reference into any future filing under the Securities Act or the Exchange Act, except to the extent that we specifically incorporate it by reference into such filing.

Recent Sales of Unregistered Securities

None.

Issuer Purchases of Equity Securities

On March 29, 2007, our Board of Directors (the “Board”) approved a stock repurchase program to acquire up to 1.0 million shares of our outstanding common stock. Subsequently, the Board has from time to time increased the number of shares that may be acquired under the program and approved extensions of the program. Since the inception of the repurchase program, the Board has approved 8.1 million shares to be repurchased. As of December 31, 2017, we have repurchased a cumulative total of 7.6 million shares at an average price of $13.75 per share under the repurchase program.

The share repurchases will be made from time to time at our discretion in the open market or privately negotiated transactions as permitted by securities laws and other legal requirements, and subject to market conditions and other factors. The Board may modify, suspend, extend or terminate the program at any time. During the twelve

months ended December 31, 2017, we repurchased 0.3 million shares for approximately $9.0 million at an average price of $34.23 per share.

During the year ended December 31, 2017, we purchased our common shares in the following amounts at the following weighted‑average prices:

ITEM 6.  Selected Financial Data

The following selected historical financial data has been derived from our audited financial statements and should be read in conjunction with the historical Consolidated Financial Statements and related notes:

ITEM 7.  Management’s Discussion and Analysis of Financial Condition and Results of Operations

The following discussion and analysis should be read in conjunction with the Consolidated Financial Statements and related notes included elsewhere in this annual report on Form 10‑K. Also see “Forward‑Looking Statements” discussion.

Introduction and Overview

We are a national provider of comprehensive mechanical installation, renovation, maintenance, repair and replacement services within the mechanical services industry. We operate primarily in the commercial, industrial and institutional HVAC markets and perform most of our services within office buildings, retail centers, apartment complexes, manufacturing plants, and healthcare, education and government facilities.

Nature and Economics of Our Business

Approximately 81% of our revenue is earned on a project basis for installation of mechanical systems in newly constructed facilities or for replacement of systems in existing facilities. Customers hire us to ensure such systems deliver specified or generally expected heating, cooling, conditioning and circulation of air in a facility. This entails installing core system equipment such as packaged heating and air conditioning units, or in the case of larger facilities, separate core components such as chillers, boilers, air handlers, and cooling towers. We also typically install connecting and distribution elements such as piping and ducting. Our responsibilities usually require conforming the systems to pre‑established engineering drawings and equipment and performance specifications, which we frequently participate in establishing. Our project management responsibilities include staging equipment and materials to project sites, deploying labor to perform the work, and coordinating with other service providers on the project, including any subcontractors we might use to deliver our portion of the work.

When competing for project business, we usually estimate the costs we will incur on a project, and then propose a bid to the customer that includes a contract price and other performance and payment terms. Our bid price and terms are intended to cover our estimated costs on the project and provide a profit margin to us commensurate with the value of the installed system to the customer, the risk that project costs or duration will vary from estimate, the schedule on which we will be paid, the opportunities for other work that we might forego by committing capacity to this project, and other costs that we incur to support our operations but which are not specific to the project. Typically, customers will seek pricing from competitors for a given project. While the criteria on which customers select a service provider vary widely and include factors such as quality, technical expertise, on‑time performance, post‑project support and service, and company history and financial strength, we believe that price for value is the most influential factor for most customers in choosing a mechanical installation and service provider.

After a customer accepts our bid, we generally enter into a contract with the customer that specifies what we will deliver on the project, what our related responsibilities are, and how much and when we will be paid. Our overall price for the project is typically set at a fixed amount in the contract, although changes in project specifications or work conditions that result in unexpected additional work are usually subject to additional payment from the customer via what are commonly known as change orders. Project contracts typically provide for periodic billings to the customer as we meet progress milestones or incur cost on the project. Project contracts in our industry also frequently allow for a small portion of progress billings or contract price to be withheld by the customer until after we have completed the work. Amounts withheld under this practice are known as retention or retainage.

Labor and overhead costs account for the majority of our cost of service. Accordingly, labor management and utilization have the most impact on our project performance. Given the fixed price nature of much of our project work, if our initial estimate of project costs is wrong or we incur cost overruns that cannot be recovered in change orders, we can experience reduced profits or even significant losses on fixed price project work. We also perform some project work on a cost‑plus or a time and materials basis, under which we are paid our costs incurred plus an agreed‑upon profit margin, and such projects are sometimes subject to a guaranteed maximum cost. These margins are frequently less than fixed‑price contract margins because there is less risk of unrecoverable cost overruns in cost‑plus or time and materials work.

As of December 31, 2017, we had 4,690 projects in process. Our average project takes six to nine months to complete, with an average contract price of approximately $504,000. Our projects generally require working capital

funding of equipment and labor costs. Customer payments on periodic billings generally do not recover these costs until late in the job. Our average project duration together with typical retention terms as discussed above generally allow us to complete the realization of revenue and earnings in cash within one year. We have what we believe is a well‑diversified distribution of revenue across end‑use sectors that we believe reduces our exposure to negative developments in any given sector. Because of the integral nature of HVAC and related controls systems to most buildings, we have the legal right in almost all cases to attach liens to buildings or related funding sources when we have not been fully paid for installing systems, except with respect to some government buildings. The service work that we do, which is discussed further below, usually does not give rise to lien rights.

We also perform larger projects. Taken together, projects with contract prices of $1 million or more totaled $1.83 billion of aggregate contract value as of December 31, 2017, or approximately 80%, out of a total contract value for all projects in progress of $2.36 billion. Generally, projects closer in size to $1 million will be completed in one year or less. It is unusual for us to work on a project that exceeds two years in length.

A stratification of projects in progress as of December 31, 2017, by contract price, is as follows:

In addition to project work, approximately 19% of our revenue represents maintenance and repair service on already installed HVAC and controls systems. This kind of work usually takes from a few hours to a few days to perform. Prices to the customer are based on the equipment and materials used in the service as well as technician labor time. We usually bill the customer for service work when it is complete, typically with payment terms of up to thirty days. We also provide maintenance and repair service under ongoing contracts. Under these contracts, we are paid regular monthly or quarterly amounts and provide specified service based on customer requirements. These agreements typically are for one or more years and frequently contain thirty‑ to sixty‑day cancellation notice periods.

