Attached files

file filename
EX-31.2 - EXHIBIT 31.2 - KBR, INC.kbr-ex312x20150930.htm
EX-32.1 - EXHIBIT 32.1 - KBR, INC.kbr-ex321x20150930.htm
EX-10.2 - EXHIBIT 10.2 - KBR, INC.kbr-ex102x20150930.htm
EX-31.1 - EXHIBIT 31.1 - KBR, INC.kbr-ex311x20150930.htm
EX-32.2 - EXHIBIT 32.2 - KBR, INC.kbr-ex322x20150930.htm


 
UNITED STATES
SECURITIES AND EXCHANGE COMMISSION
Washington, D.C. 20549
 
 
FORM 10-Q
ý
Quarterly Report Pursuant to Section 13 or 15(d) of the Securities Exchange Act of 1934
For the quarterly period ended September 30, 2015
OR
¨
Transition Report Pursuant to Section 13 or 15(d) of the Securities Exchange Act of 1934 for the transition period from             to
Commission File Number: 1-33146
 
 
 
KBR, Inc.
(Exact name of registrant as specified in its charter)
Delaware
 
20-4536774
(State of incorporation)
 
(I.R.S. Employer Identification No.)
 
 
 
601 Jefferson Street, Suite 3400, Houston, Texas
 
77002
(Address of principal executive offices)
 
(Zip Code)

(713) 753-3011
(Registrant's telephone number including area code)

 

 
Indicate by check mark whether the registrant (1) has filed all reports required to be filed by Section 13 or 15(d) of the Securities Exchange Act of 1934 during the preceding 12 months (or for such shorter period that the registrant was required to file such reports), and (2) has been subject to such filing requirements for the past 90 days.     Yes  ý    No  ¨

Indicate by check mark whether the registrant has submitted electronically and posted on its corporate Web site, if any, every Interactive Data File required to be submitted and posted pursuant to Rule 405 of Regulation S-T (§232.405 of this chapter) during the preceding 12 months (or for such shorter period that the registrant was required to submit and post such files).     Yes  ý    No  ¨

Indicate by check mark whether the registrant is a large accelerated filer, an accelerated filer, a non-accelerated filer, or a smaller reporting company. See the definitions of “large accelerated filer,” “accelerated filer” and “smaller reporting company” in Rule 12b-2 of the Exchange Act.
Large accelerated filer
 
ý
Accelerated filer
 
¨
Non-accelerated filer
 
¨ (Do not check if a smaller reporting company)
Smaller reporting company
 
¨

Indicate by check mark whether the registrant is a shell company (as defined in Rule 12b-2 of the Exchange Act).     Yes  ¨    No  ý

As of October 14, 2015, there were 144,262,730 shares of KBR, Inc. Common Stock, par value $0.001 per share, outstanding.

 




TABLE OF CONTENTS
 



2



Forward-Looking and Cautionary Statements

This report contains certain statements that are, or may be deemed to be, “forward-looking statements” within the meaning of Section 27A of the Securities Act of 1933, as amended, and Section 21E of the Securities Exchange Act of 1934, as amended. The Private Securities Litigation Reform Act of 1995 provides safe harbor provisions for forward-looking information. Some of the statements contained in this quarterly report are forward-looking statements. All statements other than statements of historical fact are, or may be deemed to be, forward-looking statements. The words “believe,” “may,” “estimate,” “continue,” “anticipate,” “intend,” “plan,” “expect” and similar expressions are intended to identify forward-looking statements. Forward-looking statements include information concerning our possible or assumed future financial performance and results of operations.

We have based these statements on our assumptions and analyses in light of our experience and perception of historical trends, current conditions, expected future developments and other factors we believe are appropriate in the circumstances. Forward-looking statements by their nature involve substantial risks and uncertainties that could significantly affect expected results, and actual future results could differ materially from those described in such statements. While it is not possible to identify all factors, factors that could cause actual future results to differ materially include the risks and uncertainties disclosed in our 2014 Annual Report on Form 10-K contained in Part I under “Risk Factors.”

Many of these factors are beyond our ability to control or predict. Any of these factors, or a combination of these factors, could materially and adversely affect our future financial condition or results of operations and the ultimate accuracy of the forward-looking statements. These forward-looking statements are not guarantees of our future performance, and our actual results and future developments may differ materially and adversely from those projected in the forward-looking statements. We caution against putting undue reliance on forward-looking statements or projecting any future results based on such statements or on present or prior earnings levels. In addition, each forward-looking statement speaks only as of the date of the particular statement, and we undertake no obligation to publicly update or revise any forward-looking statement.


3



PART I. FINANCIAL INFORMATION

Item 1. Financial Information

KBR, Inc.
Condensed Consolidated Statements of Operations
(In millions, except for per share data)
(Unaudited)
 
Three Months Ended
 
Nine Months Ended
 
September 30,
 
September 30,
 
2015
 
2014
 
2015
 
2014
Revenues
$
1,199

 
$
1,657

 
$
4,016

 
$
4,949

Cost of revenues
(1,112
)
 
(1,627
)
 
(3,785
)
 
(4,852
)
Gross profit
87

 
30

 
231

 
97

Equity in earnings of unconsolidated affiliates
35

 
38

 
123

 
118

General and administrative expenses
(38
)
 
(58
)
 
(119
)
 
(178
)
Asset impairment and restructuring charges
(15
)
 

 
(34
)
 

Gain on disposition of assets
6

 

 
34

 
8

Operating income
75

 
10

 
235

 
45

Other non-operating income
3

 
34

 
4

 
18

Income before income taxes and noncontrolling interests
78

 
44

 
239

 
63

Benefit (provision) for income taxes
(19
)
 
1

 
(61
)
 
(30
)
Net income
59

 
45

 
178

 
33

Net income attributable to noncontrolling interests
(4
)
 
(15
)
 
(17
)
 
(54
)
Net income (loss) attributable to KBR
$
55

 
$
30

 
$
161

 
$
(21
)
Net income (loss) attributable to KBR per share:
 
 
 
 
 
 
 
Basic
$
0.38

 
$
0.21

 
$
1.11

 
$
(0.14
)
Diluted
$
0.38

 
$
0.21

 
$
1.11

 
$
(0.14
)
Basic weighted average common shares outstanding
144

 
145

 
144

 
145

Diluted weighted average common shares outstanding
144

 
145

 
144

 
145

Cash dividends declared per share
$
0.08

 
$
0.08

 
$
0.24

 
$
0.24

See accompanying notes to condensed consolidated financial statements.

4



KBR, Inc.
Condensed Consolidated Statements of Comprehensive Income (Loss)
(In millions)
(Unaudited)

 
Three Months Ended
 
Nine Months Ended
 
September 30,
 
September 30,
 
2015
 
2014
 
2015
 
2014
Net income
$
59

 
$
45

 
$
178

 
$
33

Other comprehensive income (loss), net of tax:
 
 
 
 
 
 
 
Foreign currency translation adjustments:
 
 
 
 
 
 
 
Foreign currency translation adjustments, net of tax
(13
)
 
(49
)
 
(74
)
 
(27
)
Reclassification adjustment included in net income

 

 

 
1

Foreign currency translation adjustments, net of taxes of $6, $(6), $5 and $(1)
(13
)
 
(49
)
 
(74
)
 
(26
)
Pension and post-retirement benefits, net of tax:
 
 
 
 
 
 
 
Actuarial losses, net of tax

 

 

 

Reclassification adjustment included in net income
10

 
8

 
32

 
25

Pension and post-retirement benefits, net of taxes of $2, $3, $5 and $7
10

 
8

 
32

 
25

Changes in fair value of derivatives:
 
 
 
 
 
 
 
Changes in fair value of derivatives, net of tax

 

 

 
(1
)
Reclassification adjustment included in net income
1

 
(1
)
 
1

 
(1
)
Changes in fair value of derivatives, net of taxes of $0, $0, $0 and $0
1

 
(1
)
 
1

 
(2
)
Other comprehensive income (loss), net of tax
(2
)
 
(42
)
 
(41
)
 
(3
)
Comprehensive income
57

 
3

 
137

 
30

Less: Comprehensive income attributable to noncontrolling interests
(6
)
 
(16
)
 
(20
)
 
(55
)
Comprehensive income (loss) attributable to KBR
$
51

 
$
(13
)
 
$
117

 
$
(25
)
See accompanying notes to condensed consolidated financial statements.


5



KBR, Inc.
Condensed Consolidated Balance Sheets
(In millions, except share data)
 
September 30,
 
December 31,
 
2015
 
2014
 
(Unaudited)
 
 
Assets
 
 
 
Current assets:
 
 
 
Cash and equivalents
$
768

 
$
970

Accounts receivable, net of allowance for doubtful accounts of $20 and $19
699

 
847

Costs and estimated earnings in excess of billings on uncompleted contracts ("CIE")
284

 
490

Deferred income taxes
68

 
90

Other current assets
143

 
147

Total current assets
1,962

 
2,544

Property, plant, and equipment, net of accumulated depreciation of $340 and $385 (including net PPE of $51 and $57 owned by a variable interest entity)
198

 
247

Goodwill
324

 
324

Intangible assets, net of accumulated amortization of $90 and $96
38

 
41

Equity in and advances to unconsolidated affiliates
261

 
151

Deferred income taxes
176

 
174

Claims and accounts receivable
549

 
570

Other assets
143

 
148

Total assets
$
3,651

 
$
4,199

Liabilities and Shareholders’ Equity
 
 
 
Current liabilities:
 
 
 
Accounts payable
$
485

 
$
742

Payable to former parent
19

 
56

Billings in excess of costs and estimated earnings on uncompleted contracts ("BIE")
500

 
531

Accrued salaries, wages and benefits
176

 
197

Nonrecourse project debt
10

 
10

Other current liabilities
326

 
488

Total current liabilities
1,516

 
2,024

Pension obligations
444

 
502

Employee compensation and benefits
110

 
112

Income tax payable
72

 
69

Deferred income taxes
175

 
170

Nonrecourse project debt
56

 
63

Deferred income from unconsolidated affiliates
103

 
95

Other liabilities
201

 
229

Total liabilities
2,677

 
3,264

KBR shareholders’ equity:
 
 
 
Preferred stock, $0.001 par value, 50,000,000 shares authorized, 0 shares issued and outstanding

 

Common stock, $0.001 par value, 300,000,000 shares authorized, 175,044,525 and 174,448,399 shares issued, and 144,260,718 and 144,837,281 shares outstanding

 

Paid-in capital in excess of par ("PIC")
2,066

 
2,091

Accumulated other comprehensive loss ("AOCL")
(920
)
 
(876
)
Retained earnings
565

 
439

Treasury stock, 30,783,807 shares and 29,611,118 shares, at cost
(729
)
 
(712
)
Total KBR shareholders’ equity
982

 
942

Noncontrolling interests ("NCI")
(8
)
 
(7
)
Total shareholders’ equity
974

 
935

Total liabilities and shareholders’ equity
$
3,651

 
$
4,199

See accompanying notes to condensed consolidated financial statements.

6



KBR, Inc.
Condensed Consolidated Statements of Cash Flows
(In millions)
(Unaudited)
 
Nine Months Ended September 30,
 
2015
 
2014
Cash flows from (used in) operating activities:
 
 
 
Net income
$
178

 
$
33

Adjustments to reconcile net income to net cash provided by (used in) operating activities:
 
 
 
Depreciation and amortization
29

 
55

Equity in earnings of unconsolidated affiliates
(123
)
 
(118
)
Deferred income tax (benefit) expense
14

 
(2
)
Gain on disposition of assets
(34
)
 
(8
)
Gain on negotiated settlement with former parent

 
(24
)
Other
29

 
33

Changes in operating assets and liabilities:
 
 
 
Accounts receivable, net of allowance for doubtful accounts
(19
)
 
66

Costs and estimated earnings in excess of billings on uncompleted contracts
168

 
(109
)
Accounts payable
(239
)
 
(43
)
Billings in excess of costs and estimated earnings on uncompleted contracts
(10
)
 
53

Accrued salaries, wages and benefits
(5
)
 
(16
)
Reserve for loss on uncompleted contracts
(100
)
 
13

Receipts of advances from unconsolidated affiliates, net
10

 
14

Distributions of earnings from unconsolidated affiliates
84

 
212

Income taxes payable
(7
)
 
22

Pension funding
(37
)
 
(37
)
Net settlement of derivative contracts
(40
)
 
2

Other assets and liabilities
17

 
32

Total cash flows provided by (used in) operating activities
(85
)
 
178

Cash flows from (used in) investing activities:
 
 
 
Purchases of property, plant and equipment
(8
)
 
(46
)
Payment for investment in partnership
(15
)
 

Proceeds from sale of assets or investments
71

 
9

Total cash flows provided by (used in) investing activities
$
48

 
$
(37
)

7



KBR, Inc.
Condensed Consolidated Statements of Cash Flows
(In millions)
(Unaudited)
 
Nine Months Ended September 30,
 
2015
 
2014
Cash flows used in financing activities:
 
 
 
Payments to reacquire common stock
$
(22
)
 
$
(102
)
Acquisition of noncontrolling interest
(40
)
 

Investments from noncontrolling interests

 
10

Distributions to noncontrolling interests
(21
)
 
(49
)
Payments of dividends to shareholders
(35
)
 
(35
)
Net proceeds from issuance of common stock
1

 
4

Payments on short-term and long-term borrowings
(7
)
 
(7
)
Other
(4
)
 
1

Total cash flows used in financing activities
(128
)
 
(178
)
Effect of exchange rate changes on cash
(37
)
 
(21
)
Decrease in cash and equivalents
(202
)
 
(58
)
Cash and equivalents at beginning of period
970

 
1,106

Cash and equivalents at end of period
$
768

 
$
1,048

Supplemental disclosure of cash flows information:
 
 
 
Cash paid for interest
$
8

 
$
9

Cash paid for income taxes (net of refunds)
$
56

 
$
13

Noncash financing activities
 
 
 
Dividends declared
$
12

 
$
12

See accompanying notes to condensed consolidated financial statements.

8



KBR, Inc.
Notes to Condensed Consolidated Financial Statements
(Unaudited)

Note 1. Description of Company and Significant Accounting Policies

KBR, Inc., a Delaware corporation, was formed on March 21, 2006 and is headquartered in Houston, Texas. KBR, Inc. and its wholly owned and majority-owned subsidiaries (collectively referred to herein as "KBR", "the Company", "we", "us" or "our") is an engineering, procurement, construction and services company supporting the global hydrocarbons and international government services market segments. Our capabilities include engineering, procurement, construction, construction management, technology licensing, operations, maintenance and other support services to a diverse customer base, including international and national oil and gas companies, independent refiners, petrochemical producers, fertilizer producers, manufacturers and domestic and foreign governments.
  
Principles of Consolidation

Our condensed consolidated financial statements have been prepared in accordance with accounting principles generally accepted in the United States ("U.S. GAAP") and include the accounts of KBR and our wholly owned and majority-owned, controlled subsidiaries and variable interest entities ("VIEs") of which we are the primary beneficiary. We account for investments over which we have significant influence but not a controlling financial interest using the equity method of accounting. See Note 7 to our condensed consolidated financial statements for further discussion on our equity investments and VIEs. The cost method is used when we do not have the ability to exert significant influence. All material intercompany balances and transactions are eliminated in consolidation.

Certain prior year amounts have been reclassified to conform to the current year presentation on the condensed consolidated statements of operations, condensed consolidated balance sheets and the condensed consolidated statements of cash flows.

We have evaluated all events and transactions occurring after the balance sheet date but before the financial statements were issued and have included the appropriate disclosures.

Use of Estimates

The preparation of our condensed consolidated financial statements in conformity with U.S. GAAP requires us to make estimates and assumptions that affect the reported amounts of assets and liabilities and disclosures of contingent assets and liabilities at the date of the condensed consolidated financial statements and the reported amounts of revenues and expenses during the reporting period. Actual results could differ from those estimates. Areas requiring significant estimates and assumptions by our management include the following:

project revenues, costs and profits on engineering and construction contracts and government services contracts, including recognition of estimated losses on uncompleted contracts
provisions for uncollectible receivables and client claims and recoveries of costs from subcontractors, vendors and others
provisions for income taxes and related valuation allowances and tax uncertainties
recoverability of goodwill
recoverability of other intangibles and long-lived assets and related estimated lives
recoverability of equity method and cost method investments
valuation of pension obligations and pension assets
accruals for estimated liabilities, including litigation accruals
consolidation of VIEs
valuation of share-based compensation

In accordance with normal practice in the construction industry, we include in current assets and current liabilities amounts related to construction contracts realizable and payable over a period in excess of one year. If the underlying estimates and assumptions upon which the financial statements are based change in the future, actual amounts may differ from those included in the accompanying condensed consolidated financial statements.


9



Deconsolidation of a Subsidiary

We account for a gain or loss on deconsolidation of a subsidiary or derecognition of a group of assets in accordance with the guidance in Accounting Standards Codification ("ASC") 810-10-40-5. We measure the gain or loss as the difference between (a) the aggregate of all the following: (1) the fair value of any consideration received (2) the fair value of any retained noncontrolling investment in the former subsidiary or group of assets at the date the subsidiary is deconsolidated or the group of assets is derecognized and (3) the carrying amount of any noncontrolling interest in the former subsidiary (including any accumulated other comprehensive income attributable to the noncontrolling interest) at the date the subsidiary is deconsolidated and (b) the carrying amount of the former subsidiary’s assets and liabilities or the carrying amount of the group of assets.

Service Concession Arrangements

On January 24, 2014, the Financial Accounting Standards Board ("FASB") issued Accounting Standards Update ("ASU") No. 2014-05, Service Concession Arrangements. A service concession arrangement is an arrangement between a public-sector entity and an operating entity under which the operating entity operates the grantor's infrastructure. This ASU specifies that an operating entity should not account for a service concession arrangement within the scope of this ASU as a lease in accordance with ASC 840 - Leases. An operating entity should refer to other ASUs as applicable to account for various aspects of a service concession arrangement. The amendments also specify that the infrastructure used in a service concession agreement should not be recognized as property, plant and equipment of the operating entity. The amendments in this ASU are effective using a modified retrospective approach for annual reporting periods beginning after December 15, 2014 and interim periods within those annual periods. The adoption of ASU 2014-05 on January 1, 2015 did not have a material impact on our financial statements.