A relatively small portion of our revenue comes from national and regional account customers. These customers typically have multiple sites, and contract with us to perform maintenance and repair service. These contracts may also provide for us to perform new or replacement systems installation. We operate a national call center to dispatch technicians to sites requiring service. We perform the majority of this work with our own employees, with the balance being subcontracted to third parties that meet our performance qualifications.

Profile and Management of Our Operations

We manage our 36 operating units based on a variety of factors. Financial measures we emphasize include profitability, and use of capital as indicated by cash flow and by other measures of working capital principally involving project cost, billings and receivables. We also monitor selling, general, administrative and indirect project support expense, backlog, workforce size and mix, growth in revenue and profits, variation of actual project cost from original estimate, and overall financial performance in comparison to budget and updated forecasts. Operational factors we emphasize include project selection, estimating, pricing, management and execution practices, labor utilization, safety, training, and the make‑up of both existing backlog as well as new business being pursued, in terms of project size, technical application and facility type, end‑use customers and industries, and location of the work.

Most of our operations compete on a local or regional basis. Attracting and retaining effective operating unit managers is an important factor in our business, particularly in view of the relative uniqueness of each market and operation, the importance of relationships with customers and other market participants such as architects and consulting engineers, and the high degree of competition and low barriers to entry in most of our markets. Accordingly, we devote considerable attention to operating unit management quality, stability, and contingency planning, including related considerations of compensation, and non‑competition protection where applicable.

Economic and Industry Factors

As a mechanical and building controls services provider, we operate in the broader nonresidential construction services industry and are affected by trends in this sector. While we do not have operations in all major cities of the United States, we believe our national presence is sufficiently large that we experience trends in demand for and pricing of our services that are consistent with trends in the national nonresidential construction sector. As a result, we monitor the views of major construction sector forecasters along with macroeconomic factors they believe drive the sector, including trends in gross domestic product, interest rates, business investment, employment, demographics, and the general fiscal condition of federal, state and local governments.

Spending decisions for building construction, renovation and system replacement are generally made on a project basis, usually with some degree of discretion as to when and if projects proceed. With larger amounts of capital, time, and discretion involved, spending decisions are affected to a significant degree by uncertainty, particularly concerns about economic and financial conditions and trends. We have experienced periods of time when economic weakness caused a significant slowdown in decisions to proceed with installation and replacement project work.

Operating Environment and Management Emphasis

Nonresidential building construction and renovation activity, as reported by the federal government, declined steeply over the four-year period from 2009 to 2012, and 2013 and 2014 activity levels were relatively stable at the low levels of the preceding years. During the three-year period from 2015 to 2017, there was an increase in overall activity levels and we currently expect that activity will continue at these improved levels during 2018.

As a result of our continued strong emphasis on cash flow, at December 31, 2017 we had modest indebtedness under our revolving credit facility, with positive uncommitted cash balances, as discussed further in “Liquidity and Capital Resources” below. We have a credit facility in place with considerably less restrictive terms than those of our previous facilities; this facility does not expire until February 2021. We have strong surety relationships to support our bonding needs, and we believe our relationships with the surety markets are strong and benefit from our solid current results and financial position. We have generated positive free cash flow in each of the last nineteen calendar years and will continue our emphasis in this area. We believe that the relative size and strength of our balance sheet and surety support as compared to most companies in our industry represent competitive advantages for us.

As discussed at greater length in “Results of Operations” below, we expect price competition to continue as our customers and local and regional competitors respond cautiously to improved market conditions. We will continue to invest in our service business, to pursue the more active sectors in our markets, and to emphasize our regional and national account business. Our primary emphasis for 2018 will be on execution and cost control, but we are seeking growth based on our belief that industry conditions will continue to be strong in the near term, and we believe that activity levels will permit us to continue to earn solid profits while preserving and developing our workforce. We continue to focus on project qualification, estimating, pricing and management; and we are investing in growth and improved performance.

Critical Accounting Policies

Our critical accounting policies are based upon the significance of the accounting policy to our overall financial statement presentation, as well as the complexity of the accounting policy and our use of estimates and subjective assessments. Our most critical accounting policy is revenue recognition. As discussed elsewhere in this annual report on Form 10‑K, our business has two service functions: (i) installation, which we account for under the percentage of completion method, and (ii) maintenance, repair and replacement, which we account for as the services are performed, or in the case of replacement, under the percentage of completion method. In addition, we identified other critical accounting policies related to our allowance for doubtful accounts receivable, the recording of our self‑insurance liabilities, valuation of deferred tax assets, accounting for acquisitions and the recoverability of goodwill and identifiable intangible assets. These accounting policies, as well as others, are described in Note 2 to the Consolidated Financial Statements included elsewhere in this annual report on Form 10‑K.

Percentage of Completion Method of Accounting

Approximately 81% of our revenue was earned on a project basis and recognized through the percentage of completion method of accounting during 2017. Under this method, contract revenue recognizable at any time during the

life of a contract is determined by multiplying expected total contract revenue by the percentage of contract costs incurred at any time to total estimated contract costs. More specifically, as part of the negotiation and bidding process in connection with obtaining installation contracts, we estimate our contract costs, which include all direct materials (exclusive of rebates), labor and subcontract costs and indirect costs related to contract performance, such as indirect labor, supplies, tools, repairs and depreciation costs. These contract costs are included in our results of operations under the caption “Cost of Services.” Then, as we perform under those contracts, we measure costs incurred, compare them to total estimated costs to complete the contract, and recognize a corresponding proportion of contract revenue. Labor costs are considered to be incurred as the work is performed. Subcontractor labor is recognized as the work is performed, but is generally subjected to approval as to milestones or other evidence of completion. Non‑labor project costs consist of purchased equipment, prefabricated materials and other materials. Purchased equipment on our projects is substantially produced to job specifications and is a value added element to our work. The costs are considered to be incurred when title is transferred to us, which typically is upon delivery to the worksite. Prefabricated materials, such as ductwork and piping, are generally performed at our shops and recognized as contract costs when fabricated for the unique specifications of the job. Other materials costs are not significant and are generally recorded when delivered to the worksite. This measurement and comparison process requires updates to the estimate of total costs to complete the contract, and these updates may include subjective assessments.

We generally do not incur significant costs prior to receiving a contract, and therefore, these costs are expensed as incurred. In limited circumstances, when significant pre‑contract costs are incurred, they are deferred if the costs can be directly associated with a specific contract and if their recoverability from the contract is probable. Upon receiving the contract, these costs are included in contract costs. Deferred costs associated with unsuccessful contract bids are written off in the period that we are informed that we will not be awarded the contract.

Project contracts typically provide for a schedule of billings or invoices to the customer based on reaching agreed upon milestones or as we incur costs. The schedules for such billings usually do not precisely match the schedule on which costs are incurred. As a result, contract revenue recognized in the statement of operations can and usually does differ from amounts that can be billed or invoiced to the customer at any point during the contract. Amounts by which cumulative contract revenue recognized on a contract as of a given date exceed cumulative billings to the customer under the contract are reflected as a current asset in our balance sheet under the caption “Costs and estimated earnings in excess of billings.” Amounts by which cumulative billings to the customer under a contract as of a given date exceed cumulative contract revenue recognized on the contract are reflected as a current liability in our balance sheet under the caption “Billings in excess of costs and estimated earnings.”

The percentage of completion method of accounting is also affected by changes in job performance, job conditions, and final contract settlements. These factors may result in revisions to estimated costs and, therefore, revenue. Such revisions are frequently based on further estimates and subjective assessments. The effects of these revisions are recognized in the period in which revisions are determined. When such revisions lead to a conclusion that a loss will be recognized on a contract, the full amount of the estimated ultimate loss is recognized in the period such conclusion is reached, regardless of the percentage of completion of the contract.

Revisions to project costs and conditions can give rise to change orders under which the customer agrees to pay additional contract price. Revisions can also result in claims we might make against the customer to recover project variances that have not been satisfactorily addressed through change orders with the customer. Except in certain circumstances, we do not recognize revenue or margin based on change orders or claims until they have been agreed upon with the customer. The amount of revenue associated with unapproved change orders and claims was immaterial for the year ended December 31, 2017.

Variations from estimated project costs could have a significant impact on our operating results, depending on project size, and the recoverability of the variation via additional customer payments.

Accounting for Allowance for Doubtful Accounts

We are required to estimate the collectability of accounts receivable and provide an allowance for doubtful accounts for receivable amounts we believe we will not ultimately collect. This requires us to make certain judgments and estimates involving, among others, the creditworthiness of our customers, prior collection history with our customers, ongoing relationships with our customers, the aging of past due balances, our lien rights, if any, in the property where we performed the work, and the availability, if any, of payment bonds applicable to the contract. These estimates are evaluated and adjusted as needed when additional information is received.

Accounting for Self‑Insurance Liabilities

We are substantially self‑insured for workers’ compensation, employer’s liability, auto liability, general liability and employee group health claims in view of the relatively high per‑incident deductibles we absorb under our insurance arrangements for these risks. Losses are estimated and accrued based upon known facts, historical trends and industry averages. Estimated losses in excess of our deductible, which have not already been paid, are included in our accrual with a corresponding receivable from our insurance carrier. Loss estimates associated with the larger and longer‑developing risks—workers’ compensation, auto liability and general liability—are reviewed by a third party actuary quarterly.

We believe these accruals are adequate. However, insurance liabilities are difficult to estimate due to unknown factors, including the severity of an injury, the determination of our liability in proportion to other parties, timely reporting of occurrences, ongoing treatment or loss mitigation, general trends in litigation recovery outcomes and the effectiveness of safety and risk management programs. Therefore, if actual experience differs from the assumptions and estimates used for recording the liabilities, adjustments may be required and would be recorded in the period that such experience becomes known.

Accounting for Deferred Tax Assets

We regularly evaluate valuation allowances established for deferred tax assets for which future realization is uncertain. We perform this evaluation quarterly. In assessing the realizability of deferred tax assets, we must consider whether it is more-likely-than-not some portion, or all, of the deferred tax assets will not be realized. We consider all available evidence, both positive and negative, in determining whether a valuation allowance is required. Such evidence includes the scheduled reversal of deferred tax liabilities, projected future taxable income, taxable income in prior carryback years and tax planning strategies in making this assessment, and judgment is required in considering the relative weight of negative and positive evidence.

Acquisitions

We recognize assets acquired and liabilities assumed in business combinations, including contingent assets and liabilities, based on fair value estimates as of the date of acquisition.

Contingent Consideration—In certain acquisitions, we agree to pay additional amounts to sellers contingent upon achievement by the acquired businesses of certain predetermined profitability targets. We have recognized liabilities for these contingent obligations based on their estimated fair value at the date of acquisition with any differences between the acquisition‑date fair value and the ultimate settlement of the obligations being recognized in income from operations.

Contingent Assets and Liabilities—Assets and liabilities arising from contingencies are recognized at their acquisition date fair value when their respective fair values can be determined. If the fair values of such contingencies cannot be determined, they are recognized at the acquisition date if the contingencies are probable and an amount can be reasonably estimated. Acquisition date fair value estimates are revised as necessary if, and when, additional information regarding these contingencies becomes available to further define and quantify assets acquired and liabilities assumed.

Recoverability of Goodwill and Identifiable Intangible Assets

Goodwill is the excess of purchase price over the fair value of the net assets of acquired businesses. We assess goodwill for impairment each year, and more frequently if circumstances suggest an impairment may have occurred.

When the carrying value of a given reporting unit exceeds its fair value, an impairment loss is recorded to the extent that the implied fair value of the goodwill of the reporting unit is less than its carrying value. If other reporting units have had increases in fair value, such increases may not be recorded. Accordingly, such increases may not be netted against impairments at other reporting units. The requirements for assessing whether goodwill has been impaired involve market‑based information. This information, and its use in assessing goodwill, entails some degree of subjective assessment.

We perform our annual impairment testing as of October 1 and any impairment charges resulting from this process are reported in the fourth quarter. We segregate our operations into reporting units based on the degree of operating and financial independence of each unit and our related management of them. We perform our annual goodwill impairment testing at the reporting unit level. Each of our operating units represents an operating segment, and our operating segments are our reporting units.