Additional Balance Sheet Information

Other Current Liabilities

The components of “other current liabilities” on our condensed consolidated balance sheets as of September 30, 2015 and December 31, 2014 are presented below:
 
September 30,
 
December 31,
Dollars in millions
2015
 
2014
Reserve for estimated losses on uncompleted contracts (a)
$
54

 
$
159

Retainage payable
61

 
88

Income taxes payable
55

 
61

Deferred tax liabilities
50

 
46

Value-added tax payable
27

 
31

Insurance payable
15

 
19

Dividend payable
12

 
12

Other miscellaneous liabilities (b)
52

 
72

Total other current liabilities
$
326

 
$
488

 
(a)
See Note 2 for further discussion on our reserve for estimated losses on uncompleted contracts.
(b)
Included in other current miscellaneous liabilities is $7 million of deferred rent as of September 30, 2015 and December 31, 2014, respectively.

Other Liabilities

Included in the "other liabilities" balance on our condensed consolidated balance sheets as of September 30, 2015 and December 31, 2014 is noncurrent deferred rent of $118 million and $128 million, respectively.

Note 2. Business Segment Information
Following the completion of our strategic review, in December 2014, we reorganized our business into three segments in order to focus on core strengths in technology and consulting, engineering and construction, and government services.  We also reorganized the businesses that we intend to exit into our Non-strategic Business segment because they no longer constitute a part of our future strategic focus. Each business segment reflects a reportable segment led by a separate business segment president

10



who reports directly to our chief operating decision maker ("CODM").  Business segment performance is evaluated by our CODM using gross profit (loss), which is defined as business segment revenues less the cost of revenues, and includes overhead directly attributable to the business segment. We have revised our business segment reporting to reflect our current management approach and recast prior periods to conform to the current business segment presentation.

Our business segments are described below.

Technology & Consulting ("T&C"). Our T&C business segment combines proprietary KBR technologies, knowledge-based services and our three specialist consulting brands, Granherne, Energo and GVA, under a single customer-facing global business.  This business segment provides licensed technologies and consulting services throughout the oil and gas value chain, from wellhead to crude refining and through to specialty chemicals production.  In addition to sharing many of the same customers, these brands share the approach of early and continuous customer involvement to deliver an optimal solution to meet the customer’s objectives through early planning and scope definition, advanced technologies, and project lifecycle support.
Engineering & Construction ("E&C"). Our E&C business segment leverages our operational and technical excellence as a global provider of engineering, procurement, construction ("EPC"), commissioning and maintenance services for oil and gas, refining, petrochemical and chemical customers.  E&C is managed on a geographic basis in order to facilitate close proximity to our customers and our people, while utilizing a consistent global execution strategy. 
Government Services ("GS"). Our GS business segment focuses on long-term service contracts with annuity streams, particularly for the United Kingdom ("U.K."), Australian and United States ("U.S.") governments.
Non-strategic Business. Our Non-strategic Business segment represents the operations or activities that we intend to either sell to third parties or exit upon completion of existing contracts.
Other. Our Other business segment includes our corporate expenses and general and administrative expenses not allocated to the business segments above and any future activities that do not individually meet the criteria for segment presentation. 

The following table presents revenues, gross profit, equity in earnings of unconsolidated affiliates and operating income (loss) by reporting segment.

11



Operations by Reportable Segment
 
Three Months Ended
 
Nine Months Ended
 
September 30,
 
September 30,
Dollars in millions
2015
 
2014
 
2015
 
2014
Revenues:
 
 
 
 
 
 
 
Technology & Consulting
$
79

 
$
94

 
$
231

 
$
285

Engineering & Construction
828

 
1,196

 
2,758

 
3,546

Government Services
176

 
178

 
489

 
527

Other

 

 

 

Subtotal
1,083

 
1,468

 
3,478

 
4,358

Non-strategic Business
116

 
189

 
538

 
591

Total revenues
$
1,199

 
$
1,657

 
$
4,016

 
$
4,949

Gross profit (loss):
 
 
 
 
 
 
 
Technology & Consulting
$
17

 
$
18

 
$
57

 
$
48

Engineering & Construction
48

 
46

 
155

 
108

Government Services
8

 
24

 
3

 
28

Other

 

 

 

Subtotal
73

 
88

 
215

 
184

Non-strategic Business
14

 
(58
)
 
16

 
(87
)
Total gross profit (loss)
$
87

 
$
30

 
$
231

 
$
97

Equity in earnings of unconsolidated affiliates:
 
 
 
 
 
 
 
Technology & Consulting
$

 
$

 
$

 
$

Engineering & Construction
26

 
26

 
87

 
63

Government Services
9

 
12

 
36

 
55

Other

 

 

 

Subtotal
35

 
38

 
123

 
118

Non-strategic Business

 

 

 

Total equity in earnings of unconsolidated affiliates
$
35

 
$
38

 
$
123

 
$
118

Asset impairment and restructuring charges:
 
 
 
 
 
 
 
Technology & Consulting
$

 
$

 
$
(1
)
 
$

Engineering & Construction
(13
)
 

 
(25
)
 

Government Services

 

 

 

Other
(1
)
 

 
(5
)
 

Subtotal
(14
)
 

 
(31
)
 

Non-strategic Business
(1
)
 

 
(3
)
 

Total asset impairment and restructuring charges
$
(15
)
 
$

 
$
(34
)
 
$

Segment operating income (loss):
 
 
 
 
 
 
 
Technology & Consulting
$
16

 
$
18

 
$
53

 
$
48

Engineering & Construction
61

 
58

 
201

 
129

Government Services
15

 
34

 
34

 
77

Other
(28
)
 
(42
)
 
(92
)
 
(122
)
Subtotal
64

 
68

 
196

 
132

Non-strategic Business
11

 
(58
)
 
39

 
(87
)
Total segment operating income (loss)
$
75

 
$
10

 
$
235

 
$
45



12



Prior Period Adjustment
During the second quarter of 2015, we corrected a cumulative error related to transactions between the unconsolidated affiliates associated with our Mexican offshore maintenance joint venture within our E&C business segment. The cumulative error occurred throughout the period beginning in 2007 and through the first quarter of 2015 and resulted in a $15 million favorable impact to "equity in earnings of unconsolidated affiliates" on our condensed consolidated statements of operations during the second quarter of 2015. We evaluated the cumulative error on both a quantitative and qualitative basis under the guidance of ASC 250 - Accounting Changes and Error Corrections. We determined that the cumulative impact of the error did not affect the trend of net income, cash flows or liquidity and therefore did not have a material impact to previously issued financial statements. Additionally, we do not expect our consolidated financial statements for the current annual period to be materially impacted by the error correction.
Changes in Estimates

There are many factors that can affect the accuracy of our cost estimates and ultimately our future profitability, including, but not limited to, the availability and costs of resources, including labor, materials and equipment, productivity and weather, and for unit rate and construction service contracts, the availability and detail of customer supplied engineering drawings. In the past, we have realized both lower and higher than expected margins and have incurred losses as a result of unforeseen changes in our project costs. We recognize revisions of revenues and costs in the period in which the revisions are known. This may result in the recognition of costs before the recognition of related revenue recovery, if any. However, historically, our estimates have been reasonably dependable regarding the recognition of revenues and profit on percentage of completion contracts.

Significant changes in estimates periodically result in the recognition of losses on a particular contract. We generally believe that the recognition of a contract as a loss contract is a significant change in estimate. Activity in our reserve for estimated losses on uncompleted contracts, which is a component of "other current liabilities" on our condensed consolidated balance sheets, was as follows:
Dollars in millions
Reserve for Estimated Losses
Balance at December 31, 2014
$
159

Changes in estimates on loss projects
(7
)
Change due to progress on loss projects
(98
)
Balance at September 30, 2015
$
54

 
 
Dollars in millions
Reserve for Estimated Losses
Balance at December 31, 2013
$
109

Changes in estimates on loss projects
76

Change due to progress on loss projects
(67
)
Balance at September 30, 2014
$
118


Included in the reserve for estimated losses on uncompleted contracts is $41 million as of September 30, 2015 and $80 million as of December 31, 2014 primarily related to two power project in our Non-strategic Business segment, which we recognized as loss contracts during the fourth quarter of 2014. During the three and nine months ended September 30, 2015, there were no significant changes in our estimates of losses on these projects. Our estimates of revenues and costs at completion for these power projects have been, and may continue to be, impacted by our performance, the performance of our subcontractors, and the U.S. labor market. Our estimated losses at completion as of September 30, 2015 on these power projects represent our best estimate based on current information. Actual results could differ from the estimates we have used to account for these power projects as of September 30, 2015.

Included in the reserve for estimated losses on uncompleted contracts is $2 million as of September 30, 2015 and $53 million as of December 31, 2014 related to our Canadian pipe fabrication and module assembly projects. During the three and nine months ended September 30, 2015 we recognized favorable changes in estimates of losses on these projects of $4 million and $21 million, respectively, primarily due to negotiated settlements in the second quarter of 2015. During the three months ended September 30, 2014 we recognized favorable changes in estimates of losses of $2 million and unfavorable changes in our estimates of losses at completion of $80 million during the nine months ended September 30, 2014. We have completed or substantially completed these projects. We continue to finalize and negotiate financial closure of these projects with our customers. Our estimated losses as of September 30, 2015 on these projects represent our best estimate based on current information. Actual

13



results could differ from the estimates we have used to account for these projects as of September 30, 2015.

Dispositions

On June 30, 2015, we closed on the sale of our Building Group subsidiary to a subsidiary of Pernix Group, Inc., for consideration of $23 million, net cash proceeds including working capital adjustments and the assumption of some liabilities. The sale of the Building Group within our Non-strategic Business segment is consistent with our restructuring plans announced in December 2014. The disposition resulted in a pre-tax gain of $27 million and is subject to future adjustments resulting from the finalization of the closing balance sheet. The gain is included under “gain on disposition of assets” on our condensed consolidated statements of operations

On September 30, 2015, we executed agreements to establish two strategic relationships within our E&C business segment. See Note 7 to our condensed consolidated financial statements for information about dispositions related to the establishment of these new strategic relationships.

Restructuring

Included in "other current liabilities" on our condensed consolidated balance sheets at September 30, 2015 and December 31, 2014 are $9 million and $21 million, respectively, representing unpaid termination benefits related to our workforce reduction which was announced as a part of our strategic reorganization in the last quarter of 2014. We recognized an additional $11 million of termination benefits within our E&C and Non-strategic Business segments in the second quarter. During 2015, we made payments of $23 million.

Subsequent Event

Subsequent to September 30, 2015, we reached a definitive agreement for the sale of our U.S. Infrastructure business within the Non-strategic Business segment.

Note 3. Cash and Equivalents

We consider all highly liquid investments with an original maturity of three months or less to be cash equivalents. Cash and equivalents include cash balances held by our wholly-owned subsidiaries as well as cash held by joint ventures that we consolidate. Joint venture cash balances are limited to joint venture activities and are not available for other projects, general cash needs or distribution to us without approval of the board of directors of the respective joint ventures. We expect to use joint venture cash for project costs and distributions of earnings related to joint venture operations. However, some of the earnings distributions may be paid to other KBR entities where the cash can be used for general corporate needs.


14



The components of our cash and equivalents balance are as follows:
 
September 30, 2015
Dollars in millions
International (a)
 
Domestic (b)
 
Total
Operating cash and equivalents
$
136

 
$
298

 
$
434

Time deposits
259

 
6

 
265

Cash and equivalents held in joint ventures
65

 
4

 
69

Total
$
460

 
$
308

 
$
768


 
December 31, 2014
Dollars in millions
International (a)
 
Domestic (b)
 
Total
Operating cash and equivalents
$
209

 
$
121

 
$
330

Time deposits
481

 
79

 
560

Cash and equivalents held in joint ventures
71

 
9

 
80

Total
$
761

 
$
209

 
$
970

 
(a)
Includes deposits held in non-U.S. operating accounts.
(b)
Includes U.S. dollar and foreign currency deposits held in operating accounts that constitute onshore cash for tax purposes but may reside either in the U.S. or in a foreign country.

Our international cash balances are primarily held in Australia and the Netherlands.

Note 4. Accounts Receivable
    
The components of our accounts receivable, net of allowance for doubtful accounts balance are as follows:
 
September 30, 2015
Dollars in millions
Retainage
 
Trade & Other
 
Total
Technology & Consulting
$

 
$
68

 
$
68

Engineering & Construction
36

 
411

 
447

Government Services
2

 
87

 
89

Other

 
5

 
5

Subtotal
38

 
571

 
609

Non-strategic Business
56

 
34

 
90

Total
$
94

 
$
605

 
$
699


 
December 31, 2014
Dollars in millions
Retainage
 
Trade & Other
 
Total
Technology & Consulting
$

 
$
51

 
$
51

Engineering & Construction
45

 
538

 
583

Government Services
5

 
84

 
89

Other

 
3

 
3

Subtotal
50

 
676

 
726

Non-strategic Business
48

 
73

 
121

Total
$
98

 
$
749

 
$
847


In addition, noncurrent retainage receivable included in "other assets" on our condensed consolidated balance sheets was $1 million and $14 million as of September 30, 2015 and December 31, 2014, respectively, primarily in our Non-strategic Business segment.


15



Note 5. Costs and Estimated Earnings in Excess of Billings on Uncompleted Contracts and Billings in Excess of Costs and Estimated Earnings on Uncompleted Contracts
Our CIE balances by business segment are as follows:
 
September 30,
 
December 31,
Dollars in millions
2015
 
2014
Technology & Consulting
$
32

 
$
38

Engineering & Construction
159

 
357

Government Services
90

 
73

Subtotal
281

 
468

Non-strategic Business
3

 
22

Total
$
284

 
$
490


Our BIE balances by business segment are as follows:
 
September 30,
 
December 31,
Dollars in millions
2015
 
2014
Technology & Consulting
$
65

 
$
56

Engineering & Construction
252

 
212

Government Services
90

 
93

Subtotal
407

 
361

Non-strategic Business
93

 
170

Total
$
500

 
$
531


Unapproved change orders and claims

The amounts of unapproved change orders and claims included in determining the profit or loss on contracts are as follows:
Dollars in millions
2015
 
2014
Amounts included in project estimates-at-completion at January 1,
$
31

 
$
115

Changes in estimates-at-completion
48

 
81

Approved (a)
(46
)
 
(134
)
Amounts included in project estimates-at-completion at September 30,
$
33

 
$
62

 
 
 
 
Amounts recorded in revenues on a percentage-of-completion basis at September 30,
$
32

 
$
53

 
(a)
Includes $6 million of adjustments associated with the sale of our Building Group subsidiary in the second quarter of 2015.

The table above excludes unapproved change orders and claims related to our unconsolidated affiliates. Our proportionate share of unapproved change orders and claims on a percentage-of-complete basis was $59 million as of September 30, 2015 and $84 million as of September 30, 2014 on a project in our E&C business segment. The decrease is primarily due to changes in estimated costs of unapproved change orders related to our unconsolidated affiliates.

Liquidated damages

Some of our engineering and construction contracts have schedule dates and performance obligations that if not met could subject us to penalties for liquidated damages. These generally relate to specified activities that must be completed by a set contractual date or by achievement of a specified level of output or throughput. Each contract defines the conditions under which a customer may make a claim for liquidated damages. However, in some instances, liquidated damages are not asserted by the customer, but the potential to do so is used in negotiating or settling claims and closing out the contract.


16



It is possible that liquidated damages related to several projects totaling $6 million at September 30, 2015 and $12 million at December 31, 2014, respectively, (including amounts related to our share of unconsolidated subsidiaries), could be incurred if the projects are completed as currently forecasted. However, based upon our evaluation of our performance we have concluded these liquidated damages are not probable; therefore, they have not been recognized.

Note 6. Claims and Accounts Receivable

The components of our claims and accounts receivable account balance not expected to be collected within the next 12 months are as follows:
 
September 30,
 
December 31,
Dollars in millions
2015
 
2014
Engineering & Construction
$
425

 
$
425

Government Services
124

 
145

Total
$
549

 
$
570


Our E&C business segment's claims and accounts receivable includes $401 million related to our EPC 1 arbitration. See Note 12 to our condensed consolidated financial statements under PEMEX and PEP Arbitration for further discussion. The remaining balance is related to a construction project for which we are actively pursuing the recovery of these receivables.

Our GS business segment's claims and accounts receivable reflects claims for costs incurred under various U.S. government contracts. See "Other Matters" in Note 11 to our condensed consolidated financial statements for further discussion on our U.S. government claims.


17



Note 7. Equity Method Investments and Variable Interest Entities

We conduct some of our operations through joint ventures which operate through partnership, corporations, undivided interest and other business forms and are principally accounted for using the equity method of accounting. Additionally, the majority of our joint ventures are also VIEs.

The following table presents a rollforward of our equity in and advances to unconsolidated affiliates:
 
September 30,
 
December 31,
Dollars in millions
2015
 
2014
Beginning balance
$
151

 
$
156

Equity in earnings of unconsolidated affiliates
123

 
163

Distribution of earnings of unconsolidated affiliates
(84
)
 
(249
)
Advances
(10
)
 
(13
)
Investments (a)
76

 

Foreign currency translation adjustments
(9
)
 
(1
)
Other
2

 

Balance before reclassification
$
249

 
$
56

Reclassification of excess distribution
16

 
102

Recognition of excess distributions
(4
)
 
(7
)
Ending balance
$
261

 
$
151

 
(a)
Investments include a $58 million investment in the Brown & Root Industrial Services joint venture and a $20 million investment in EPIC Piping, including prior quarter dispositions related to the Building Group. See below for further discussion related to joint venture formations and investments.

During 2014, we received cash dividends of $102 million in excess of the carrying value of one of our investments. We have no obligation to return any portion of the cash dividends received. We recorded the excess dividend amount as “deferred income from unconsolidated affiliates” on our condensed consolidated balance sheets and will recognize these dividends as earnings are generated by the investment. We recognized $7 million of the excess dividends during 2014. During 2015, we received an additional $16 million of cash dividends in excess of the carrying value of our investment and recognized $4 million of excess dividends.