In the evaluation of goodwill for impairment, we have the option to first assess qualitative factors to determine whether the existence of events or circumstances lead to a determination that it is more likely than not that the fair value of one of our reporting units is greater than its carrying value. If, after completing such assessment, we determine it is more likely than not that the fair value of a reporting unit is greater than its carrying amount, then there is no need to perform any further testing. If we conclude otherwise, then we perform the first step of a two‑step impairment test by calculating the fair value of the reporting unit and comparing the fair value with the carrying value of the reporting unit.

We estimate the fair value of the reporting unit based on a market approach and an income approach, which utilizes discounted future cash flows. Assumptions critical to the fair value estimates under the discounted cash flow model include discount rates, cash flow projections, projected long‑term growth rates and the determination of terminal values. The market approach utilized market multiples of invested capital from comparable publicly traded companies (“public company approach”). The market multiples from invested capital include revenue, book equity plus debt and earnings before interest, provision for income taxes, depreciation and amortization (“EBITDA”).

There are significant inherent uncertainties and management judgment involved in estimating the fair value of each reporting unit. While we believe we have made reasonable estimates and assumptions to estimate the fair value of our reporting units, it is possible that a material change could occur. If actual results are not consistent with our current estimates and assumptions, or the current economic outlook worsens, goodwill impairment charges may be recorded in future periods.

We amortize identifiable intangible assets with finite lives over their useful lives. Changes in strategy and/or market condition, may result in adjustments to recorded intangible asset balances or their useful lives.

Results of Operations (in thousands):

2017 Compared to 2016

We had 35 operating locations as of December 31, 2016. During 2017, we completed one acquisition in the second quarter of 2017, known as “BCH”, that reports as a separate operating location in the Tampa, Florida area. Other than the addition of BCH, we did not make any changes to operating locations. As of December 31, 2017, we had 36 operating locations. Acquisitions are included in our results of operations from the respective acquisition date. The

same‑store comparison from 2017 to 2016, as described below, excludes nine months of results for BCH, which was acquired in April 2017 as well as the first month of 2017 for Shoffner, which was acquired in February 2016. An operating location is included in the same‑store comparison on the first day it has comparable prior year operating data.

Revenue—Revenue increased $153.6 million, or 9.4% to $1.79 billion in 2017 compared to 2016. The increase included a 6.4% increase related to the acquisitions of BCH and Shoffner and a 3.0% increase in revenue related to same‑store activity. The same‑store revenue increase was primarily due to one of our Virginia operations ($24.1 million) and our Wisconsin operation ($22.9 million), which experienced increased large project work compared to the prior year, specifically in the industrial sector.  

Backlog reflects revenue still to be recognized under contracted or committed installation and replacement project work. Project work generally lasts less than one year. Service agreement revenue and service work and short duration projects, which are generally billed as performed, do not flow through backlog. Accordingly, backlog represents only a portion of our revenue for any given future period, and it represents revenue that is likely to be reflected in our operating results over the next six to twelve months. As a result, we believe the predictive value of backlog information is limited to indications of general revenue direction over the near term, and should not be interpreted as indicative of ongoing revenue performance over several quarters.

Backlog as of December 31, 2017 was $948.4 million, a 5.2% increase from September 30, 2017 backlog of $901.2 million and a 24.2% increase from December 31, 2016 backlog of $763.4 million. Sequential backlog increased primarily due to increased project bookings at our North Carolina operation ($43.0 million). The year‑over‑year backlog increase included the acquisition of BCH ($30.0 million or 3.9%).  Same-store backlog increased 20.3% primarily due to increased project bookings at our North Carolina operation ($63.3 million), one of our Virginia operations ($39.0 million) and our Colorado operation ($37.3 million). 

Gross Profit—Gross profit increased $22.3 million, or 6.5%, to $366.3 million in 2017 as compared to 2016. The increase included a $18.3 million, or 5.3%, increase related to the acquisitions of BCH and Shoffner and a $4.0 million, or 1.2%, increase on a same‑store basis. The same‑store increase in gross profit was primarily due to increased volumes at our Wisconsin operation ($6.9 million) and our New Hampshire operation ($3.7 million).  This was partially offset by a decrease at our North Carolina operation ($6.4 million), which has experienced lower project activity when compared to the same period in 2016. As a percentage of revenue, gross profit decreased from 21.0% in 2016 to 20.5% in 2017 primarily due to a $3.6 million increase in amortization expense, primarily related to the BCH acquisition, as well as the factors discussed above.

Selling, General and Administrative Expenses (“SG&A”)—SG&A increased $23.4 million, or 9.6%, to $266.6 million for 2017 as compared to 2016. On a same‑store basis, excluding amortization expense, SG&A increased $7.3 million, or 3.1%. This increase is primarily due to $0.8 million in compensation costs related to leadership changes and the increase in same-store revenue.  Additionally, we incurred $0.4 million in expenses in the first quarter of 2017 related to the acquisition of BCH completed on April 1, 2017. Amortization expense increased $5.6 million during the period primarily as a result of the BCH acquisition. As a percentage of revenue, SG&A was 14.9% in both 2017 and 2016.

We have included same‑store SG&A, excluding amortization, because we believe it is an effective measure of comparative results of operations. However, same‑store SG&A, excluding amortization, is not considered under

generally accepted accounting principles to be a primary measure of an entity’s financial results, and accordingly, should not be considered an alternative to SG&A as shown in our consolidated statements of operations.

Interest Expense—Interest expense increased $0.8 million, or 34.6%, in 2017. The increase reflects the increased borrowings on the revolving credit facility as well as notes to former owners used to fund the BCH acquisition during the second quarter of 2017.

Changes in the Fair Value of Contingent Earn‑out Obligations—The contingent earn‑out obligations are measured at fair value each reporting period and changes in estimates of fair value are recognized in earnings. Income from changes in the fair value of contingent earn‑out obligations increased $3.0 million in 2017 compared to 2016. This increase was the result of reducing our obligation related to the BCH acquisition primarily due to results being below the initial estimate as a result of the impact of Hurricane Irma and less project activity than previously estimated. In 2016, based on updated measurements of estimated future cash flows for our contingent obligations, we reduced our obligation related to the EAS acquisition resulting in a gain of $0.8 million.