New Investment

On September 30, 2015, we executed an agreement with Bernhard Capital Partners ("BCP"), the private equity firm, to establish the Brown & Root Industrial Services joint venture. In connection with the formation of the joint venture, we contributed our Industrial Services Americas business and received net cash consideration of $48 million and a 50% interest in the joint venture. As a result of the transaction, we no longer have a controlling interest in this Industrial Services business and have deconsolidated it effective September 30, 2015. The transaction resulted in a pre-tax gain of $7 million, which is included in “gain on disposition of assets” on our condensed consolidated statements of operations. The fair value of our retained interest in the former subsidiary was determined using both a market approach and an income approach. Cash consideration was the primary input used for the market approach.
The Brown & Root Industrial Services joint venture will continue to offer services similar or related to those offered when the business was part of KBR. Our interest in this venture is accounted for using the equity method and we have determined that the Brown & Root Industrial Services joint venture is not a VIE. Our continuing involvement in the joint venture will be through our 50% voting interest and representation on the board of managers. Consistent with our other equity investments, transactions between us and the joint venture, if any, will be deemed related party transactions. Also, in connection with this transaction, we entered into an agreement effective October 1, 2015 to provide specified transition services to the new joint venture over a limited duration. The joint venture will reimburse us for all costs incurred on these transition services.
On September 30, 2015, we acquired general and limited partner interests in a partnership that owns a pipe fabrication business operating under the name EPIC Piping LLC ("EPIC"). BCP also holds general and limited partner interests in this partnership. Consideration for these interests was $15 million in cash and contribution of the majority of our Canada pipe fabrication and module assembly business. We have determined that this arrangement is not a VIE and we will account for our ownership

18



interest using the equity method. In addition, we entered into an alliance agreement with EPIC to provide certain pipe fabrication services to KBR. As a result of these transactions we recognized a $9 million charge on the early termination of leases related to a Canadian fabrication yard and a $5 million impairment of our Canadian enterprise resource planning assets.
Related Party Transactions

We often provide engineering, construction management and other services as a subcontractor to the joint ventures in which we participate. The amounts included in our revenues represent revenues from services we provide directly to the joint ventures. For the three and nine months ended September 30, 2015 our revenues included $96 million and $223 million, respectively, related to services we provided to our joint ventures, primarily those in our E&C business segment. For the three and nine months ended September 30, 2014 our revenues included $84 million and $228 million, respectively, related to services we provided to our joint ventures in our E&C business segment.

Amounts included in our condensed consolidated balance sheets related to services we provided to our unconsolidated joint ventures as of September 30, 2015 and December 31, 2014 are as follows:
 
September 30,
 
December 31,
Dollars in millions
2015
 
2014
Accounts receivable, net of allowance for doubtful accounts
$
10

 
$
7

Costs and estimated earnings in excess of billings on uncompleted contracts
$
6

 
$
2

Billings in excess of costs and estimated earnings on uncompleted contracts
$
52

 
$
21


Our related party accounts payable for both periods were immaterial.

Unconsolidated Variable Interest Entities

Generally, our maximum exposure to loss is limited to our equity investment in the joint venture and any amounts payable to us for services we provided to the joint venture reduced for any unearned revenues on the projects. On the Aspire Defence project, in addition to the maximum exposure to loss indicated in the table below, we have exposure to any losses incurred by the construction or operating joint ventures under their respective subcontract arrangements with the project company. Our exposure is, however, limited to our equity participation in these entities. The Ichthys liquefied natural gas ("LNG") project joint venture executes a project that has a lump sum component; in addition to the maximum exposure to loss indicated in the table below, we have an exposure to losses to the extent of our ownership percentage in the joint venture if the project exceeds the lump sum component. Our maximum exposure to loss on the EBIC Ammonia plant reflects our 65% ownership of the development corporation which owns 25% of the company that consolidates the ammonia plant. We continue to monitor our investment in this joint venture as the profitability of its operations has been impacted by the challenges related to the availability of natural gas feedstock in Egypt.

The following summarizes the total assets and total liabilities as reflected in our condensed consolidated balances sheets as well as our maximum exposure to losses related to our unconsolidated VIEs in which we have a significant variable interest but are not the primary beneficiary.

 
September 30, 2015
Dollars in millions
Total assets
 
Total liabilities
 
Maximum
exposure to 
loss
Aspire Defence project
$
15

 
$
127

 
$
15

Ichthys LNG project
$
72

 
$
58

 
$
72

U.K. Road projects
$
35

 
$
11

 
$
35

EBIC Ammonia plant (65% interest)
$
37

 
$
2

 
$
23

 

19



 
December 31, 2014
Dollars in millions
Total assets
 
Total liabilities
 
Maximum
exposure to 
loss
Aspire Defence project
$
17

 
$
118

 
$
17

Ichthys LNG project
$
49

 
$
35

 
$
49

U.K. Road projects
$
34

 
$
11

 
$
34

EBIC Ammonia plant (65% interest)
$
42

 
$
2

 
$
26


Consolidated Variable Interest Entities

We consolidate VIEs if we determine we are the primary beneficiary of the project entity because we control the activities that most significantly impact the economic performance of the entity. The following is a summary of the significant VIEs where we are the primary beneficiary:
Dollars in millions
September 30, 2015
Total assets
 
Total liabilities
Gorgon LNG project
$
152

 
$
176

Escravos Gas-to-Liquids project
$
15

 
$
31

Fasttrax Limited project
$
80

 
$
75

 

Dollars in millions
December 31, 2014
Total assets
 
Total liabilities
Gorgon LNG project
$
282

 
$
309

Escravos Gas-to-Liquids project
$
23

 
$
36

Fasttrax Limited project
$
83

 
$
81


Acquisition of Noncontrolling Interest

During the three months ended March 31, 2015, we entered into an agreement to acquire the noncontrolling interest in one of our consolidated joint ventures for $40 million. We paid the partner previously accrued expenses of $8 million. The acquisition of these shares was recorded as an equity transaction, with a $40 million reduction in our paid-in capital in excess of par.

Note 8. Pension Plans

The components of net periodic benefit cost related to pension benefits for the three and nine months ended September 30, 2015 and 2014 were as follows:
 
Three Months Ended September 30,
Dollars in millions
2015
 
2014
 
United States
 
Int’l
 
United States
 
Int’l
Components of net periodic benefit cost
 
 
 
 
 
 
 
Service cost
$

 
$

 
$

 
$
1

Interest cost
1

 
19

 
1

 
23

Expected return on plan assets

 
(24
)
 
(1
)
 
(26
)
Recognized actuarial loss
1

 
11

 
1

 
10

Net periodic benefit cost
$
2

 
$
6

 
$
1

 
$
8



20



 
Nine Months Ended September 30,
Dollars in millions
2015
 
2014
 
United States
 
Int’l
 
United States
 
Int’l
Components of net periodic benefit cost
 
 
 
 
 
 
 
Service cost
$

 
$
1

 
$

 
$
2

Interest cost
2

 
57

 
2

 
68

Expected return on plan assets
(2
)
 
(73
)
 
(3
)
 
(78
)
Recognized actuarial loss
4

 
33

 
3

 
29

Net periodic benefit cost
$
4

 
$
18

 
$
2

 
$
21


For the nine months ended September 30, 2015, we have contributed approximately $32 million of the $43 million we expect to contribute to our international plans in 2015. For the nine months ended September 30, 2015, we have also contributed $5 million to one of our domestic plans that we are in the process of terminating.

Note 9. Debt and Other Credit Facilities

Credit Agreement

On September 25, 2015, we entered into a new $1 billion, unsecured revolving credit agreement (the “Credit Agreement”) with a syndicate of banks replacing the previous agreement which was scheduled to mature in December 2016. The Credit Agreement is guaranteed by certain of the Company's domestic subsidiaries, matures in September 2020 and is available for cash borrowings and the issuance of letters of credit related to general corporate needs. Subject to certain conditions, we may request (i) that the aggregate commitments under the Credit Agreement be increased by up to an additional $500 million, and (ii) that the maturity the Credit Agreement be extended by two additional one-year terms.

Amounts drawn under the Credit Agreement will bear interest at variable rates, per annum, based either on (i) the London interbank offered rate (“LIBOR”) plus an applicable margin of 1.375% to 1.75%, or (ii) a base rate plus an applicable margin of 0.375% to 0.75%, with the base rate equal to the highest of (a) reference bank’s publicly announced base rate, (b) the Federal Funds Rate plus 0.5%, or (c) LIBOR plus 1%. The amount of the applicable margin to be applied will be determined by the Company’s ratio of consolidated debt to consolidated EBITDA for the prior four fiscal quarters, except for the period ended September 30, 2015, for which the prior three fiscal quarters are utilized, as defined in the Credit Agreement. The Credit Agreement provides for fees on letters of credit issued under the Credit Agreement at a rate equal to the applicable margin for LIBOR-based loans, except for performance letters of credit, which are priced at 50% of such applicable margin. KBR pays an annual issuance fee of 0.125% of the face amount of a letter of credit and pays a commitment fee of 0.225% to 0.25%, per annum, on any unused portion of the commitment under the Credit Agreement based on the Company's consolidated leverage ratio. As of September 30, 2015, there were $130 million in letters of credit and no cash borrowings outstanding.

The Credit Agreement contains customary covenants, as defined in the Credit Agreement, which include financial covenants requiring maintenance of a ratio of consolidated debt to consolidated EBITDA not greater than 3.5 to 1 and a minimum consolidated net worth of $1.2 billion plus 50% of consolidated net income for each quarter beginning September 30, 2015 and 100% of any increase in shareholders’ equity attributable to the sale of equity interests. As of September 30, 2015, we were in compliance with our financial covenants.

The Credit Agreement contains a number of other covenants restricting, among other things, our ability to incur additional liens and indebtedness, enter into asset sales, repurchase our equity shares and make certain types of investments. Our subsidiaries are restricted from incurring indebtedness, except if such indebtedness relates to purchase money obligations, capitalized leases, refinancing or renewals secured by liens upon or in property acquired, constructed or improved in an aggregate principal amount not to exceed $200 million outstanding at any time. Additionally, our subsidiaries may incur unsecured indebtedness not to exceed $200 million in aggregate outstanding principal amount at any time. We are also permitted to repurchase our equity shares, provided that no such repurchases shall be made from proceeds borrowed under the Credit Agreement, and that the aggregate purchase price and dividends paid after September 25, 2015, does not exceed the Distribution Cap (equal to the sum of $750 million plus the lesser of (1) $400 million and (2) the amount received by us in connection with the arbitration and subsequent litigation of the PEP contracts as discussed in Note 12 to our condensed consolidated financial statements). As of September 30, 2015, the remaining availability under the Distribution Cap was approximately $750 million.


21



Nonrecourse Project Debt

Fasttrax Limited, a joint venture in which we indirectly own a 50% equity interest with an unrelated partner, was awarded a concession contract in 2001 with the U.K. Ministry of Defense ("MoD") to provide a Heavy Equipment Transporter Service to the British Army. See Note 7 to our condensed consolidated financial statements for further discussion on the joint venture. Under the terms of the arrangement, Fasttrax Limited operates and maintains 91 heavy equipment transporters (“HETs”) for a term of 22 years. The purchase of the HETs by the joint venture was financed through two series of bonds secured by the assets of Fasttrax Limited and a bridge loan totaling approximately £84.9 million (approximately $120 million at the exchange rate on the date of the transaction). The secured bonds are an obligation of Fasttrax Limited and are not a debt obligation of KBR as they are nonrecourse to the joint venture partners. Accordingly, in the event of a default on the notes, the lenders may only look to the assets of Fasttrax Limited for repayment. The bridge loan of approximately £12.2 million (approximately $17 million at the exchange rate on the date of the transaction) was replaced when the joint venture partners funded their equity and subordinated debt contributions in 2005.

The secured bonds were issued in two classes consisting of Class A 3.5% Index Linked Bonds in the amount of £56 million (approximately $79 million at the exchange rate on the date of the transaction) and Class B 5.9% Fixed Rate Bonds in the amount of £16.7 million (approximately $24 million at the exchange rate on the date of the transaction).  Semi-annual payments on both classes of bonds commenced in March 2005 and will continue through maturity in 2021.  The subordinated notes payable to each of the partners initially bear interest at 11.25% increasing to 16% over the term of the notes until maturity in 2025.  Semi-annual payments on the subordinated notes commenced in March 2006. For financial reporting purposes, only our partner's portion of the subordinated notes appears in the condensed consolidated financial statements.

Note 10. Income Taxes

The effective tax rate was approximately 24% and 26% for the three and nine months ended September 30, 2015, respectively. The effective tax rate for both the three and nine months ended September 30, 2015 includes the net effect of changes in our reserve for uncertain tax positions, additional prior year foreign withholding taxes and other net changes.

The effective tax rate was approximately (2)% and 48% for the three and nine months ended September 30, 2014, respectively. The effective tax rate for the three months ended September 30, 2014 was impacted by discrete tax benefits including a reduction in our reserve for uncertain tax positions as a result of lapse of stature of limitations. The effective tax rate for the nine months ended September 30, 2014 includes the recognition of a valuation allowance on the losses recognized on our Canadian pipe fabrication and module assembly projects.

Our estimated annual rate for 2015 is 25%, which is lower than the U.S. statutory rate of 35% due to lower tax rates on foreign earnings and noncontrolling interests of approximately 5% and 9%, respectively, offset by an increase in the estimated annual rate due to withholding tax obligations for which we do not expect to recognize an offsetting foreign tax credit in 2015. Our estimated annual effective rate is subject to change based on the actual jurisdictions where our 2015 earnings are generated.

The valuation allowance for deferred tax assets as of September 30, 2015 and December 31, 2014 was $478 million and $538 million, respectively. The change in the valuation allowance was a decrease of $48 million and an increase of $3 million in the three months ended September 30, 2015 and 2014, respectively and a decrease of $60 million and increase of $35 million for the nine months ended September 30, 2015 and 2014, respectively. The valuation allowance is primarily related to U.S. federal, foreign and state net operating loss carryforwards, foreign tax credit carryforwards and other deferred tax assets that, in the judgment of management, are not more-likely-than-not to be realized. The decrease in the valuation allowance is primarily related to the utilization of federal tax attributes as a result of the gains on disposition of assets and jurisdictional sourcing of profits. The tax benefit associated with the reduction in the valuation allowance is reflected in our estimated annual effective tax rate for the year.

The reserve for uncertain tax positions included in "other liabilities" and "deferred income taxes" on our condensed consolidated balance sheets as of September 30, 2015 and December 31, 2014 was $253 million and $228 million, respectively. The net increase in the uncertain tax position for the three months ended September 30, 2015 and 2014 was $18 million and $57 million, respectively, and $25 million and $57 million for the nine months ended September 30, 2015 and 2014, respectively. During the three and nine months ended September 30, 2015, the net change includes approximately $43 million in increases in uncertain tax positions in foreign jurisdictions offset by $16 million benefits from lapse of statute of limitations. During the three and nine months ended September 30, 2014, we recognized an approximately $62 million increase in our reserve for uncertain tax positions related to a 2009 amended tax return position and a $5 million benefit from lapse of statute of limitations.


22



Note 11. U.S. Government Matters

We provide services to various U.S. governmental agencies, which include the U.S. Department of Defense (“DoD”) and the Department of State. We may have disagreements or experience performance issues on our U.S. government contracts. When performance issues arise under any of these contracts, the U.S. government retains the right to pursue various remedies, including challenges to expenditures, suspension of payments, fines and suspensions or debarment from future business with the U.S. government.

Between 2002 and 2011 we provided significant support to the U.S. Army and other U.S. government agencies in support of the war in Iraq under the LogCAP III contract. We continue to support the U.S. government around the world under the LogCAP IV and other contracts. We have been in the process of closeout of the LogCAP III contract since 2011, and we expect the closeout process to continue through at least 2017. As a result of our work under LogCAP III, there are multiple claims and disputes pending between us and the U.S. government, all of which need to be resolved to close the contracts. The closeout process includes resolving objections raised by the U.S. government through a billing dispute process referred to as Form 1s and Memorandums for Record ("MFRs") and resolving results from U.S. government audits. We continue to work with the U.S. government to resolve these issues and are engaged in efforts to reach mutually acceptable resolution of these outstanding matters. However, for certain of these matters, we have filed claims with the Armed Services Board of Contract Appeals ("ASBCA") or the U.S. Court of Federal Claims ("COFC"). We also have matters related to ongoing litigation or investigations involving U.S. government contracts. We anticipate billing additional labor, vendor resolution and litigation costs as we resolve the open matters. At this time, we cannot determine the timing or net amounts to be collected or paid to close out these contracts.

Form 1s

The U.S. government has issued Form 1s questioning or objecting to costs we billed to them. We believe the amounts we have invoiced the U.S. government are in compliance with our contract terms; however, we continue to evaluate our ability to recover these amounts as new information becomes known. A summary of our Form 1s received and amounts associated with our Form 1s is as follows:
 
September 30,
 
December 31,
Dollars in millions
2015
 
2014
Form 1s issued by the U.S. government and outstanding (a)
$
174

 
$
188

Amounts withheld by U.S. government (included in the Form 1s amount above) (b)
83

 
96

Amounts withheld from subcontractors by us
32

 
32

Claims loss accruals (c)
26

 
25


(a)
Included in the amounts shown is $56 million related to our Private Security matter discussed below.
(b)
Recorded in "claims and accounts receivable" on our condensed consolidated balance sheets. We believe these amounts are probable of collection. See discussions below for details of amounts withheld by the U.S. government on Form 1s.
(c)
Recorded as a reduction to "claims and accounts receivable" and in "other liabilities" on our condensed consolidated balance sheets. At this time, we believe the likelihood we would incur a loss related to these matters in excess of the loss accruals we have recorded is remote.

Summarized below are some of the details associated with individual Form 1s as part of the total explained above.

Private Security. Starting in February 2007, we received a series of Form 1s from the Defense Contract Audit Agency ("DCAA") informing us of the U.S. government's intent to deny reimbursement to us under the LogCAP III contract for amounts related to the use of private security contractors ("PSCs") by KBR and a subcontractor in connection with its work for KBR providing dining facility services in Iraq between 2003 and 2006. The U.S. government challenged $56 million in billings. The U.S. government had previously paid $11 million and has withheld payments of $45 million, which as of September 30, 2015 we have recorded as due from the U.S. government related to this matter in "claims and accounts receivable" on our condensed consolidated balance sheets.

On June 16, 2014, we received a decision from the ASBCA which agreed with KBR's position that the LogCAP III contract did not prohibit the use of PSCs to provide force protection to KBR or subcontractor personnel, that there was a need for force protection and that the costs were reasonable. The ASBCA also found that the Army breached its obligation to provide force protection. Accordingly, we believe that we are entitled to reimbursement by the Army for the amounts charged by our subcontractors, even if they incurred costs for PSCs. The Army appealed and on September 15, 2015, the Federal Court ruled,

23



affirming the ASBCA's decision in part, reversing in part, and remanding the issue of the Government's alleged breach of contract to the ASBCA for further consideration and definitive ruling. We are reviewing our options as to the most effective path forward. Any motion for rehearing must be filed by October 30, 2015. At this time, we believe the likelihood that we will incur a loss related to this matter is remote, and therefore we have not accrued any loss provisions related to this matter.

Containers. In June 2005, the DCAA questioned billings on costs associated with providing containerized housing for soldiers and supporting civilian personnel in Iraq. The Defense Contract Management Agency ("DCMA") recommended that payment for the billings be withheld pending receipt of additional explanation or documentation to support the subcontract costs. The Form 1 was issued for $51 million in billings. Of this amount, the U.S. government had previously paid $25 million and has withheld payments of $26 million, which as of September 30, 2015, we have recorded in "claims and accounts receivable" on our condensed consolidated balance sheets.

Included in "other liabilities" on our condensed consolidated balance sheets is $30 million of payments withheld from subcontractors related to pay-when-paid contractual terms. At this time, we believe that the likelihood we would incur a loss related to this matter in excess of the amounts we have withheld from subcontractors and the loss accruals we have recorded is remote.

There are three related actions stemming from the DCMA's action to disallow and withhold funds. First, in April 2008, we filed a counterclaim in arbitration against our LogCAP III subcontractor, First Kuwaiti Trading Company, to recover the amounts we paid to the subcontractor for containerized housing if we should lose the contract dispute with the U.S. government over the validity of the container claims. Those claims are still pending. Second, during the first quarter of 2011, we filed a complaint before the ASBCA to contest the Form 1s and to recover the amounts withheld from us by the U.S. government. At the request of the U.S. government, that complaint was dismissed without prejudice in January 2013 so that the U.S. government could pursue its False Claims Act ("FCA") suit described below. We are free to re-file the complaint in the future. Third, this matter is also the subject of a separate claim filed by the Department of Justice ("DOJ") for alleged violation of the FCA as discussed further below under the heading “Investigations, Qui Tams and Litigation.”

CONCAP III. From February 2009 through September 2010, we received Form 1s from the DCAA disapproving billed costs related to work performed under our CONCAP III contract with the U.S. Navy to provide emergency construction services primarily to U.S. government facilities damaged by Hurricanes Katrina and Wilma. The Form 1 was issued for $25 million in billings. The U.S. government had previously paid $15 million and has withheld payments of $10 million, which as of September 30, 2015 we have recorded as due from the U.S. government related to this matter in "claims and accounts receivable" on our condensed consolidated balance sheets.

In February 2012, the Contracting Officer rendered a Contracting Officer Final Determination (“COFD”) disallowing $15 million of direct costs. We filed an appeal with the ASBCA in June 2012. Trial was held before the ASBCA in September 2014, and post hearing briefs were filed in November 2014. We expect it will take several months before a ruling is issued on this matter. We believe we undertook adequate and reasonable steps to ensure that proper bidding procedures were followed and the amounts billed to the U.S. government were reasonable and not in violation of the Federal Acquisition Regulations ("FAR") and that the ASBCA will rule in our favor. As of September 30, 2015, we have accrued our estimate of probable loss related to an unfavorable settlement of this matter recorded in "other liabilities" on our condensed consolidated balance sheets. At this time, we believe that the likelihood we would incur a loss related to this matter in excess of the amounts we have accrued is remote.

Other. The U.S. government has issued Form 1s for other matters questioning $42 million of billed costs. For these matters, the U.S. government previously paid $40 million and has withheld payment of $2 million, which we have recorded in "claims and accounts receivable" on our condensed consolidated balance sheets. We have accrued our estimate of probable loss in "other liabilities" on our condensed consolidated balance sheets. At this time, we believe that the likelihood we would incur a loss related to this matter in excess of the amounts we have accrued is remote.

We have other matters (not related to Form 1s) in dispute with the U.S. government either in the COFC or before the ASBCA. These claims represent $11 million in claimed costs primarily associated with the pass-through of subcontractor claims associated with a termination for convenience in Iraq. We have accrued $4 million as our estimate of probable loss in "other liabilities" on our condensed consolidated balance sheets. At this time, we believe that the likelihood we would incur a loss related to these matters in excess of the amounts we have accrued is remote.

Audits

In addition to reviews performed by the U.S. government through the Form 1 process, the negotiation, administration and settlement of our contracts which primarily consist of DoD contracts, are subject to audit by the DCAA. The DCAA serves in an

24



advisory role to the DCMA and the DCMA is responsible for the administration of our contracts.  The scope of these audits include, among other things, the validity of incurred costs, provisional approval of annual billing rates, approval of annual overhead rates, compliance with the FAR and Cost Accounting Standards (“CAS”), compliance with certain unique contract clauses and audits of certain aspects of our internal control systems.  We attempt to resolve all issues identified in audit reports by working directly with the DCAA and the Administrative Contracting Officers ("ACOs").

As a result of these audits, there are risks that costs we have claimed as recoverable may be assessed by the U.S. government to be unallowable.  We believe our claims are in compliance with our contract terms.  In some cases, we may not reach agreement with the DCAA or the ACOs regarding potentially unallowable costs which may result in our filing of claims in various courts such as the ASBCA or the COFC.  We have accrued our estimate of potentially unallowable costs using a combination of specific estimates and our settlement rate experience with the U.S. government.  We have received audit reports for both direct and indirect incurred costs for the years 2004 through 2011 and have not received audit reports for 2012 through 2013.  Additionally, we have reached an agreement with the U.S. government on definitive incurred cost rates for the years 2003 through 2010. At September 30, 2015, we have accrued $21 million as our estimate of probable loss as a reduction to "claims and accounts receivable" and in "other liabilities" on our condensed consolidated balance sheets related to open audit.

For those years in which we have received audit reports and negotiated final settlements for both direct and indirect claimed costs, we have experienced an aggregate disallowance rate of approximately 0.1% of such costs. This has been slightly more favorable than the allowances we had previously provided.  For the period 2003 through 2010 we incurred claimed costs of $46 billion. We have reached negotiated settlement on all but $36 million which is still under review and negotiation. In reaching these settlements we have conceded $41 million. For the years 2012 through 2013 we incurred costs of $1 billion that are still under audit.

We only include amounts in revenues related to disputed and potentially unallowable costs when we determine it is probable that such costs will result in the collection of revenues.  We generally do not recognize additional revenues for disputed or potentially unallowable costs for which revenues have been previously reduced until we reach agreement with the ACOs that such costs are allowable.

In addition to audits of our incurred costs, the U.S. government also reviews our compliance with the CAS and the adequacy and compliance of our CAS disclosure statements.  We are working with the U.S. government to resolve several outstanding alleged CAS non-compliance issues.

Investigations, Qui Tams and Litigation

The following matters relate to ongoing litigation or federal investigations involving U.S. government contracts.

First Kuwaiti Trading Company arbitration. In April 2008, First Kuwaiti Trading Company ("FKTC"), one of our LogCAP III subcontractors providing housing containers, filed for arbitration with the American Arbitration Association of all its claims under various LogCAP III subcontracts. FKTC sought damages in the amount of $134 million. After complete hearings on all of FKTC's claims, an arbitration panel awarded $17 million and interest to FKTC for claims involving damages on lost or unreturned vehicles. In addition, we have determined that we owe FKTC $30 million in connection with other subcontracts. We had an agreement with FKTC that no damages will be paid until our counterclaim is decided, but FKTC filed a motion with the arbitration panel to compel KBR to pay all amounts outstanding. We paid FKTC $15 million in the third quarter of 2014, $4 million in the fourth quarter of 2014 and will pay $4 million on pay-when-paid terms. On March 24, 2015, we received a demand letter from FKTC seeking an additional $3 million; however, a formal claim has not been filed in the arbitration. On August 11, 2015, the arbitration panel issued its ruling, denying FKTC’s requests that the Tribunal (i) issue a Final Award, (ii) “set a schedule to consider whether KBR’s contingent claims can be summarily dismissed as a matter of law” and (iii) determine “pre-judgment and post-judgment interest apply to the 2009 Stipulation amounts and that post-judgment interest applies to the 2014 settlement amount." We have accrued amounts we believe are payable to FKTC in "accounts payable" and "other current liabilities" on our condensed consolidated balance sheets.

We believe any cost of litigation or any damages ultimately awarded to FKTC will be billable under the LogCAP III contract. As with all costs that are billed under LogCAP III, these costs would be subject to audit by the DCAA for reasonableness. At this time, we believe that the likelihood we would incur a loss related to this matter in excess of the amounts we have accrued is remote. See the additional legal action with the ASBCA in the container litigation discussed above.

Electrocution litigation. During 2008, a lawsuit was filed against KBR in Pittsburgh, PA, in the Allegheny County Common Pleas Court alleging that the Company was responsible for an electrical incident which resulted in the death of a soldier. This incident occurred at the Radwaniyah Palace Complex near Baghdad, Iraq. It is alleged in the suit that the electrocution incident

25



was caused by improper electrical maintenance or other electrical work. KBR denies that its conduct was the cause of the event and denies legal responsibility. Plaintiffs are claiming unspecified damages for personal injury, death and loss of consortium by the parents. On July 13, 2012, the Court granted our motions to dismiss, concluding that the case is barred by the Political Question Doctrine and preempted by the Combatant Activities Exception to the Federal Tort Claims Act. The plaintiffs appealed to the Third Circuit Court of Appeals. In August 2013, the Third Circuit Court of Appeals issued an opinion reversing the trial court's dismissal and remanding for further discovery and legal rulings. KBR filed a petition for certiorari with the U.S. Supreme Court and on January 20, 2015, the Supreme Court denied certiorari. The case is now before the U.S. District Court for the Western District of Pennsylvania for further action. KBR will continue to pursue all available jurisdictional and other dismissal options. At this time, we believe the likelihood we would incur a loss related to this matter is remote. As of September 30, 2015, no amounts have been accrued.

We believe any costs of litigation and any damages which might be awarded will be billable under the LogCAP III contract. As with all costs that are billed under LogCAP III, these costs would be subject to audit by the DCAA for reasonableness. At this time, we believe that the likelihood we would incur a loss related to this matter is remote.

Burn Pit litigation. From November 2008 through March 2013, KBR was served with over 50 lawsuits in various states alleging exposure to toxic materials resulting from the operation of burn pits in Iraq or Afghanistan in connection with services provided by KBR under the LogCAP III contract. Each lawsuit has multiple named plaintiffs and seeks class certification. The lawsuits primarily allege negligence, willful and wanton conduct, battery, intentional infliction of emotional harm, personal injury and failure to warn of dangerous and toxic exposures which has resulted in alleged illnesses for contractors and soldiers living and working in the bases where the pits were operated. The plaintiffs are claiming unspecified damages. All of the pending cases were removed to Federal Court and have been consolidated for multi-district litigation treatment before the U.S. Federal District Court in Baltimore, Maryland. In February 2013, the Court dismissed the case against KBR, accepting all of KBR's defense claims including the Political Question Doctrine; the Combatant Activities Exception to the Federal Tort Claims Act; and Derivative Sovereign Immunity. The plaintiffs appealed to the Fourth Circuit Court of Appeals on March 27, 2013. On March 6, 2014, the Fourth Circuit Court vacated the order of dismissal and remanded this multi-district litigation for further action, including a ruling on state tort law and its impact upon the "Contractor on the Battlefield" defenses. KBR filed a petition for certiorari with the U.S. Supreme Court and on January 20, 2015, the Supreme Court denied certiorari. The cases are now before the District Court in Baltimore, Maryland for further action in conformity with the Fourth Circuit's ruling. KBR will continue to pursue all available jurisdictional and other dismissal options. At this time, we believe the likelihood that we would incur a loss related to this matter is remote. As of September 30, 2015, no amounts have been accrued.

We believe any costs of litigation and any damages which might be awarded will be billable under the LogCAP III contract. As with all costs that are billed under LogCAP III, these costs would be subject to audit by the DCAA for reasonableness. At this time, we believe that the likelihood we would incur a loss related to this matter is remote.

Sodium Dichromate litigation. From December 2008 through September 2009, five cases were filed in various Federal District Courts against KBR by national guardsmen and other military personnel alleging exposure to sodium dichromate at the Qarmat Ali Water Treatment Plant in Iraq in 2003. The majority of the cases were re-filed and consolidated into two cases, with one pending in the U.S. District Court for the Southern District of Texas and one pending in the U.S. District Court for the District of Oregon.  A single plaintiff case was filed on November 30, 2012 in the District of Oregon Eugene Division. Collectively, the suits represent approximately 170 individual plaintiffs all of which are current and former national guardsmen or British soldiers who claim they were exposed to sodium dichromate while providing security services or escorting KBR employees who were working at the water treatment plant, claim that the defendants knew or should have known that the potentially toxic substance existed and posed a health hazard, and claim that the defendants negligently failed to protect the plaintiffs from exposure.  The plaintiffs are claiming unspecified damages. The U.S. Army Corps of Engineers (“USACE”) was contractually obligated to provide a benign site free of war and environmental hazards before KBR's commencement of work on the site. KBR notified the USACE within two days after discovering the potential sodium dichromate issue and took effective measures to remediate the site.  Services provided by KBR to the USACE were under the direction and control of the military and therefore, KBR believes it has adequate defenses to these claims.  KBR also has asserted the Political Question Doctrine and other U.S. government contractor defenses. Additionally, studies by the U.S. government and others on the effects of exposure to the sodium dichromate contamination at the water treatment plant have found no long term harm to the soldiers.

We believe any costs of litigation and any damages which might be awarded will be billable under the LogCAP III contract. As with all costs that are billed under LogCAP III, these costs would be subject to audit by the DCAA for reasonableness. At this time, we believe that the likelihood we would incur a loss related to this matter is remote.

Texas Proceedings. After an interlocutory appeal under 28 U.S.C. § 1292(b) to the U.S. Court of Appeals for the Fifth Circuit on KBR's motion to dismiss regarding its "Contractor on the Battlefield" defenses, on November 7, 2013 a three judge

26



panel of the Court returned the case to the trial court, holding the interlocutory appeal was improperly granted. We sought review by the entire court on this opinion which was denied. On January 23, 2015, the U.S. District Court for the Southern District of Texas issued several orders dismissing all of the plaintiffs' claims except for intentional infliction of emotional distress. On February 2, 2015, KBR filed a motion for summary judgment on this claim which was denied for procedural reasons. The Plaintiffs' filed their choice of law motion for reconsideration of the judge's dismissal of their negligence claims on March 16, 2015 and we filed our choice of law motion on April 15, 2015. On August 10, 2015, the trial judge issued an order holding Texas law applies to the case, including the intentional infliction of emotional distress claim. The court also vacated the order denying KBR's motion for summary judgment dismissal of the intentional infliction of emotional distress claim and asked the plaintiffs to file a reply, which they did. On October 23, 2015 the court dismissed the remaining intentional infliction of emotional distress claim and issued a final judgment dismissing all of the plaintiffs' claims. At this time, we believe the likelihood that we would incur a loss related to this matter is remote. As of September 30, 2015, no amounts have been accrued.

Oregon Proceedings. On November 2, 2012 in the Oregon case, a jury in the U.S. District Court for the District of Oregon issued a verdict in favor of the plaintiffs on their claims, and awarded them approximately $10 million in actual damages and $75 million in punitive damages. We filed post-verdict motions asking the court to overrule the verdict or order a new trial. On April 26, 2013, the court ruled for plaintiffs on all issues except one, reducing the total damages to $81 million which consists of $6 million in actual damages and $75 million in punitive damages. The court issued a final judgment on May 10, 2013, which was consistent with the previous ruling. KBR appealed the ruling. Our basis for appeal included the trial court's denial of the Political Question Doctrine, the Combat Activities Exception in the Federal Tort Claims Act and improper ruling on personal jurisdiction. On May 14, 2015, the Ninth Circuit issued an order reversing and remanding the case for dismissal or transfer based on a lack of personal jurisdiction over KBR in Oregon. The parties have agreed and requested that the case should be dismissed and refiled in the Southern District of Texas to be consolidated with the case pending in the Texas federal court mentioned above. The plaintiffs also agreed that all prior rulings in the Texas proceedings apply to the Bixby plaintiffs. Our motion for appeal related legal costs against the plaintiffs was denied by the trial court and we are appealing this denial to the Ninth Circuit. We have filed proceedings to enforce our rights to reimbursement and payment of legal costs pursuant to the FAR under the Restore Iraqi Oil ("RIO") contract with the USACE as referenced below. At this time we believe the likelihood that we will ultimately incur a loss related to this matter is remote. As of September 30, 2015, no amounts have been accrued.

COFC/ASBCA Claims. During the period of time since the first litigation was filed against us, we have incurred legal defense costs that we believe are reimbursable under the related U.S. government contract. We have billed for these costs and filed claims to recover the associated costs incurred to date. In late 2012 and early 2013, we filed suits against the U.S. government in the COFC for denying indemnity in the sodium dichromate cases, for reimbursement of legal fees pursuant to our contract with the U.S. government and for breach of contract by the U.S. government for failure to provide a benign site as required by our contract.  The RIO contract required KBR personnel to begin work in Iraq as soon as the invasion began in March 2003. Due to KBR's inability to procure adequate insurance coverage for this work, the Secretary of the Army approved the inclusion of an indemnification provision in the RIO Contract pursuant to Public Law 85-804.

On March 7, 2014, the COFC issued a ruling on the U.S. government's motion dismissing KBR's claims on procedural grounds. The decision did not prohibit us from resubmitting the claims to the contracting officer and we promptly refiled those claims. On April 4, 2014, we submitted a supplemental certified claim to the RIO contracting officer for additional legal fees incurred in defending the sodium dichromate cases. On June 9, 2014, we filed an appeal to the ASBCA due to the contracting officer's failure to issue a final decision on claims totaling approximately $30 million. The USACE filed an answer, denying our claims. We filed a motion for judgment on the pleadings, asking the court to rule in KBR's favor on the 85-804 indemnity clause based on the admissions made by the USACE in its answer. The court has agreed to stay our other claims while we conduct limited discovery on the 85-804 indemnity. On December 23, 2014, we filed a Motion for Partial Summary Judgment asking the ASBCA to find that, based on discovery conducted to date, the sodium dichromate related incidents and litigation are within the definition of the "unusually hazardous risks" language in the 85-804 indemnity agreement. On August 17, 2015, the ASBCA issued an order holding that KBR is entitled to reimbursement of the sodium dichromate legal fees and any resulting judgments pursuant to the 85-804 indemnity agreement. We do not yet know if the government will appeal this ruling. We subsequently filed a motion for summary judgment asking the ASBCA to find that the $30 million in legal fees are reasonable and payable by the government to KBR pursuant to the indemnity agreement.