Other Income—Other income remained relatively flat in 2017 compared to 2016. In the fourth quarter of 2017, we entered into settlement agreements with British Petroleum (“BP”) related to two claims from one of our subsidiaries regarding the April 2010 BP Deepwater Horizon oil spill. We recorded a $1.0 million gain in the fourth quarter of 2017 in “Other Income” as a result of these settlements. Additionally, in the fourth quarter of 2016, we entered into a separate settlement agreement with BP related to a claim from another one of our subsidiaries and recorded a $0.6 million gain in the fourth quarter of 2016 in “Other Income”. While we still have other subsidiaries with outstanding claims against BP related to this matter, we cannot predict when or if we will receive any further settlement compensation as a result of these outstanding claims.

Provision for Income Taxes—We conduct business throughout the United States in virtually all fifty states. Our effective tax rate changes based upon our relative profitability, or lack thereof, in states with varying tax rates and rules. In addition, discrete items, such as tax law changes, judgments and legal structures can impact our effective tax rate. These items can also include the tax treatment for impairment of goodwill and other intangible assets, changes in fair value of acquisition-related assets and liabilities, tax reserves for uncertain tax positions, accounting for losses associated with underperforming operations and noncontrolling interests.

Our effective tax rate for 2017 was 45.2%, as compared to 35.8% in 2016. The effective rate for 2017 was higher than the 35% federal statutory rate primarily due to the remeasurement of net deferred tax assets for the corporate tax rate reduction to 21% (9.4%), net state income taxes (2.8%) partially offset by the domestic production activities deduction (2.1%) and deductions for stock-based compensation (1.3%). The effective rate for 2016 was higher than the 35% federal statutory rate primarily due to net state income taxes (4.2%) partially offset by the domestic production activities deduction (2.0%) and a decrease in valuation allowances (1.2%). Refer to Note 9 in the Consolidated Financial Statements for a reconciliation of the federal statutory rate to the effective tax rate reflected in our financial statements.

The increase in the effective tax rate from 2016 to 2017 was primarily due to the impact from the remeasurement of net deferred tax assets for the corporate tax rate reduction to 21% pursuant to the recently enacted Tax Cuts and Jobs Act. While we believe we were able to make reasonable estimates of the impact of the Tax Cuts and Jobs Act in these financial statements, the amounts recorded are provisional and the final impact may differ from these estimates due to, among other things, changes in our interpretations and assumptions and additional guidance that may be issued by regulatory authorities.

We currently estimate our effective tax rate for 2018 will be between 22% and 27%. This includes the impact of a decrease in unrecognized tax benefits of up to $8.7 million that is expected within the next twelve months due to the

filing of a federal income tax automatic accounting method change application. Approximately $3.0 million of the decrease is expected to impact our effective tax rate. Starting in 2019, we currently estimate our effective tax rate will be between 25% and 30%. We expect our future tax rates to be lower than 2017 primarily due to the corporate tax rate reduction to 21% effective January 1, 2018. These estimates also reflect the repeal of the domestic production activities deduction and other items of the Tax Cuts and Jobs Act that partially offset the benefit from the reduction in the corporate tax rate.

2016 Compared to 2015

We had 35 operating locations as of December 31, 2015. During 2016, we completed one acquisition in the first quarter of 2016, known as “Shoffner”, that reports as a separate operating location in the Knoxville, Tennessee area. In addition, we merged four operating locations into two operating locations during the first quarter, and created two operating locations out of one existing operating location. As of December 31, 2016, we had 35 operating locations. Acquisitions are included in our results of operations from the respective acquisition date. The same‑store comparison from 2016 to 2015, as described below, excludes eleven months of results for Shoffner, which was acquired in February 2016. An operating location is included in the same‑store comparison on the first day it has comparable prior year operating data. An operating location is excluded from the same‑store comparison in the current year and comparable prior years when it is properly characterized as a discontinued operation under applicable accounting standards.

Revenue—Revenue increased $53.8 million, or 3.4% to $1,634.3 million in 2016 compared to 2015. The increase included a 4.6% increase related to the acquisition of Shoffner, which was partially offset by a 1.1% decrease in revenue related to same‑store activity. The same‑store revenue decrease was primarily due to our Environmental Air Systems, LLC (“EAS”) operation ($48.0 million), which experienced decreased large project work compared to the prior year, specifically in the manufacturing sector.  This decrease was partially offset by increased activity at our Michigan operation ($16.8 million) and our Northern Texas operation ($13.1 million).

Backlog reflects revenue still to be recognized under contracted or committed installation and replacement project work. Project work generally lasts less than one year. Service agreement revenue and service work and short duration projects, which are generally billed as performed, do not flow through backlog. Accordingly, backlog represents only a portion of our revenue for any given future period, and it represents revenue that is likely to be reflected in our operating results over the next six to twelve months. As a result, we believe the predictive value of backlog information is limited to indications of general revenue direction over the near term, and should not be interpreted as indicative of ongoing revenue performance over several quarters.

Backlog as of December 31, 2016 was $763.4 million, a 6.1% increase from September 30, 2016 backlog of $719.3 million and a 7.3% increase from December 31, 2015 backlog of $711.6 million. Sequential backlog increased primarily due to increased project bookings at our Colorado operation ($15.9 million), our New Hampshire operation ($13.3 million) and one of our Florida operations ($12.9 million). The year‑over‑year backlog increase was primarily due to the acquisition of Shoffner ($35.3 million or 5.0%).  Same-store backlog increased 2.3% primarily due to increased project bookings at our New Hampshire operation ($28.1 million).  This was partially offset by the completion of project work at our EAS operation ($21.0 million).

Gross Profit—Gross profit increased $25.9 million, or 8.1%, to $344.0 million in 2016 as compared to 2015. The increase included a $13.3 million, or 4.2%, increase related to the acquisition of Shoffner and a $12.6 million, or 3.9%, increase on a same‑store basis. The same‑store increase in gross profit was primarily due to broad based improvement in project execution, including our California operation ($4.0 million) and one of our New York operations ($3.5 million).  Additionally, gross profit was higher due to increased volumes at our Michigan operation ($3.9 million) and one of our Alabama operations ($3.3 million).  This was partially offset by a decrease at our EAS operation ($8.6 million), which has experienced a decrease in large project work when compared to the same period in 2015. As a percentage of revenue, gross profit increased from 20.1% in 2015 to 21.0% in 2016 primarily due to the factors discussed above.