Qui tams. On the active qui tams of which we are aware, the U.S. government has joined one of them (see DOJ FCA complaint - Iraq Subcontractor below). We believe the likelihood that we would incur a loss in the qui tams the U.S. government has not joined is remote and as of September 30, 2015, no amounts have been accrued. Costs incurred in defending the qui tams cannot be billed to the U.S. government until those matters are successfully resolved in our favor. If successfully resolved, we can bill 80% of the costs to the U.S. government under the controlling provisions of the FAR. As of September 30, 2015, we have incurred $14 million in legal costs to date in defending ourselves in qui tams.


27



Barko qui tam. Relator Harry Barko was a KBR subcontracts administrator in Iraq for a year in 2004/2005. He filed a qui tam lawsuit in June 2005 in the U.S. District Court for the District of Columbia (D.C.), alleging violations of the FCA by KBR and KBR subcontractors Daoud & Partners and Eamar Combined for General Trading and Contracting. The claim was unsealed in March of 2009. Barko alleges that KBR fraudulently charged the U.S. government for the purchase of laundry facilities from Daoud, that KBR paid Daoud for the construction of a substandard man-camp, that Daoud double-billed KBR for labor, that KBR improperly awarded well-drilling subcontracts to Daoud, and that Daoud charged excessive prices for these services and did not satisfactorily complete them. Barko also alleges fraudulent charges arising out of Eamar’s well-drilling services.

Over the last 18 months, we successfully sought review and reversal of the trial court's opinion on KBR's attorney client and work product privileges. After the second reversal, KBR was notified that the case has been transferred to a new District Court Judge. We believe the likelihood that we will incur a loss related to this matter is remote, and therefore as of September 30, 2015 we have not accrued any loss provisions related to this matter.

DOJ False Claims Act complaint - Containers. In November 2012, the DOJ filed a complaint in the U.S. District Court for the Central District of Illinois in Rock Island, IL, related to our settlement of delay claims by our subcontractor, FKTC, in connection with FKTC's provision of living trailers for the bed down mission in Iraq in 2003-2004. The DOJ alleges that KBR knew that FKTC had submitted inflated costs; that KBR did not verify the costs; that FKTC had contractually assumed the risk for the costs which KBR submitted to the U.S. government; that KBR concealed information about FKTC's costs from the U.S. government; that KBR claimed that an adequate price analysis had been done when in fact one had not been done; and that KBR submitted false claims for reimbursement to the U.S. government in connection with FKTC's services during the bed down mission. Our contractual dispute with the Army over this settlement has been ongoing since 2005. We believe these sums were properly billed under our contract with the Army and are not prohibited under the LogCAP III contract. We strongly contend that we followed the law and no fraud was committed. On May 6, 2013, KBR filed a motion to dismiss and in March 2014 the motion to dismiss was denied. We filed our answer on May 2, 2014 and on May 23, 2014 the U.S. government filed a Motion to Strike certain affirmative defenses which was denied. On September 30, 2014, the District Court granted FKTC's motion to dismiss for lack of personal jurisdiction. A scheduling conference was held on December 5, 2014 and we expect discovery be completed in 2016. At this time, we believe the likelihood that we would incur a loss related to this matter is remote. As of September 30, 2015, no amounts have been accrued.

DOJ False Claims Act complaint - Iraq Subcontractor. In January 2014, the DOJ filed a complaint in the U.S. District Court for the Central District of Illinois in Rock Island, IL, against KBR and two former KBR subcontractors alleging that 3 former KBR employees were offered and accepted kickbacks from these subcontractors in exchange for favorable treatment in the award and performance of subcontracts to be awarded during the course of KBR's performance of the LogCAP III contract in Iraq. The complaint alleges that as a result of the kickbacks, we submitted invoices with inflated or unjustified subcontract prices, resulting in alleged violations of the FCA and the Anti-Kickback Act. While the suit is relatively new, the DOJ's investigation dates back to 2004. We self-reported most of the violations and tendered credits to the U.S. government as appropriate. On May 22, 2014, FTKC filed a motion to dismiss which the U.S. government opposed. On April 22, 2014, we filed our answer and in May 2014 the U.S. government filed a Motion to Strike certain affirmative defenses and this motion was granted on March 30, 2015. We do not believe this limits KBR's ability to fully defend all allegations in this matter. As of September 30, 2015, we have accrued our best estimate of probable loss related to an unfavorable settlement of this matter recorded in "other liabilities" on our condensed consolidated balance sheets. At this time, we believe the likelihood that we would incur a loss related to this matter in excess of the amounts we have accrued is remote. Discovery in the case will start this year and likely run well into 2016.

Other Matters

Claims. We have filed claims with the U.S. government related to payments not yet received for costs incurred under various U.S. government contracts. Included in our condensed consolidated balance sheets are claims for costs incurred under various U.S. government contracts totaling $142 million at September 30, 2015. These claims relate to disputed costs and/or contracts where our costs have exceeded the U.S. government's funded value on the task order. We have $124 million of claims primarily from de-obligated funding on certain task orders that were also subject to Form 1s relating to certain DCAA audit issues discussed above.  We believe such disputed costs will be resolved in our favor at which time the U.S. government will be required to obligate funds from appropriations for the year in which resolution occurs. These claims are recorded in "claims and accounts receivable" on our condensed consolidated balance sheets.  The remaining claims balance of $18 million is recorded in "CIE" on our condensed consolidated balance sheets. The amounts recorded in CIE represent costs for which incremental funding is pending in the normal course of business. The claims outstanding at September 30, 2015 are considered to be probable of collection and have been previously recognized as revenues.

On January 21, 2015, we were notified by the U.S. government Defense Security Service ("DSS") Facility Security Office that our facility security clearance had been marked "invalid" based on findings from their recent evaluation of our processes and

28



procedures for inappropriately handling documents provided to KBR by the U.S. Army during the performance of our LogCAP III contract. Due to the invalidation of our facility security clearance, the GS business segment was precluded from bidding on new work for contracts with security requirements.  We were permitted to continue the work we were currently performing and be awarded new task orders under existing contracts; however, no new work could be awarded until this matter was resolved. On March 12, 2015, our facility security clearance was reinstated allowing us to compete for new U.S. government contracts. This matter is now resolved.

Note 12. Other Commitments and Contingencies

Litigation and regulatory matters related to the Company’s restatement of its 2013 annual financial statements
In re KBR, Inc. Securities Litigation. Lead plaintiffs, Arkansas Public Employees Retirement System and Local 58/NECA Funds, seek class action status on behalf of our shareholders, alleging violations of Sections 10(b) and 20(a) of the Securities Exchange Act of 1934 against the Company, our former chief executive officer, our current and former chief financial officers, and our former chief accounting officer, arising out of the restatement of our 2013 annual financial statements, and seek undisclosed damages. The case is currently pending in the U.S. District Court for the Southern District of Texas, Master File No. 14-cv-01287. We filed a motion to dismiss the consolidated complaint for failure to plead particularized facts supporting a strong inference of scienter on the part of the individual defendants and the motion was denied on September 3, 2015. We intend to continue to vigorously defend against these claims. Discovery in the case has begun and is expected to continue into 2016. At this early stage, we are not yet able to determine the likelihood of loss, if any, arising from this matter.

Butorin v. Blount et al, is a shareholder derivative complaint, filed on May 27, 2014 in the U.S. District Court for the Southern District of Texas on behalf of the Company naming certain current and former members of the Company's board of directors as defendants and the Company as a nominal defendant. The complaint alleges that the named directors breached their fiduciary duties by permitting the Company's internal controls to be inadequate. On March 31, 2015, the District Court transferred the case to the U.S. District Court of Delaware. The court has approved a stay of the action pending resolution of the motion to dismiss the security litigation. At this early stage, we are not yet able to determine the likelihood of loss, if any, arising from this matter.
Stella Dupree and Donald Taylor v. KBR, Inc., was filed by shareholders of the Company on May 12, 2015 in Delaware Chancery Court seeking the right to inspect and make copies of certain books and records of the Company under §220 of Delaware General Corporation Law relating primarily to the restatement of our 2013 annual financial statements. The Company has agreed to provide a limited set of documents. After the documents are produced, the matter will be dismissed.
We have also received requests for information and a subpoena for documents from the Securities Exchange Commission ("SEC") regarding the restatement of our 2013 annual financial statements. We have been and intend to continue cooperating with the SEC.

PEMEX and PEP Arbitration

In 1997, we entered into a contract with PEP, a subsidiary of PEMEX, the Mexican national oil company, to build offshore platforms and treatment and reinjection facilities in the Bay of Campeche, offshore Mexico. The project, known as EPC 1, encountered significant schedule delays and increased costs due to problems with design work, late delivery and defects in equipment, increases in scope and other changes.

PEP took possession of the facilities in March 2004 prior to the completion of our scope of work and without paying us for our work. We filed for arbitration with the International Chamber of Commerce ("ICC") in 2004 claiming recovery of damages of approximately $323 million. PEP subsequently filed counterclaims totaling $157 million. In December 2009, the ICC arbitration panel ruled in our favor, and we were awarded a total of approximately $351 million including legal and administrative recovery fees as well as interest. PEP was awarded approximately $6 million on counterclaims plus interest on a portion of that sum. In connection with this award, we recognized a gain of $117 million net of tax in 2009.

U.S. Proceedings. Collection efforts have involved multiple actions. On August 27, 2013, the U.S. District Court for the Southern District of New York entered an order stating it would confirm the award even though it had been annulled in Mexico (see Mexico proceedings discussion below). On September 25, 2013, the District Court entered the signed final judgment of $465 million, which includes the arbitration award and approximately $106 million for performance bonds discussed below, plus interest. The judgment also requires that each party pay value added tax on the amounts each has been ordered to pay. PEP filed a notice of appeal to the U.S. Court of Appeals for the Second Circuit on October 16, 2013 and posted $465 million cash as security for the judgment pending appeal. Oral argument on the appeal was held on November 20, 2014. The U.S. government was invited

29



to file a brief and did so, and the parties have filed responses to the U.S. government's brief. We continue to await the Court's ruling on the matter and while the Court may request additional briefing, there has been no indication it will do so. There has also been no indication as to when a decision will be reached and we are not aware of any factors preventing a decision from being reached. PEMEX and PEP could seek rehearing at the court of appeals and a review by the U.S. Supreme Court. At this time, we are unable to predict the timing of any ruling or resolution concerning this matter.

Mexico Proceedings. PEP's multiple attempts to nullify the award in Mexico were rejected by the Mexican courts. PEP then filed an “amparo” action alleging that its constitutional rights had been violated and this action was denied by the Mexican court in October 2010. PEP then appealed to the Mexican Collegiate Court. In September 2011, the Collegiate Court ruled that PEP, by administratively rescinding the contract in 2004, deprived the arbitration panel of jurisdiction and the award was null and void. We believe the Collegiate Court's decision is contrary to Mexican law governing contract arbitration. However, we do not expect the Collegiate Court's decision to affect our ability to ultimately collect the ICC arbitration award in the U.S. due to the posting of cash as security for the judgment pending appeal.

Other Proceedings. We have initiated collection proceedings to pursue our remedies in Luxembourg. Our efforts to collect under the North American Free Trade Agreement have been denied because of our pending collection efforts in the U.S. proceedings and in Luxembourg.

Performance Bonds

We had provided approximately $80 million in performance bonds to PEP when the project was awarded. The bonds were written by a Mexican bond company and backed by a U.S. insurance company which is indemnified by KBR. As a result of the ICC arbitration award in December 2009, the panel determined that KBR had performed on the project and recovery on the bonds by PEP was precluded.  Notwithstanding, PEP filed an action in Mexico in June 2010 against the Mexican bond company to collect the bonds. On June 17, 2013, after proceedings in multiple Mexican courts, we were required to pay $108 million to the Mexican bond company. The $108 million consists of the $80 million in outstanding bonds, plus $26 million in related interest and other expenses and $2 million in legal and banking fees.

Consistent with our treatment of claims, we have recorded $401 million, net of advances, in "claims and accounts receivable" on the condensed consolidated balance sheets as we believe it is probable we will recover the amounts awarded to us, including interest and expenses and the amounts we paid on the bonds. PEP has cash posted in the U.S. and assets in Luxembourg, which we believe we will be able to attach as a result of the recognition of the ICC arbitration award. Although it is possible we could resolve and collect the amounts due from PEP in the next 12 months, we believe the timing of the collection of the award is uncertain; therefore, consistent with our prior practice, as of September 30, 2015, we continue to classify the amount due from PEP, including the amounts paid on the performance bonds, as long term.


30



Note 13. Shareholders’ Equity

The following tables summarize our activity in shareholders’ equity:
Dollars in millions
Total
 
PIC
 
Retained
Earnings
 
Treasury
Stock
 
AOCL
 
NCI
Balance at December 31, 2014
$
935

 
$
2,091

 
$
439

 
$
(712
)
 
$
(876
)
 
$
(7
)
Acquisition of noncontrolling interest
(40
)
 
(40
)
 

 

 

 

Share-based compensation
14

 
14

 

 

 

 

Common stock issued upon exercise of stock options
1

 
1

 

 

 

 

Dividends declared to shareholders
(35
)
 

 
(35
)
 

 

 

Repurchases of common stock
(22
)
 

 

 
(22
)
 

 

Issuance of ESPP shares
5

 

 

 
5

 

 

Distributions to noncontrolling interests
(21
)
 

 

 

 

 
(21
)
Net income
178

 

 
161

 

 

 
17

Other comprehensive income (loss), net of tax
(41
)
 

 

 

 
(44
)
 
3

Balance at September 30, 2015
$
974

 
$
2,066

 
$
565

 
$
(729
)
 
$
(920
)
 
$
(8
)
 
 
 
 
 
 
 
 
 
 
 
 
Dollars in millions
Total
 
PIC
 
Retained
Earnings
 
Treasury
Stock
 
AOCL
 
NCI
Balance at December 31, 2013
$
2,439

 
$
2,065

 
$
1,748

 
$
(610
)
 
$
(740
)
 
$
(24
)
Share-based compensation
16

 
16

 

 

 

 

Common stock issued upon exercise of stock options
4

 
4

 

 

 

 

Dividends declared to shareholders
(35
)
 

 
(35
)
 

 

 

Repurchases of common stock
(102
)
 

 

 
(102
)
 

 

Issuance of ESPP shares
4

 

 

 
4

 

 

Investments by noncontrolling interests
10

 

 

 

 

 
10

Distributions to noncontrolling interests
(49
)
 

 

 

 

 
(49
)
Net income (loss)
33

 

 
(21
)
 

 

 
54

Other comprehensive income, net of tax
(3
)
 

 

 

 
(4
)
 
1

Balance at September 30, 2014
$
2,317

 
$
2,085

 
$
1,692

 
$
(708
)
 
$
(744
)
 
$
(8
)


Accumulated other comprehensive loss, net of tax
 
September 30,
Dollars in millions
2015
 
2014
Accumulated foreign currency translation adjustments, net of tax of $1 and $(1)
$
(280
)
 
$
(158
)
Pension and post-retirement benefits, net of tax of $(226) and $(214)
(638
)
 
(583
)
Fair value of derivatives, net of tax of $0 and $0
(2
)
 
(3
)
Total accumulated other comprehensive loss
$
(920
)
 
$
(744
)

31




Changes in accumulated other comprehensive loss, net of tax, by component
Dollars in millions
Accumulated foreign currency translation adjustments
 
Accumulated pension liability adjustments
 
Changes in fair value of derivatives
 
Total
Balance at December 31, 2014
$
(203
)
 
$
(670
)
 
$
(3
)
 
$
(876
)
Other comprehensive income adjustments before reclassifications
(77
)
 

 

 
(77
)
Amounts reclassified from accumulated other comprehensive income

 
32

 
1

 
33

Balance at September 30, 2015
$
(280
)
 
$
(638
)
 
$
(2
)
 
$
(920
)

Dollars in millions
Accumulated foreign currency translation adjustments
 
Accumulated pension liability adjustments
 
Changes in fair value of derivatives
 
Total
Balance at December 31, 2013
$
(131
)
 
$
(608
)
 
$
(1
)
 
$
(740
)
Other comprehensive income adjustments before reclassifications
(28
)
 

 
(1
)
 
(29
)
Amounts reclassified from accumulated other comprehensive income
1

 
25

 
(1
)
 
25

Balance at September 30, 2014
$
(158
)
 
$
(583
)
 
$
(3
)
 
$
(744
)


Reclassifications out of accumulated other comprehensive loss, net of tax, by component
 
Nine Months Ended September 30,
 
 
Dollars in millions
2015
 
2014
 
Affected line item on the Condensed Consolidated Statements of Operations
Accumulated pension liability adjustments
 
 
 
 
 
    Amortization of actuarial loss (a)
$
(37
)
 
$
(32
)
 
See (a) below
Tax benefit
5

 
7

 
Provision for income taxes
Net pension and post-retirement benefits
$
(32
)
 
$
(25
)
 
Net of tax
 
(a)
This item is included in the computation of net periodic pension cost. See Note 8 to our condensed consolidated financial statements for further discussion.


32



Note 14. Share Repurchases

Authorized Share Repurchase Program

On February 25, 2014, our Board of Directors authorized a plan to repurchase up to $350 million of our outstanding common shares, which replaced and terminated the August 26, 2011 share repurchase program. The authorization does not obligate the Company to acquire any particular number of common shares and may be commenced, suspended or discontinued without prior notice. The share repurchases are intended to be funded through the Company’s current and future cash and the authorization does not have an expiration date.

Share Maintenance Programs

Stock options and restricted stock awards granted under the KBR Stock and Incentive Plan may be satisfied using shares of our authorized but unissued common stock or our treasury share account.

The Employee Stock Purchase Plan ("ESPP") allows eligible employees to withhold up to 10% of their earnings, subject to some limitations, to purchase shares of KBR common stock. These shares are issued from our treasury share account.

Withheld to Cover Program

In addition to the plans above, we also have in place a "withheld to cover" program, which allows us to withhold ordinary shares from employees in connection with the settlement of income tax and related benefit withholding obligations arising from the issuance of share based equity awards under the KBR Stock and Incentive Plan.

The table below presents information on our share repurchases activity under these programs:
 
Three Months Ended
 
Nine Months Ended
 
September 30, 2015
 
September 30, 2015
 
Number of Shares
 
Average Price per Share
 
Dollars in Millions
 
Number of Shares
 
Average Price per Share
 
Dollars in Millions
Repurchases under the $350 million authorized share repurchase program
250,000

 
$
16.92

 
$
4

 
746,440

 
$
15.72

 
$
12

Repurchases under the existing share maintenance programs

 

 

 
466,974

 
15.43

 
7

Withheld to cover shares
7,868

 
17.85

 

 
163,274

 
16.97

 
3

Total
257,868

 
$
16.94

 
$
4

 
1,376,688

 
$
15.77

 
$
22

 
 
 
 
 
 
 
 
 
 
 
 
 
Three Months Ended
 
Nine Months Ended
 
September 30, 2014
 
September 30, 2014
 
Number of Shares
 
Average Price per Share
 
Dollars in Millions
 
Number of Shares
 
Average Price per Share
 
Dollars in Millions
Repurchases under the $350 million authorized share repurchase program
175,522

 
$
20.78

 
$
4

 
3,149,151

 
$
26.89

 
$
85

Repurchases under the existing share maintenance programs
125,078

 
20.78

 
2

 
587,970

 
26.13

 
15

Withheld to cover shares
6,222

 
22.11

 

 
73,050

 
27.76

 
2

Total
306,822

 
$
20.81

 
$
6

 
3,810,171

 
$
26.79

 
$
102


Note 15. Income (Loss) per Share

Basic income (loss) per share is based upon the weighted average number of common shares outstanding during the period. Dilutive income (loss) per share includes additional common shares that would have been outstanding if potential common shares with a dilutive effect had been issued using the treasury stock method.

A reconciliation of the number of shares used for the basic and diluted income (loss) per share calculations is as follows:

33



 
Three Months Ended
 
Nine Months Ended
 
September 30,
 
September 30,
Shares in millions
2015
 
2014
 
2015
 
2014
Basic weighted average common shares outstanding
144

 
145

 
144

 
145

Stock options and restricted shares

 

 

 

Diluted weighted average common shares outstanding
144

 
145

 
144

 
145


For purposes of applying the two-class method in computing income (loss) per share, there were $0.5 million and $1.4 million net earnings allocated to participating securities, or a negligible amount per share, for the three and nine months ended September 30, 2015, respectively. Net earnings allocated to participating securities for the three and nine months ended September 30, 2014 were $0.2 million and none, respectively. The diluted income (loss) per share calculation did not include 3.6 million antidilutive weighted average shares for the three and nine months ended September 30, 2015. The diluted income (loss) per share calculation did not include 3.4 million and 2.8 million antidilutive weighted average shares for the three and nine months ended September 30, 2014, respectively.

Note 16. Financial Instruments and Risk Management

Foreign currency risk. We conduct business globally in numerous currencies and are therefore exposed to foreign currency fluctuations. We may use derivative instruments to reduce the volatility of earnings and cash flows associated with changes in foreign currency exchange rates. We do not use derivative instruments for speculative trading purposes. We generally utilize foreign exchange forwards and currency option contracts to hedge exposures associated with forecasted future cash flows and to hedge exposures present on our balance sheet.

As of September 30, 2015, the gross notional value of our foreign currency exchange forwards and option contracts used to hedge balance sheet exposures was $56 million, all of which had durations of 33 days or less. We also had approximately $16 million (notional value) of cash flow hedges of up to 27 months in duration.

The fair value of our balance sheet and cash flow hedges included in "other current assets" on our condensed consolidated balance sheets was less than $1 million and $3 million at September 30, 2015 and December 31, 2014, respectively. The fair value of our balance sheet and cash flow hedges included in "other current liabilities" on our condensed consolidated balance sheets is $2 million and $7 million at September 30, 2015 and December 31, 2014, respectively. These fair values of our derivatives are considered Level 2 under ASC 820 - Fair Value Measurement as they are based on quoted prices directly observable in active markets.
The following table summarizes the recognized changes in fair value of our balance sheet hedges offset by remeasurement of balance sheet positions. These amounts are recognized in our condensed consolidated statements of operations for the periods presented. The net of our changes in fair value of hedges and the remeasurement of our assets and liabilities is included in "other non-operating income" on our condensed consolidated statements of operations.
 
September 30,
 
December 31,
Gains (losses) dollars in millions
2015
 
2014
Balance sheet hedges - fair value
$
(37
)
 
$
(47
)
Balance sheet position - remeasurement
49

 
47

Net
$
12

 
$


Note 17. Recent Accounting Pronouncements

On February 18, 2015, the FASB issued ASU No. 2015-02, Consolidation (Topic 810) - Amendments to the Consolidation Analysis. The amendment eliminates the deferral of certain consolidation standards for entities considered to be investment companies and makes changes to both the variable interest model and the voting model. These changes will require re-evaluation of certain entities for consolidation and will require us to revise our documentation regarding the consolidation or deconsolidation of such VIEs. This ASU is effective for annual periods beginning after December 15, 2016 and interim periods within those annual periods. We are in the process of assessing the impact of the adoption of ASU 2015-02 on our financial statements.

On August 27, 2014, the FASB issued ASU No. 2014-15, Presentation of Financial Statements - Going Concern. This ASU provides guidance on management's responsibility to evaluate whether there is substantial doubt about a company's ability to

34



continue as a going concern and about related footnote disclosures. For each reporting period, management will be required to evaluate whether there are conditions or events that raise substantial doubt about a company's ability to continue as a going concern within one year from the date the financial statements are issued. Substantial doubt exists when relevant conditions and events indicate that it is probable that the entity will be unable to meet its obligations as they become due within the time frame specified earlier. This ASU is effective for annual reporting periods beginning after December 15, 2016 and interim periods within those annual periods. The adoption of ASU 2014-15 is not expected to have a material impact on our financial statements.

On May 28, 2014, the FASB issued ASU No. 2014-09, Revenue from Contracts with Customers. This ASU supersedes the revenue recognition requirements in Accounting Standards Codification 605 - Revenue Recognition and most industry-specific guidance throughout the Codification. The standard requires that an entity recognizes revenue to depict the transfer of promised goods or services to customers in an amount that reflects the consideration to which the company expects to be entitled in exchange for those goods or services. This ASU is effective on January 1, 2018 and should be applied retrospectively to each prior reporting period presented or retrospectively with the cumulative effect of initially applying the ASU recognized at the date of initial application. We are in the process of assessing the impact of the adoption of ASU 2014-09 on our financial statements. We have not yet selected a transition method nor have we determined the effect of the standard on our ongoing financial reporting.

35



Item 2. Management’s Discussion and Analysis of Financial Condition and Results of Operations

Introduction

The purpose of management’s discussion and analysis (“MD&A”) is to disclose material changes in our financial condition since the most recent fiscal year-end and results of operations during the current fiscal period as compared to the corresponding period of the preceding fiscal year. The MD&A should be read in conjunction with the condensed consolidated financial statements and accompanying notes and our 2014 Annual Report on Form 10-K.

Executive Overview

Business Reorganization

Following the completion of our strategic review, in December 2014, we reorganized our business into three segments, Technology & Consulting ("T&C"), Engineering & Construction ("E&C") and Government Services ("GS"), in order to focus on core strengths in global hydrocarbons and international government services. Our corporate expenses and other operations that do not individually meet the criteria for group presentation continue to be reported in our Other business segment, while operations we intend to sell or exit upon completion of our existing contracts are presented separately in the Non-strategic Business segment. Each business segment excluding “Other” reflects a reportable segment led by a separate business segment president who reports directly to our chief operating decision maker ("CODM"). We have revised our business segment reporting to reflect our current management approach and recast prior periods to conform to the current business segment presentation. See additional information on our business segments in Note 2 to our condensed consolidated financial statements.

Business Environment

Demand for our services depends primarily on the level of capital expenditure in our market sectors, which is driven generally by global and regional economic growth (primarily GDP growth) and more specifically by the demand for energy and derivative products and government services. While the decline in oil prices is having a near term adverse impact on the global hydrocarbons industry, we continue to see long-term growth in energy projects such as low cost production, shallow water, onshore production, subsea tiebacks and brownfields revamping. Low energy prices reflected in the current oil price provide opportunities in new brownfield liquefied natural gas ("LNG") and new petrochemicals, chemicals and fertilizer markets. We believe KBR has a balanced portfolio of upstream, midstream and downstream projects and recurring revenues in outsourced government services, which we believe provide us with less exposure to the oil price declines than some of our peers.
We expect LNG demand to grow annually mainly in Asia and demand in Europe to rebound. We expect global capacity coming online in the next 15 years to translate to the letting of two new LNG plants per year and we believe growth regions include the United States ("U.S.") Gulf Coast and the Asia-Pacific region, Canada and East Africa.

Three months ended September 30, 2015 compared to the three months ended September 30, 2014

Overview of Financial Results

Our results for the quarter ended September 30, 2015 were significantly improved from the third quarter of 2014 driven by strong operational performance, including a positive earnings contribution from power projects in our Non-strategic Business segment versus more than $30 million in charges taken in the third quarter of 2014. Continued steady progress towards the achievement of our strategic objectives also contributed to our results, including reduced overhead costs and de-risking of the business through the completion or near completion of loss projects.

Our E&C business segment, where we execute large engineering, procurement and construction ("EPC") projects, generated revenues of $828 million and gross profit of $48 million through continued operational performance and successful execution on two mega-LNG projects in Australia. This business segment continues to actively pursue opportunities for LNG, floating LNG ("FLNG"), oil & gas, ammonia and chemicals projects and expects increased growth in services contracts executed by our recently completed Brown & Root Industrial Services joint venture with Bernhard Capital Partners ("BCP"). We have substantially completed work on the seven Canadian pipe fabrication and module assembly projects. One of these projects is a master services-type agreement that provides our client with the right, but not the obligation, to place new pipe fabrication and module assembly orders until 2017. We have not received any new orders under this agreement since 2013. The majority of our Canadian pipe fabrication and module assembly business has now been contributed to a separate third party pipe fabrication entity as part of our minority ownership in that entity.


36



During the quarter, despite being challenged by reduced proprietary equipment sales and professional consulting services, our T&C business segment’s gross profits were relatively equal to the prior year.

Our GS business segment provides support services to the United Kingdom (“U.K.”) Ministry of Defence (“MoD”) related to maintenance of military facilities under multi-year contracts. Our business in support of the U.S. military continues to experience increased activity on the LogCAP IV and other international operating base contracts. However, this business segment continues to be adversely impacted by legal fees associated with LogCAP III and Restore Iraqi Oil (“RIO”) legacy projects executed during the Iraq wars. The GS business segment is well placed in sole source negotiations on two large-scale contracts for the U.K. MoD.

Our Non-strategic Business segment was created as a part of our restructuring initiative and is primarily composed of three EPC power projects, two of which are currently in loss positions. The execution and close out of projects within the Non-strategic segment is the responsibility of our E&C management team. During the third quarter of 2015, one project was completed, while the remaining two projects are scheduled for completion in 2016 and 2017, respectively. During the quarter ended September 30, 2015, this business segment benefited from improved performance and a favorable settlement with a major vendor.

Subsequent Event

Subsequent to September 30, 2015, we reached a definitive agreement for the sale of our U.S. Infrastructure business within the Non-strategic Business segment.

The information below is an analysis of our consolidated results for the three months ended September 30, 2015. See Results of Operations by Business Segment below for additional information describing the performance of each of our reportable segments.
Revenues
Three Months Ended September 30,
 
 
 
 
 
2015 vs. 2014
Dollars in millions
2015
 
2014
 
$
 
%
Revenues
$
1,199

 
$
1,657

 
$
(458
)
 
(28
)%

The decrease in consolidated revenues was primarily due to reduced activity within our E&C business segment from the substantial completion one of the major LNG projects in Australia. The decrease in revenues was also attributable to the completion or substantial completion of several projects in the U.S., Middle East and Canada. These decreases were partially offset by increased work or ramp up on chemicals and ammonia projects in the U.S. and a new oil and gas project in Europe. Our revenues were also impacted by activity within our Non-strategic Business segment, including the elimination of revenues related to the Building Group, which we sold at the end of the second quarter of 2015, and the continued wind-down on two power projects that are nearing completion. In addition, the decline in both proprietary equipment sales and awards of new consulting contracts from upstream oil related projects within our T&C business segment contributed to the decrease.
Gross Profit
Three Months Ended September 30,
 
 
 
 
 
2015 vs. 2014
Dollars in millions
2015
 
2014
 
$
 
%
Gross profit
$
87

 
$
30

 
$
57

 
190
%

The increase in consolidated gross profit was primarily due to the non-recurrence of losses and charges in the third quarter of 2015 that were recognized during the corresponding period of 2014 on projects within our E&C and Non-strategic Business segments. Gross profit was also impacted by the recognition of favorable settlements in the third quarter of 2015 within our Non-strategic Business segment, ongoing execution on base operations and other contracts within our GS business segment and reduced overhead spending within our E&C business segment. This increase was partially offset by the non-recurrence of favorable settlements in the third quarter of 2015 related to dispute resolution activities in our GS segment recognized in the corresponding period of 2014 and reduced activity on the major LNG project discussed above.


37



Equity in Earnings of Unconsolidated Affiliates
Three Months Ended September 30,
 
 
 
 
 
2015 vs. 2014
Dollars in millions
2015
 
2014
 
$
 
%
Equity in earnings of unconsolidated affiliates
$
35

 
$
38

 
$
(3
)
 
(8
)%

The decrease in equity in earnings of unconsolidated affiliates was due to scheduled maintenance spending during the third quarter on a joint venture in our GS business segment that occurred in the fourth quarter of 2014.

General and Administrative Expenses
Three Months Ended September 30,
 
 
 
 
 
2015 vs. 2014
Dollars in millions
2015
 
2014
 
$
 
%
General and administrative expenses
$
(38
)
 
$
(58
)
 
$
(20
)
 
(34
)%

The decrease in general and administrative expenses was primarily due to lower information technology support costs resulting from the cancellation of our enterprise resource planning ("ERP") implementation project in the fourth quarter of 2014, reduced overhead costs resulting from headcount reductions and other cost savings initiatives implemented at the end of 2014 and during 2015. General and administrative expenses in the third quarter of 2015 and 2014 included $27 million and $43 million, respectively, related to corporate activities and $11 million and $15 million, respectively, related to the business segments.

Asset Impairment and Restructuring Charges
Three Months Ended September 30,
 
 
 
 
 
2015 vs. 2014
Dollars in millions
2015
 
2014
 
$
 
%
Asset impairment and restructuring charges
$
(15
)
 
$

 
$
15

 
100
%

Asset impairment and restructuring charges in 2015 are primarily due to costs associated with the termination of leases related to our Canadian fabrication yard and partial impairment of our Canadian ERP assets as a result of the investment in the Brown & Root Industrial Services joint venture and EPIC Piping LLC within our E&C business segment. See Note 7 to our condensed consolidated financial statements for information related to these new investments.

Gain on Disposition of Assets
Three Months Ended June 30,
 
 
 
 
 
2015 vs. 2014
Dollars in millions
2015
 
2014
 
$
 
%
Gain on disposition of assets
$
6

 
$

 
$
6

 
100
%

The gain on disposition of assets primarily reflects the gain recognized on the deconsolidation of our Industrial Services business in our E&C business segment for an interest in the Brown & Root Industrial Services joint venture.

Non-operating Income
Three Months Ended September 30,
  
 
 
 
 
2015 vs. 2014
Dollars in millions
2015
 
2014
 
$
 
%
Non-operating income
$
3

 
$
34

 
$
(31
)
 
(91
)%

Non-operating income includes interest income, interest expense, foreign exchange gains and losses and other non-operating income or expense items. The decrease in non-operating income was primarily due to the gain on a negotiated settlement with our former parent as well as the reversal of associated interest under a tax sharing agreement recognized in 2014 that did not recur in 2015.


38



Benefit (provision) for Income Taxes
Three Months Ended September 30,
  
 
 
 
 
2015 vs. 2014
Dollars in millions
2015
 
2014
 
$
 
%
Income before benefit (provision) for income taxes
$
78

 
$
44

 
$
34

 
77
%
Benefit (provision) for income taxes
$
(19
)
 
$
1

 
$
(20
)
 
n/m

 
n/m - not meaningful

Our provision for income taxes for the quarter ended September 30, 2015 reflects a 24% tax rate. The benefit for income taxes for the quarter ended September 30, 2014 reflects lower income. Additionally, tax expense for the three months ending September 30, 2014 included a $5 million benefit from the settlement of a previously unrecognized tax benefit along with other discrete tax benefits. See an explanation of our effective tax rates for the quarter ended September 30, 2015 in Note 10 to our condensed consolidated financial statements.

Net Income Attributable to Noncontrolling Interests
Three Months Ended September 30,
  
 
 
 
 
2015 vs. 2014
Dollars in millions
2015
 
2014
 
$
 
%
Net income attributable to noncontrolling interests
$
(4
)
 
$
(15
)
 
$
(11
)
 
(73
)%

The decrease in net income attributable to noncontrolling interests was primarily due to additional fees recognized on approved man hours on an LNG project joint venture in Australia in our E&C business segment in 2014 that did not recur in 2015.


39



Results of Operations by Business Segment

We analyze the financial results for each of our five business segments. The business segments presented are consistent with our reportable segments discussed in Note 2 to our condensed consolidated financial statements.

 
Three Months Ended September 30,
Dollars in millions
2015
 
2014
Revenues
 
 
 
Technology & Consulting
$
79

 
$
94

Engineering & Construction
828

 
1,196

Government Services
176

 
178

  Other

 

Subtotal
1,083

 
1,468

Non-strategic Business
116

 
189

Total
$
1,199

 
$
1,657

 
 
 
 
Gross profit (loss)
 
 
 
Technology & Consulting
$
17

 
$
18

Engineering & Construction
48

 
46

Government Services
8

 
24

Other

 

Subtotal
73

 
88

Non-strategic Business
14

 
(58
)
Total
$
87

 
$
30

 
 
 
 
Equity in earnings of unconsolidated affiliates
 
 
 
Technology & Consulting
$

 
$

Engineering & Construction
26

 
26

Government Services
9

 
12

Other

 

Subtotal
35

 
38

Non-strategic Business

 

Total
$
35

 
$
38

 
 
 
 
Total general and administrative expenses
$
(38
)
 
$
(58
)
 
 
 
 
Asset impairment and restructuring charges
$
(15
)
 
$

 
 
 
 
Gain on disposition of assets
$
6

 
$

 
 
 
 
Total operating income
$
75

 
$
10




40



Technology & Consulting

T&C revenues decreased by $15 million, or 16%, to $79 million in the third quarter of 2015 compared to $94 million in the third quarter of 2014 due to a decrease in proprietary equipment sales and other technology and consulting projects primarily for upstream oil projects.