Selling, General and Administrative Expenses (“SG&A”)—SG&A increased $14.2 million, or 6.2%, to $243.2 million for 2016 as compared to 2015. On a same‑store basis, excluding amortization expense, SG&A increased $4.2 million, or 1.9%. This increase was primarily due to increased compensation costs ($4.8 million), which are primarily related to an increase in operating results and expanded service activities at multiple locations.  This was offset by a decrease in bad debt expense ($1.6 million) primarily due to collections of aged receivables. Amortization expense

decreased $0.7 million during 2016 compared to the prior year. As a percentage of revenue, SG&A increased from 14.5% in 2015 to 14.9% in 2016, primarily due to the factors discussed above.

We have included same‑store SG&A, excluding amortization, because we believe it is an effective measure of comparative results of operations. However, same‑store SG&A, excluding amortization, is not considered under generally accepted accounting principles to be a primary measure of an entity’s financial results, and accordingly, should not be considered an alternative to SG&A as shown in our consolidated statements of operations.

Interest Expense—Interest expense increased $0.6 million, or 33.8%, in 2016. The increase is due to higher average net borrowings on the revolving credit facility in 2016 compared to 2015.

Changes in the Fair Value of Contingent Earn‑out Obligations—The contingent earn‑out obligations are measured at fair value each reporting period and changes in estimates of fair value are recognized in earnings. Income from changes in the fair value of contingent earn‑out obligations increased $0.5 million in 2016 compared to 2015. Based on updated measurements of estimated future cash flows for our contingent obligations, we reduced our obligation related to the EAS acquisition resulting in a gain of $0.8 million.  This was partially offset by increases in the fair value of contingent earn-out obligations related to various acquisitions during 2016.

Other Income—Other income increased $1.0 million in 2016 compared to 2015. In the fourth quarter of 2016, we entered into a settlement agreement with British Petroleum (“BP”) related to a claim from one of our subsidiaries regarding the April 2010 BP Deepwater Horizon oil spill. We recorded a $0.6 million gain in the fourth quarter of 2016 in “Other Income” as a result of this settlement.

Provision for Income Taxes—We conduct business throughout the United States in virtually all fifty states. Our effective tax rate changes based upon our relative profitability, or lack thereof, in states with varying tax rates and rules. In addition, discrete items, such as tax law changes, judgments and legal structures can impact our effective tax rate. These items can also include the tax treatment for impairment of goodwill and other intangible assets, changes in fair value of acquisition-related assets and liabilities, tax reserves for uncertain tax positions, accounting for losses associated with underperforming operations and noncontrolling interests.

Our effective tax rate for 2016 was 35.8%, as compared to 35.2% in 2015. The effective rate for 2016 was higher than the 35% federal statutory rate primarily due to net state income taxes (4.2%) partially offset by the domestic production activities deduction (2.0%) and a decrease in valuation allowances (1.2%). The effective rate for 2015 was slightly higher than the 35% federal statutory rate primarily due to an increase in net state income taxes (3.9%) which was partially offset by a decrease from the impact of the noncontrolling interest of EAS which for federal tax purposes is treated as a partnership (3.2%). Refer to Note 9 in the Consolidated Financial Statements for a reconciliation of the federal statutory rate to the effective tax rate reflected in our financial statements. The increase in the effective tax rate from 2015 to 2016 was primarily due to the impact of our noncontrolling interests, which was partially offset by the impact on the rate from the benefits from deductions on stock-based compensation, valuation allowances and net state income taxes.

Net Income Attributable to Noncontrolling Interests— There was no net income attributable to noncontrolling interests for 2016 due to our January 1, 2016 purchase of the remaining 40% noncontrolling interest in Environmental Air Systems, LLC. 

Outlook

Industry conditions improved during the three-year period from 2015 to 2017 and we currently expect that activity will continue at these improved levels during 2018. Our emphasis for 2018 will be on cost discipline and efficient project performance, labor force development, and investing in growth, particularly in service and small projects. Based on our backlog, and in light of economic conditions, we currently expect improvement in our revenue and net earnings in 2018.

Liquidity and Capital Resources

Cash Flow

Our business does not require significant amounts of investment in long‑term fixed assets. The substantial majority of the capital used in our business is working capital that funds our costs of labor and installed equipment deployed in project work until our customer pays us. Customary terms in our industry allow customers to withhold a small portion of the contract price until after we have completed the work, typically for six months. Amounts withheld under this practice are known as retention or retainage. Our average project duration together with typical retention terms generally allow us to complete the realization of revenue and earnings in cash within one year.

2017 Compared to 2016

Cash Provided by Operating Activities—Cash flow from operations is primarily influenced by demand for our services and operating margins, but can also be influenced by working capital needs associated with the various types of services that we provide. In particular, working capital needs may increase when we commence large volumes of work under circumstances where project costs, primarily associated with labor, equipment and subcontractors, are required to be paid before the receivables resulting from the work performed are billed and collected. Working capital needs are generally higher during the late winter and spring months as we prepare and plan for the increased project demand when favorable weather conditions exist in the summer and fall months. Conversely, working capital assets are typically converted to cash during the late summer and fall months as project completion is underway. These seasonal trends are sometimes offset by changes in the timing of major projects, which can be impacted by the weather, project delays or accelerations and other economic factors that may affect customer spending.

We generated $114.1 million of cash flow from operating activities during 2017 compared with $91.2 million during 2016. The $22.9 million increase is primarily due to the $22.3 million increase in gross profit, increases in billings in excess of costs of $21.6 million, primarily due to the timing of billings and various project work, and increases in accounts payable and accrued liabilities of $19.3 million due to increased activity and revenue as well as increased compensation accruals. These increases to operating cash flow were partially offset by the change in receivables of $44.8 million primarily related to the timing of customer billings and payments.

Cash Used in Investing Activities—Cash used in investing activities was $129.0 million for 2017 compared to $79.3 million during 2016. The $49.7 million increase in cash used primarily relates to cash paid (net of cash acquired)

for the BCH acquisition in 2017 of $86.1 million compared to the EAS and Shoffner acquisitions in 2016 ($56.3 million).

Cash Provided by (Used in) Financing Activities—Cash provided by financing activities was $19.3 million for 2017 compared to cash used in financing activities of $36.3 million during 2016. The $55.6 million increase in cash provided by financing activities primarily relates to $55.0 million of additional net proceeds from the revolving line of credit in 2017 compared to the prior year.

2016 Compared to 2015

Cash Provided by Operating Activities—We generated $91.2 million of cash flow from operating activities during 2016 compared with $97.9 million during 2015. The $6.7 million decrease is primarily due to decreases in billings in excess of costs of $16.3 million, primarily due to the timing of billings and various project work, and increases in prepaid expenses and other current assets of $9.2 million, primarily due to increases of insurance receivables. These uses of operating cash flow were partially offset by the change in receivables of $10.6 million primarily related to the timing of customer billings and payments and overall higher net income in 2016 compared to 2015.

Cash Used in Investing Activities—Cash used in investing activities was $79.3 million for 2016 compared to $25.6 million during 2015. The $53.7 million increase in cash used primarily relates to cash paid for the EAS and Shoffner acquisitions that were completed in 2016.

Cash Used in Financing Activities—Cash used in financing activities was $36.3 million for 2016 compared to $47.8 million during 2015. The $11.6 million decrease in cash used in financing activities primarily relates to $18.5 million less in net payments on the revolving line of credit in 2016. Additionally, we repurchased $4.8 million of incremental shares in 2016 and did not have distributions to noncontrolling interests after we acquired the remaining 40% noncontrolling interest in EAS.

Free Cash Flow

We define free cash flow as cash provided by operating activities, less customary capital expenditures, plus the proceeds from asset sales and taxes paid related to pre‑acquisition equity transactions of an acquired company. We believe free cash flow, by encompassing both profit margins and the use of working capital over our approximately one year working capital cycle, is an effective measure of operating effectiveness and efficiency. We have included free cash flow information here for this reason, and because we are often asked about it by third parties evaluating us. However, free cash flow is not considered under generally accepted accounting principles to be a primary measure of an entity’s financial results, and accordingly free cash flow should not be considered an alternative to operating income, net income, or amounts shown in our consolidated statements of cash flows as determined under generally accepted accounting principles. Free cash flow may be defined differently by other companies.

Share Repurchase Program

On March 29, 2007, our Board of Directors (the “Board”) approved a stock repurchase program to acquire up to 1.0 million shares of our outstanding common stock. Subsequently, the Board has from time to time increased the number of shares that may be acquired under the program and approved extensions of the program. Since the inception of the repurchase program, the Board has approved 8.1 million shares to be repurchased. As of December 31, 2017, we have repurchased a cumulative total of 7.6 million shares at an average price of $13.75 per share under the repurchase program.

The share repurchases will be made from time to time at our discretion in the open market or privately negotiated transactions as permitted by securities laws and other legal requirements, and subject to market conditions and other factors. The Board may modify, suspend, extend or terminate the program at any time. During the twelve months ended December 31, 2017, we repurchased 0.3 million shares for approximately $9.0 million at an average price of $34.23 per share.

Debt

Revolving Credit Facility

We have a $325.0 million senior credit facility (the “Facility”) provided by a syndicate of banks, with a $100 million accordion option. The Facility, which is available for borrowings and letters of credit, expires in February 2021 and is secured by a first lien on substantially all of our personal property except for assets related to projects subject to surety bonds and assets held by certain unrestricted subsidiaries and a second lien on our assets related to projects subject to surety bonds. As of December 31, 2017, we had $45.0 million of outstanding borrowings, $39.6 million in letters of credit outstanding and $240.4 million of credit available.

There are two interest rate options for borrowings under the Facility, the Base Rate Loan option and the Eurodollar Rate Loan option. These rates are floating rates determined by the broad financial markets, meaning they can and do move up and down from time to time. Additional margins are then added to these two rates. The weighted average interest rate applicable to the borrowings under the Facility was approximately 2.8% as of December 31, 2017.

Certain of our vendors require letters of credit to ensure reimbursement for amounts they are disbursing on our behalf, such as to beneficiaries under our self‑funded insurance programs. We have also occasionally used letters of credit to guarantee performance under our contracts and to ensure payment to our subcontractors and vendors under those contracts. Our lenders issue such letters of credit through the Facility for a fee. We have never had a claim made against a letter of credit that resulted in payments by a lender or by us and believe such claims are unlikely in the foreseeable future. The letter of credit fees range from 1.25% to 2.00% per annum, based on the ratio of Consolidated Total Indebtedness to Credit Facility Adjusted EBITDA, as defined in the credit agreement.

Commitment fees are payable on the portion of the revolving loan capacity not in use for borrowings or letters of credit at any given time. These fees range from 0.20%‑0.35% per annum, based on the ratio of Consolidated Total Indebtedness to Credit Facility Adjusted EBITDA, as defined in the credit agreement.

Interest expense included the following primary elements (in thousands):

The Facility contains financial covenants defining various measures and the levels of these measures with which we must comply. Covenant compliance is assessed as of each quarter end. Credit Facility Adjusted EBITDA is defined under the Facility for financial covenant purposes as net earnings for the four quarters ending as of any given quarterly covenant compliance measurement date, plus the corresponding amounts for (a) interest expense; (b) provision for income taxes; (c) depreciation and amortization; (d) stock compensation; (e) other non‑cash charges; and (f) pre‑acquisition results of acquired companies. The following is a reconciliation of Credit Facility Adjusted EBITDA to net income for 2017 (in thousands):

The Facility’s principal financial covenants include:

Leverage Ratio—The Facility requires that the ratio of our Consolidated Total Indebtedness to our Credit Facility Adjusted EBITDA not exceed 2.75 to 1.00 as of the end of each fiscal quarter. The leverage ratio as of December 31, 2017 was 0.4.