T&C gross profit decreased by $1 million, or 6%, to $17 million in the third quarter of 2015 compared to $18 million in the third quarter of 2014. This decrease was primarily driven by the reduction in activity discussed above.

Engineering & Construction

E&C revenue decreased by $368 million, or 31%, to $828 million in the third quarter of 2015 compared to $1.2 billion in the third quarter of 2014. This decrease was primarily due to reduced activity on one of the major LNG projects in Australia, a petrochemical project in the U.S., an oil and gas project in Europe and a chemical complex in the Middle East. In addition, the substantial completion of construction, EPC, petrochemical, maintenance and pipe fabrication and module assembly projects in the U.S. and Canada contributed to the overall decrease.  This was partially offset by new ammonia and chemicals projects in the U.S. and a new oil and gas project in Europe.

E&C gross profit increased by $2 million, or 4% to $48 million in the third quarter of 2015 compared to $46 million in the third quarter of 2014. This increase was primarily due to the non-recurrence of losses in the third quarter of 2015 recognized on several projects in the U.S. and Canada during the corresponding period of 2014 and reduced spending in the U.S., a reduction in work on a major LNG projects in Australia and increased losses on a petrochemicals project in the third quarter of 2015.

E&C equity in earnings of unconsolidated affiliates remained flat in the third quarter of 2015 compared to the third quarter of 2014, at $26 million and was impacted improved utilization of the marine vessels related to our Mexican offshore maintenance joint venture which were out of service in the same period of 2014 as well as increased earnings on other joint ventures. These increases were offset by reduced earnings on an LNG project joint venture in Australia due to a decline in work.

Government Services

GS revenues decreased by $2 million, or 1%, to $176 million in the third quarter of 2015 compared to $178 million in the third quarter of 2014. This decrease was driven primarily by the reduction in support services due to the scale-back in military operations and reduction in troop numbers on U.K. MoD and North Atlantic Treaty Organization ("NATO") contracts in Afghanistan and the completion of several projects in early 2015. These were partially offset by increased activity on base support and other contracts with the U.S. government.

GS gross profit decreased by $16 million, or 67%, to $8 million in the third quarter of 2015 compared to $24 million in the third quarter of 2014. The decrease in gross profit was attributable to the non-recurrence of favorable settlements in the third quarter of 2015 related to dispute resolution activities compared to the corresponding period in 2014.

GS equity in earnings of unconsolidated affiliates decreased by $3 million, or 25%, to $9 million in the third quarter of 2015 compared to $12 million in the third quarter of 2014 primarily due to regularly scheduled maintenance activity related to joint venture project assets that occurred in the third quarter of 2015 as compared to the fourth quarter of 2014.

Non-strategic Business

Non-strategic Business revenue decreased by $73 million, or 39%, to $116 million in the third quarter of 2015 compared to $189 million in the third quarter of 2014. This decrease was due to the elimination of revenues resulting from the sale of the Building Group in the second quarter of 2015 and the near completion of two power projects and North American construction projects, partially offset by increased activity on a power project in 2015.

Non-strategic Business gross profit increased by $72 million to a profit of $14 million in the third quarter of 2015 compared to a loss of $58 million in the third quarter of 2014. This increase was due to the non-recurrence of charges recognized on a power project in the third quarter of 2014, improved performance and favorable settlements with a vendor in the third quarter of 2015 and overhead savings resulting from the sale of Building Group in the second quarter of 2015. This increase was partially offset by a small loss provision recognized on an infrastructure project in the third quarter of 2015.


41



Changes in Estimates

Information relating to our changes in estimates is discussed in Note 2 to our condensed consolidated financial statements.


Nine months ended September 30, 2015 compared to the nine months ended September 30, 2014

Overview of Financial Results

Our earnings for the nine months ended September 30, 2015 improved from the nine months ended September 30, 2014 driven by our E&C business segment which generated revenues of $2.8 billion and gross profit of $155 million during the nine months ended September 30, 2015. See discussion in the Overview of Financial Results for the quarter ended September 30, 2015 for information related to our Canadian pipe fabrication and module assembly projects.
 
Our T&C business segment results benefited from higher profitability on the mix of projects and a larger number of project milestones achieved during the nine month period.

Our GS business segment continues to be impacted by a reduction in troop numbers and other operations for the U.K. MoD and the U.S. government; however, we are experiencing increased activity in base operations with the U.S. government and other support contracts. Costs from the close out of contracts under the LogCAP III and RIO projects continue to impact our results.

Our Non-strategic Business segment continues to make progress toward completing the three EPC power projects. The sale of Building Group, successful project execution and the non-recurrence of losses and charges that we recognized in the corresponding period of 2014 positively impacted our results.
Prior Period Adjustment
During the second quarter of 2015, we corrected a cumulative error related to transactions between the unconsolidated affiliates associated with our Mexican offshore maintenance joint venture within our E&C business segment. The cumulative error occurred throughout the period beginning in 2007 and through the first quarter of 2015 and resulted in a $15 million favorable impact to "equity in earnings of unconsolidated affiliates" on our condensed consolidated statements of operations during the second quarter. We evaluated the cumulative error on both a quantitative and qualitative basis and determined that the cumulative impact of the error did not affect the trend of net income, cash flows or liquidity and therefore did not have a material impact to previously issued financial statements. Additionally, we do not expect our consolidated financial statements for the current annual period to be materially impacted by the error correction.
The information below is an analysis of our consolidated results for the nine months ended September 30, 2015. See Results of Operations by Business Segment below for additional information describing the performance of each of our reportable segments.
Revenues
Nine Months Ended September 30,
 
 
 
 
 
2015 vs. 2014
Dollars in millions
2015
 
2014
 
$
 
%
Revenues
$
4,016

 
$
4,949

 
$
(933
)
 
(19
)%

The decrease in consolidated revenues was primarily driven by lower activity in the E&C business segment due to the completion or substantial completion of several projects including construction projects in the U.S. and Canada, the Canadian pipe fabrication and maintenance projects, two LNG/Gas to Liquids ("GTL") projects in Africa and a petrochemical project in the U.S. The decrease was also attributable to lower activity on a major LNG project in Australia, an offshore project in Europe and a petrochemical project in the U.S. as these projects continue to wind down. The elimination of revenues related to the second quarter 2015 sale of the Building Group and lower activity on two power projects within our Non-strategic Business segment also contributed to the decrease. In addition, the decrease in revenues was due to lower overall activity associated with our GS business segment's support and logistics contracts for the U.K. government in Afghanistan as well as the decline in both proprietary equipment sales and awards of new consulting contracts within our T&C business segment. These were offset by higher activity on a chemical complex in the Middle East as well as new ammonia and oil and gas projects in the U.S. and Europe, respectively within our E&C business segment.


42



Gross Profit
Nine Months Ended September 30,
 
 
 
 
 
2015 vs. 2014
Dollars in millions
2015
 
2014
 
$
 
%
Gross profit
$
231

 
$
97

 
$
134

 
138
%

The increase in consolidated gross profit was primarily due to the non-recurrence in the third quarter of 2015 of charges recognized in 2014 on certain projects within our Non-strategic Business segment as well as favorable settlements in 2015 compared to losses taken in 2014 related to our Canadian pipe fabrication and module assembly projects within our E&C business segment. Lower overhead costs resulting from reduced headcount and other cost saving initiatives following restructuring efforts beginning at the end of 2014 and during 2015 also contributed to the increase. The increase was partially offset by the impact of reduced activity on a major LNG project in Australia, the favorable settlement of certain claims on this project in 2014 which did not recur in the 2015 both within our E&C business segment as well as lower activity on the support and logistics contracts for the U.K. government in Afghanistan within our GS business segment.

Equity in Earnings of Unconsolidated Affiliates
Nine Months Ended September 30,
 
 
 
 
 
2015 vs. 2014
Dollars in millions
2015
 
2014
 
$
 
%
Equity in earnings of unconsolidated affiliates
$
123

 
$
118

 
$
5

 
4
%

The increase in equity in earnings of unconsolidated affiliates was primarily due to activities within our E&C business segment, including improved utilization of marine vessels in our Mexican offshore maintenance joint venture compared to 2014, and the $15 million adjustment in the second quarter of 2015 as well as increased progress on an LNG project joint venture. This increase was partially offset by the impact of interruptions in the supply of natural gas feedstock to our E&C business segment's ammonia plant joint venture in Egypt as well as the non-recurrence of insurance recovery and reduced costs in 2015 recognized in the corresponding period of 2014 on a joint venture for a U.K. MoD project within our GS business segment.

General and Administrative Expenses
Nine Months Ended September 30,
 
 
 
 
 
2015 vs. 2014
Dollars in millions
2015
 
2014
 
$
 
%
General and administrative expenses
$
(119
)
 
$
(178
)
 
$
(59
)
 
(33
)%

The decrease in general and administrative expenses was primarily due to lower information technology support costs resulting from the cancellation of our ERP implementation project in the fourth quarter of 2014, reduced overhead costs resulting from headcount reductions and other cost savings initiatives implemented at the end of 2014 and during 2015. General and administrative expenses in the nine months ended September 30, 2015 and 2014 included $87 million and $130 million, respectively, related to corporate activities and $32 million and $48 million, respectively, related to the business segments.

Asset Impairment and Restructuring Charges
Nine Months Ended September 30,
 
 
 
 
 
2015 vs. 2014
Dollars in millions
2015
 
2014
 
$
 
%
Asset impairment and restructuring charges
$
(34
)
 
$

 
$
34

 
100
%

Asset impairment and restructuring charges are the result of additional severance costs within our E&C and Non-strategic Business segments related to the workforce reduction efforts during 2015 in addition to those recognized in the last quarter of 2014. Included in this amount is $20 million related to early termination of leases, impairment of associated leasehold improvements and other long-lived assets within our E&C and Other business segments.


43



Gain on Disposition of Assets
Nine Months Ended September 30,
 
 
 
 
 
2015 vs. 2014
Dollars in millions
2015
 
2014
 
$
 
%
Gain on disposition of assets
$
34

 
$
8

 
$
26

 
n/m

Gain on disposition of assets reflects the $28 million gain recognized in the second quarter of 2015, net a $1 million adjustment in the third quarter of 2015, on the sale of the Building Group subsidiary within our Non-strategic Business segment. In addition we recognized a $7 million gain on the deconsolidation of our Industrial Services business in our E&C business segment for an interest in the Brown & Root Industrial Services joint venture in the third quarter of 2015.

Non-operating Income
Nine Months Ended September 30,
 
 
 
 
 
2015 vs. 2014
Dollars in millions
2015
 
2014
 
$
 
%
Non-operating income
$
4

 
$
18

 
$
(14
)
 
(78
)%

Non-operating income includes interest income, interest expense, foreign exchange gains and losses and other non-operating income or expense items. The decrease in income was primarily due to a gain on a negotiated settlement with our former parent as well as the reversal of associated interest pursuant to the terms of a tax sharing agreement in 2014 that did not recur in 2015. Also contributing to operating income were foreign exchange gains in 2015 due to the strengthening of the U.S. dollar against the majority of our foreign currencies compared to losses in 2014.

Provision for Income Taxes
Nine Months Ended September 30,
 
 
 
 
 
2015 vs. 2014
Dollars in millions
2015
 
2014
 
$
 
%
Income before provision for income taxes
$
239

 
$
63

 
$
176

 
n/m

Provision for income taxes
$
(61
)
 
$
(30
)
 
$
31

 
103
%
 
n/m - not meaningful

Our provision for income taxes for the nine months ended September 30, 2015 reflects a 26% tax rate. The provision for income taxes for nine months ended September 30, 2014 reflects lower income but was offset by an increase in our valuation allowance associated with losses recognized on our Canadian pipe fabrication and assembly projects. See an explanation of our effective tax rates for the nine months ended September 30, 2015 in Note 10 to our condensed consolidated financial statements.

Net Income Attributable to Noncontrolling Interests
Nine Months Ended September 30,
  
 
 
 
 
2015 vs. 2014
Dollars in millions
2015
 
2014
 
$
 
%
Net income attributable to noncontrolling interests
$
(17
)
 
$
(54
)
 
$
(37
)
 
(69
)%

The decrease in net income attributable to noncontrolling interests was primarily due to additional fees recognized on approved man hours on an LNG project joint venture in Australia in our E&C business segment in 2014 that did not recur in 2015.


44



Results of Operations by Business Segment

We analyze the financial results for each of our five business segments. The business segments presented are consistent with our reportable segments discussed in Note 2 to our condensed consolidated financial statements.

 
Nine Months Ended September 30,
Dollars in millions
2015
 
2014
Revenues
 
 
 
Technology & Consulting
$
231

 
$
285

Engineering & Construction
2,758

 
3,546

Government Services
489

 
527

  Other

 

Subtotal
3,478

 
4,358

Non-strategic Business
538

 
591

Total
$
4,016

 
$
4,949

 
 
 
 
Gross profit (loss)
 
 
 
Technology & Consulting
$
57

 
$
48

Engineering & Construction
155

 
108

Government Services
3

 
28

Other

 

Subtotal
215

 
184

Non-strategic Business
16

 
(87
)
Total
$
231

 
$
97

 
 
 
 
Equity in earnings of unconsolidated affiliates
 
 
 
Technology & Consulting
$

 
$

Engineering & Construction
87

 
63

Government Services
36

 
55

Other

 

Subtotal
123

 
118

Non-strategic Business

 

Total
$
123

 
$
118

 
 
 
 
Total general and administrative expenses
$
(119
)
 
$
(178
)
 
 
 
 
Asset impairment and restructuring charges
$
(34
)
 
$

 
 
 
 
Gain on disposition of assets
$
34

 
$
8

 
 
 
 
Total operating income
$
235

 
$
45




45



Technology & Consulting

T&C revenues decreased by $54 million, or 19%, to $231 million in the nine months ended September 30, 2015 compared to $285 million in the same period of the prior year due to a decrease in proprietary equipment sales offset partially by an increase related to several petrochemicals, ammonia and refining projects.

T&C gross profit increased by $9 million, or 19%, to $57 million in the nine months ended September 30, 2015 compared to $48 million in the same period of the prior year primarily due to higher profitability on the mix of projects executed, a larger number of license milestones achieved and significant overhead reductions during the nine months ended September 30, 2015.

Engineering & Construction

E&C revenue decreased by $788 million, or 22%, to $2.8 billion in the nine months ended September 30, 2015 compared to $3.5 billion in the nine months ended September 30, 2014. This decrease was primarily due to reduced activity on a major LNG project in Australia, an oil and gas project in Europe and a petrochemical project in the U.S. This decrease was also attributable to lower activity resulting from the substantial completion of construction, EPC, petrochemical, maintenance and pipe fabrication and module assembly projects in the U.S. and Canada as well as LNG/GTL projects in Africa. This decrease was partially offset by increased project management activity on a chemical complex in the Middle East, new ammonia projects in the U.S., a new FLNG project in Africa and a new offshore platform in the Middle East.

E&C gross profit increased by $47 million, or 44%, to $155 million in the nine months ended September 30, 2015 compared to $108 million in the nine months ended September 30, 2014. This increase was due to profits resulting from negotiated settlements on our Canadian pipe fabrication and module assembly projects in the nine months ended September 30, 2015 compared to losses associated with these projects during the same period in 2014. Increased project management activity for a chemical complex in the Middle East as well as cost reductions in divisional overheads achieved during the nine months ended September 30, 2015 also contributed to this improvement. The increase was partially offset by the decline in work on one of the LNG projects in Australia, the net favorable settlement of certain claims on an LNG project in Africa that did not recur in the nine months ended September 30, 2015 as well as reduced activity on a petrochemical project in the U.S.

E&C equity in earnings of unconsolidated affiliates increased by $24 million, or 38%, to $87 million in the nine months ended September 30, 2015 compared to $63 million in the nine months ended September 30, 2014. The increase was due to increased earnings on our offshore maintenance joint venture in Mexico due to improved utilization of vessels, which were in dry dock during the same period of the prior year, and the $15 million adjustment in the second quarter of 2015, as well as increased progress on an LNG project joint venture in Australia. The increase was partially offset by reduced earnings from our ammonia plant joint venture in Egypt due to the limited availability of natural gas feedstock.

Government Services

GS revenues decreased by $38 million, or 7%, to $489 million in the nine months ended September 30, 2015 compared to $527 million in the same period in the prior year. This decrease was driven primarily by the reduction in support services due to the scale-back in military operations and reduction in troop numbers on U.K. MoD and NATO contracts in Afghanistan and the substantial completion of several projects in the first quarter of 2014 and early 2015. This decrease was offset by increased activity from new work or expansion in existing U.S. government contracts as well as the favorable settlement of disputes with the U.S. government on some of our legacy projects.

GS gross profit decreased by $25 million, or 89%, to $3 million in the nine months ended September 30, 2015 compared $28 million in the same period in the prior year. This decrease was primarily driven by the reduction in U.K. MoD support activities, the completion of projects discussed above and the recognition of $13 million in legal fees related to U.S. government legacy contracts during the nine months ended September 30, 2015. This decrease was partially offset by increased activity and favorable settlement with the U.S. government, also discussed above.

GS equity in earnings of unconsolidated affiliates decreased by $19 million, or 35%, to $36 million in the nine months ended September 30, 2015 compared to $55 million in the same period in the prior year. This decrease was driven primarily by insurance recovery and reduced costs on a joint venture for a U.K. MoD project in the prior year as well as regularly scheduled maintenance costs that occurred in the third quarter of 2015 as compared to the fourth quarter of 2014 related to joint venture project assets.

46



Non-strategic Business

Non-strategic Business revenue decreased by $53 million, or 9%, to $538 million in the nine months ended September 30, 2015 compared to $591 million in the nine months ended September 30, 2014. This decrease was due to the sale of Building Group in the second quarter of 2015 and the near completion of several power and construction projects and was offset by increased activity on power and infrastructure projects that began in the second half of 2014.

Non-strategic Business gross profit increased by $103 million to a profit of $16 million in the nine months ended September 30, 2015 compared to a loss of $87 million in the nine months ended September 30, 2014. This increase was due to the non-recurrence of charges recognized during 2014 on a power project, improved performance and favorable settlements on power projects in the third quarter of 2015 as well as overhead savings resulting from headcount reductions which began in late 2014.

Changes in Estimates

Information relating to our changes in estimates is discussed in Note 2 to our condensed consolidated financial statements.