Fixed Charge Coverage Ratio— The Facility requires that the ratio of (a) Credit Facility Adjusted EBITDA, less non‑financed capital expenditures, provision for income taxes, dividends and amounts used to repurchase stock to (b) the sum of interest expense and scheduled principal payments of indebtedness be at least 2.00 to 1.00; provided that the calculation of the fixed charge coverage ratio excludes stock repurchases and the payment of dividends at any time that the Company’s Net Leverage Ratio does not exceed 1.50 to 1.00. The Facility also allows the fixed charge coverage ratio not to be reduced for stock repurchases through September 30, 2015 in an aggregate amount not to exceed $25 million and for stock repurchases made after February 22, 2016 but on or prior to December 31, 2017 in an aggregate amount not to exceed $25 million, if at the time of and after giving effect to such repurchase the Company’s Net Leverage Ratio was less than or equal to 1.50 to 1.00. Capital expenditures, provision for income taxes, dividends and stock repurchase payments are defined under the Facility for purposes of this covenant to be amounts for the four quarters ending as of any given quarterly covenant compliance measurement date. The fixed charge coverage ratio as of December 31, 2017 was 21.8.

Other Restrictions— The Facility permits acquisitions of up to $30.0 million per transaction, provided that the aggregate purchase price of all such acquisitions in the same fiscal year does not exceed $65.0 million. However, these limitations only apply when the Company’s Total Leverage Ratio is greater than 2.00 to 1.00.

While the Facility’s financial covenants do not specifically govern capacity under the Facility, if our debt level under the Facility at a quarter‑end covenant compliance measurement date were to cause us to violate the Facility’s leverage ratio covenant, our borrowing capacity under the Facility and the favorable terms that we currently have could be negatively impacted by the lenders.

We were in compliance with all of our financial covenants as of December 31, 2017.

Notes to Former Owners

As part of the consideration used to acquire two companies, we have outstanding notes to the former owners. These notes had an outstanding balance of $15.3 million as of December 31, 2017. In conjunction with the BCH acquisition in the second quarter of 2017, we issued a promissory note to the former owners with an outstanding balance of $14.3 million as of December 31, 2017 that bears interest, payable quarterly, at a weighted average interest rate of 3.0%. The principal is due in equal installments in April 2020 and 2021. In conjunction with the Shoffner acquisition in the first quarter of 2016, we issued a subordinated note to former owners with an outstanding balance of $1.0 million as of December 31, 2017 that bears interest, payable quarterly, at a weighted average interest rate of 3.0%. The principal is due in equal installments in February 2018 and 2019.

Other Debt

As part of the Shoffner acquisition, we acquired debt with an outstanding balance at the acquisition date of $0.4 million with principal and interest due the last day of every month; ending on the December 30, 2019 maturity date. The interest rate is the one month LIBOR rate plus 2.25%. As of December 31, 2017, $0.2 million of the note was outstanding, of which $0.1 million was considered current.

Outlook

We have generated positive net free cash flow for the last nineteen calendar years, much of which occurred during challenging economic and industry conditions. We also continue to have significant borrowing capacity under our credit facility, and we maintain what we feel are reasonable cash balances. We believe these factors will provide us with sufficient liquidity to fund our operations for the foreseeable future.

Off‑Balance Sheet Arrangements and Other Commitments

As is common in our industry, we have entered into certain off‑balance sheet arrangements in the ordinary course of business that result in risks not directly reflected in our balance sheets. Our most significant off‑balance sheet

transactions include liabilities associated with noncancelable operating leases. We also have other off‑balance sheet obligations involving letters of credit and surety guarantees.

We enter into noncancelable operating leases for many of our facility, vehicle and equipment needs. These leases allow us to conserve cash by paying a monthly lease rental fee for use of facilities, vehicles and equipment rather than purchasing them. At the end of the lease, we have no further obligation to the lessor. If we decide to cancel or terminate a lease before the end of its term, we would typically owe the lessor the remaining lease payments under the term of the lease.

Certain of our vendors require letters of credit to ensure reimbursement for amounts they are disbursing on our behalf, such as to beneficiaries under our self‑funded insurance programs. We have also occasionally used letters of credit to guarantee performance under our contracts and to ensure payment to our subcontractors and vendors under those contracts. The letters of credit we provide are actually issued by our lenders through the Facility as described above. A letter of credit commits the lenders to pay specified amounts to the holder of the letter of credit if the holder demonstrates that we have failed to perform specified actions. If this were to occur, we would be required to reimburse the lenders. Depending on the circumstances of such a reimbursement, we may also have to record a charge to earnings for the reimbursement. Absent a claim, there is no payment or reserving of funds by us in connection with a letter of credit. However, because a claim on a letter of credit would require immediate reimbursement by us to our lenders, letters of credit are treated as a use of the Facility’s capacity just the same as actual borrowings. Claims against letters of credit are rare in our industry. To date we have not had a claim made against a letter of credit that resulted in payments by a lender or by us. We believe that it is unlikely that we will have to fund claims under a letter of credit in the foreseeable future.

Many customers, particularly in connection with new construction, require us to post performance and payment bonds issued by a financial institution known as a surety. If we fail to perform under the terms of a contract or to pay subcontractors and vendors who provided goods or services under a contract, the customer may demand that the surety make payments or provide services under the bond. We must reimburse the sureties for any expenses or outlays they incur. To date, we are not aware of any losses to our sureties in connection with bonds the sureties have posted on our behalf, and we do not expect such losses to be incurred in the foreseeable future.

Under standard terms in the surety market, sureties issue bonds on a project‑by‑project basis and can decline to issue bonds at any time. Historically, approximately 20% to 30% of our business has required bonds. While we currently have strong surety relationships to support our bonding needs, future market conditions or changes in our sureties’ assessment of our operating and financial risk could cause our sureties to decline to issue bonds for our work. If that were to occur, our alternatives include doing more business that does not require bonds, posting other forms of collateral for project performance such as letters of credit or cash, and seeking bonding capacity from other sureties. We would likely also encounter concerns from customers, suppliers and other market participants as to our creditworthiness. While we believe our general operating and financial characteristics would enable us to ultimately respond effectively to an interruption in the availability of bonding capacity, such an interruption would likely cause our revenue and profits to decline in the near term.

Contractual Obligations

The following recaps the future maturities of our contractual obligations as of December 31, 2017 (in thousands):