Backlog of Unfilled Orders

Backlog generally represents the dollar amount of revenues we expect to realize in the future as a result of performing work on contracts and our pro-rata share of work to be performed by unconsolidated joint ventures. We generally include total expected revenues in backlog when a contract is awarded under a legally binding commitment. In many instances, arrangements included in backlog are complex, nonrepetitive and may fluctuate depending on estimated revenues and contract duration. Where contract duration is indefinite and clients can terminate for convenience at any time without having to compensate us for periods beyond the date of termination, projects included in backlog are limited to the estimated amount of expected revenues within the following twelve months. Certain contracts provide maximum dollar limits, with actual authorization to perform work under the contract agreed upon on a periodic basis with the customer. In these arrangements, only the amounts authorized are included in backlog. For projects where we act solely in a project management capacity, we only include the value of our services of each project in backlog. Previously, for long term contracts associated with the U.K. government's privately financed initiatives or projects (“PFIs”), the amount included in backlog was limited to five years. Effective in the second quarter of 2015, we modified our backlog policy and now record the estimated value of all work forecast to be performed under the PFI contracts. The reason for the change is that under these PFI contracts, the client is obligated to pay us certain amounts spanning periods beyond five years even if the client terminates the contracts for convenience. Also, recording the full value of PFIs into backlog is a relatively common industry practice. This change only relates to backlog of unfilled orders and does not alter our longstanding policies for revenue recognition; therefore, it has no impact on our financial statements. The $5 billion included in the change in policy column below represents our estimate of revenues related to payment obligations for periods beyond five years.

We have included in the table below our proportionate share of unconsolidated joint ventures' estimated revenues. However, because these projects are accounted for under the equity method, only our share of future earnings from these projects will be recorded in our results of operations. Our backlog for projects related to unconsolidated joint ventures totaled $9.1 billion, including the PFI change discussed above, at September 30, 2015 and $4.3 billion at December 31, 2014. We consolidate joint ventures which are majority-owned and controlled or are variable interest entities ("VIEs") in which we are the primary beneficiary. Our backlog included in the table below for projects related to consolidated joint ventures with noncontrolling interests includes 100% of the backlog associated with those joint ventures and totaled $423 million at September 30, 2015 and $928 million at December 31, 2014. Backlog attributable to unfunded government orders was none at September 30, 2015 and $36 million at December 31, 2014. The following table summarizes our backlog by business segment.


47



 
December 31,
 
 
 
Change in
 
Changes in scope on existing contracts (a)
 
Net Workoff (b)
 
September 30,
Dollars in millions
2014
 
New Awards
 
Policy (c)
 
 
 
2015
Technology & Consulting
$
400

 
$
231

 

 
$
23

 
$
(231
)
 
$
423

Engineering & Construction
7,788

 
1,335

 

 
(537
)
 
(2,846
)
 
5,740

Government Services
1,763

 
124

 
5,358

 
63

 
(525
)
 
6,783

Subtotal
9,951

 
1,690

 
5,358

 
(451
)
 
(3,602
)
 
12,946

Non-strategic Business
908

 
49

 

 
(66
)
 
(537
)
 
354

Total backlog
$
10,859

 
$
1,739

 
$
5,358

 
$
(517
)
 
$
(4,139
)
 
$
13,300

 
(a)
In addition to changes in scope, these amounts reflect the elimination of our proportionate share of non-partner costs related to our unconsolidated joint ventures and adjustments for changes in foreign exchange rates.
(b)
These amounts include the workoff of our projects as well as our proportionate share of the workoff of our unconsolidated joint ventures' projects.
(c)
Change in policy was implemented in the second quarter of 2015.

We estimate that as of September 30, 2015, 35% of our backlog will be executed within one year. As of September 30, 2015, 67% of our backlog was attributable to fixed-price contracts, including 47% related to our PFI contracts, and 33% of our backlog was attributable to cost-reimbursable contracts. For contracts that contain both fixed-price and cost-reimbursable components, we classify the individual components as either fixed-price or cost-reimbursable according to the composition of the contract; however, for smaller contracts, we characterize the entire contract based on the predominant component.

Liquidity and Capital Resources

Cash and equivalents totaled $768 million at September 30, 2015 and $970 million at December 31, 2014 and consisted of the following:
 
September 30,
 
December 31,
Dollars in millions
2015
 
2014
Domestic U.S. cash
$
304

 
$
200

International cash
395

 
690

Joint venture cash
69

 
80

Total
$
768

 
$
970


Domestic cash relates to cash balances held by U.S. entities and is largely used to support obligations of those businesses as well as general corporate needs such as the payment of dividends to shareholders and potential repurchases of our outstanding common stock.

The international cash balances may be available for general corporate purposes but are subject to local restrictions, such as capital adequacy requirements and local obligations, such as maintaining sufficient cash balances to support our underfunded U.K. pension plan and other obligations incurred in the normal course of business by those foreign entities. Repatriated foreign cash may become subject to U.S. income taxes. In December 2014, we implemented a foreign cash repatriation strategy for which we have provided cumulative income taxes on certain foreign earnings.

Joint venture cash balances reflect the amounts held by joint venture entities that we consolidate for financial reporting purposes. Such amounts are limited to joint venture activities and are not readily available for general corporate purposes but portions of such amounts may become available to us in the future should there be distribution of dividends to the joint venture partners. We expect that the majority of the joint venture cash balances will be utilized for the corresponding joint venture projects.

Cash generated from operations is our primary source of operating liquidity. Our cash balances are held in numerous locations throughout the world. We believe that existing cash balances and internally generated cash flows are sufficient to support our day-to-day domestic and foreign business operations for at least the next 12 months.

Our operating cash flow can vary significantly from year to year and is affected by the mix, terms and percentage of completion of our engineering and construction projects. We sometimes receive cash through billings to our customers on our larger engineering and construction projects and those of our consolidated joint ventures in advance of incurring the related costs.

48



In other projects our net investment in the project costs may be greater than available project cash and we may utilize other cash on hand or availability under our Credit Agreement to satisfy any periodic operating cash requirements.

Engineering and construction projects generally require us to provide credit support for our performance obligations to our customers in the form of letters of credit, surety bonds or guarantees. Our ability to obtain new project awards in the future may be dependent on our ability to maintain or increase our letter of credit and surety bonding capacity, which may be further dependent on the timely release of existing letters of credit and surety bonds. As the need for credit support arises, letters of credit will be issued under our Credit Agreement or arranged with our banks on a bilateral, syndicated or other basis. We believe we have adequate letter of credit capacity under our existing Credit Agreement and bilateral lines, as well as adequate surety bond capacity under our existing lines to support our operations and current backlog for the next 12 months.

As of September 30, 2015, substantially all of our excess cash was held in commercial bank time deposits or interest bearing short-term investment accounts with the primary objectives of preserving capital and maintaining liquidity.

Cash flows activities summary
 
 
 
 
Nine Months Ended September 30,
Dollars in millions
2015
 
2014
Cash flows provided by (used in) operating activities
$
(85
)
 
$
178

Cash flows provided by (used in) investing activities
48

 
(37
)
Cash flows used in financing activities
(128
)
 
(178
)
Effect of exchange rate changes on cash
(37
)
 
(21
)
Decrease in cash and equivalents
$
(202
)
 
$
(58
)

Operating activities. Cash used in operations totaled $85 million in the first nine months in 2015 and resulted from changes in our working capital accounts, which includes $100 million to fund loss projects, partially offset by distributions of earnings received from our unconsolidated affiliates of $84 million. In addition, we used $40 million for net settlement of foreign exchange derivative hedging contracts and contributed $37 million to our pension funds.

Cash provided by operations totaled $178 million in the first nine months in 2014 and was primarily attributable to fluctuations in our working capital accounts as well as distributions of earnings received from our unconsolidated affiliates of $212 million. This increase in cash was partially offset by contributions of $37 million to our pension funds.

Investing activities. Cash provided by investing activities totaled $48 million in the first nine months in 2015 and was primarily due to $71 million in proceeds from the sale of assets or investments. This increase was partially offset by a payment of $15 million to acquire an investment in a partnership.

Cash used in investing activities totaled $37 million in the first nine months in 2014 and was primarily due to purchases of equipment associated with information technology projects which have now largely been stopped.

Financing activities. Cash used in financing activities totaled $128 million in the first nine months in 2015 and included $40 million for our purchase of the noncontrolling interest in a joint venture, $22 million for the purchase of treasury stock, $35 million for dividend payments to common shareholders, $21 million for distributions to noncontrolling interests, $7 million for principal payments on short-term and long-term borrowings consisting primarily of nonrecourse debt of our Fasttrax VIE and $4 million for other financing expenditures.

Cash used in financing activities totaled $178 million in the first nine months in 2014 and included $102 million for the purchase of treasury stock, $35 million for dividend payments to common shareholders, $49 million for distributions to noncontrolling interests and $7 million for principal payments on short-term and long-term borrowings consisting primarily of nonrecourse debt of our Fasttrax VIE. The uses of cash were partially offset by $10 million of investments from noncontrolling interests and $4 million of proceeds from the exercise of stock options.

Future sources of cash. Future sources of cash include cash flows from operations, cash derived from working capital management, sales of non-strategic and other businesses and cash borrowings under our Credit Agreement as well as potential litigation proceeds.


49



Future uses of cash. Future uses of cash will primarily relate to working capital requirements, capital expenditures, dividends, share repurchases and strategic investments. In addition, we will use cash to fund pension obligations, payments under operating leases and various other obligations, including potential litigation payments, as they arise. Our capital expenditures will be focused primarily on facilities and equipment to support our businesses.

Other factors potentially affecting liquidity

Power project losses. Our reserve for estimated losses on uncompleted contracts included in "other current liabilities" on our condensed consolidated balance sheets consists of $41 million primarily related to a power project at September 30, 2015. These accrued losses will result in future cash expenditures in excess of customer receipts. Based on current contracts and work authorizations, we anticipate completion of this project in 2017. See Note 2 to our condensed consolidated financial statements for more information related to changes in estimates.

Credit Agreement

On September 25, 2015, we entered into a new $1 billion, unsecured revolving credit agreement (the “Credit Agreement”) with a syndicate of banks replacing the previous agreement which was scheduled to mature in December 2016. The Credit Agreement is guaranteed by certain of the Company's domestic subsidiaries, matures in September 2020 and is available for cash borrowings and the issuance of letters of credit related to general corporate needs. Subject to certain conditions, we may request (i) that the aggregate commitments under the Credit Agreement be increased by up to an additional $500 million, and (ii) that maturity of the Credit Agreement be extended by two additional one-year terms.
  
Amounts drawn under the Credit Agreement will bear interest at variable rates, per annum, based either on (i) the London interbank offered rate (“LIBOR”) plus an applicable margin of 1.375% to 1.75%, or (ii) a base rate plus an applicable margin of 0.375% to 0.75%, with the base rate equal to the highest of (a) reference bank’s publicly announced base rate, (b) the Federal Funds Rate plus 0.5%, or (c) LIBOR plus 1%. The amount of the applicable margin to be applied will be determined by the Company’s ratio of consolidated debt to consolidated EBITDA for the prior four fiscal quarters, except for the period ended September 30, 2015, for which the prior three fiscal quarters are utilized, as defined in the Credit Agreement. The Credit Agreement provides for fees on letters of credit issued under the Credit Agreement at a rate equal to the applicable margin for LIBOR-based loans, except for performance letters of credit, which are priced at 50% of such applicable margin. KBR pays an annual issuance fee of 0.125% of the face amount of a letter of credit and pays a commitment fee of 0.225% to 0.25%, per annum, on any unused portion of the commitment under the Credit Agreement based on the Company's consolidated leverage ratio. As of September 30, 2015, there were $130 million in letters of credit and no cash borrowings outstanding.

The Credit Agreement contains customary covenants, as defined in the Credit Agreement, which include financial covenants requiring maintenance of a ratio of consolidated debt to consolidated EBITDA not greater than 3.5 to 1 and a minimum consolidated net worth of $1.2 billion plus 50% of consolidated net income for each quarter beginning September 30, 2015 and 100% of any increase in shareholders’ equity attributable to the sale of equity interests. As of September 30, 2015, we were in compliance with our financial covenants.

The Credit Agreement contains a number of other covenants restricting, among other things, our ability to incur additional liens and indebtedness, enter into asset sales, repurchase our equity shares and make certain types of investments. Our subsidiaries are restricted from incurring indebtedness, except if such indebtedness relates to purchase money obligations, capitalized leases, refinancing or renewals secured by liens upon or in property acquired, constructed or improved in an aggregate principal amount not to exceed $200 million outstanding at any time. Additionally, our subsidiaries may incur unsecured indebtedness not to exceed $200 million in aggregate outstanding principal amount at any time. We are also permitted to repurchase our equity shares, provided that no such repurchases shall be made from proceeds borrowed under the Credit Agreement, and that the aggregate purchase price and dividends paid after September 25, 2015, does not exceed the Distribution Cap (equal to the sum of $750 million plus the lesser of (1) $400 million and (2) the amount received by us in connection with the arbitration and subsequent litigation of the PEP contracts as discussed in Note 12 to our condensed consolidated financial statements). At September 30, 2015, the remaining availability under the Distribution Cap was approximately $750 million.

Nonrecourse Project Finance Debt

Information relating to our nonrecourse project debt is described in Note 9 to our condensed consolidated financial statements.


50



Off-Balance Sheet Arrangements

Letters of credit, surety bonds and guarantees. In connection with certain projects, we are required to provide letters of credit, surety bonds or guarantees to our customers. Letters of credit are provided to certain customers and counterparties in the ordinary course of business as credit support for contractual performance guarantees, advanced payments received from customers and future funding commitments. We have approximately $2.1 billion in committed and uncommitted lines of credit to support the issuance of letters of credit and as of September 30, 2015, we have utilized $530 million of our present capacity under lines of credit. Surety bonds are also posted under the terms of certain contracts to guarantee our performance. The letters of credit outstanding included $130 million issued under our Credit Agreement and $400 million issued under uncommitted bank lines as of September 30, 2015. Of the letters of credit outstanding under our Credit Agreement, none have expiry dates beyond the maturity date of the Credit Agreement. Of the total letters of credit outstanding, $237 million relate to our joint venture operations where the letters of credit are posted using our capacity to support our pro-rata share of obligations under various contracts executed by joint ventures of which we are a member. As the need arises, future projects will be supported by letters of credit issued under our Credit Agreement or other lines of credit arranged on a bilateral, syndicated or other basis. We believe we have adequate letter of credit capacity under our Credit Agreement and bilateral lines of credit to support our operations for the next 12 months.

Transactions with Joint Ventures

We perform many of our projects through incorporated and unincorporated joint ventures. In addition to participating as a joint venture partner, we often provide engineering, procurement, construction, operations or maintenance services to the joint venture as a subcontractor. Where we provide services to a joint venture that we control and therefore consolidate for financial reporting purposes, we eliminate intercompany revenues and expenses on such transactions. In situations where we account for our interest in the joint venture under the equity method of accounting, we do not eliminate any portion of our revenues or expenses. We recognize the profit on our services provided to joint ventures that we consolidate and joint ventures that we record under the equity method of accounting primarily using the percentage-of-completion method. See Note 7 to our condensed consolidated financial statements for more information.

Legal Proceedings

Information relating to various commitments and contingencies is described in Notes 11 and 12 to our condensed consolidated financial statements.

Item 3. Quantitative and Qualitative Disclosures about Market Risk

We invest excess cash and equivalents in short-term securities, primarily time deposits, which carry a fixed rate of return for a given duration of time. Additionally, a substantial portion of our cash balances are maintained in foreign countries.

We are exposed to market risk associated with changes in foreign currency exchange rates, which may adversely affect our results of operations and financial condition.

We are exposed to and use derivative instruments, such as foreign exchange forward contracts and options to hedge foreign currency risk related to non-functional currency assets and liabilities on our balance sheet. Each period, these balance sheet hedges are marked to market through earnings and the change in their fair value is offset by remeasurement of the underlying assets and liabilities. See Note 16 to our condensed consolidated financial statements for more information.


51



Item 4. Controls and Procedures

In accordance with the Securities Exchange Act of 1934 Rules 13a-15 and 15d-15, as amended (the "Exchange Act"), we carried out an evaluation, under the supervision and with the participation of management, including our Chief Executive Officer and Chief Financial Officer, of the effectiveness of our disclosure controls and procedures as of the end of the period covered by this report. Based on that evaluation, our Chief Executive Officer and Chief Financial Officer concluded that our disclosure controls and procedures were effective as of September 30, 2015 to provide reasonable assurance that information required to be disclosed in our reports filed or submitted under the Exchange Act is recorded, processed, summarized, and reported within the time periods specified in the Securities and Exchange Commission’s rules and forms. Our disclosure controls and procedures include controls and procedures designed to ensure that information required to be disclosed in reports filed or submitted under the Exchange Act is accumulated and communicated to our management, including our Chief Executive Officer and Chief Financial Officer, as appropriate, to allow timely decisions regarding required disclosure.

During the three months ended September 30, 2015, there have been no changes in our internal controls over financial reporting that have materially affected, or are reasonably likely to materially affect, our internal controls over financial reporting.


52



PART II. OTHER INFORMATION

Item 1.Legal Proceedings

Information relating to various commitments and contingencies is described in Notes 11 and 12 to our condensed consolidated financial statements in Part I, Item 1 of this quarterly report, and the information discussed therein is incorporated herein.

Item 1A. Risk Factors

We have updated certain risk factors affecting our business since those presented in our Annual Report on Form 10-K, Part I, Item 1A, for the fiscal year ended December 31, 2014. Except for the risk factors updated, there have been no material changes in our assessment of our risk factors from those set forth in our Annual Report on Form 10-K, which is incorporated herein by reference, for the year ended December 31, 2014. Our updated risk factors are included below.

Risks Related to Operations of our Business

A portion of our revenues is generated by large, recurring business from certain significant customers. A loss, cancellation or delay in projects by our significant customers in the future could negatively affect our revenues.

While we provide services to a diverse customer base, including international and national oil and gas companies, independent refiners, petrochemical producers, fertilizer producers and domestic and foreign governments, a considerable percentage of our revenues, particularly in our E&C business segment, is generated from transactions with certain significant customers. Revenues from Chevron represented 11% of our total consolidated revenues for the nine months ended September 30, 2015. The loss of our significant customers, or the cancellation or delay in their projects, could adversely affect our revenues and results of operations.

Item 2.Unregistered Sales of Equity Securities and Use of Proceeds

(a)    None.

(b)    None.

(c)    On February 25, 2014, our Board of Directors authorized a $350 million share repurchase program, which replaced and terminated the August 26, 2011 share repurchase program. The authorization does not specify an expiration date for the share repurchase program. The following is a summary of share repurchases of our common stock settled during the three months ended September 30, 2015.
Purchase Period
Total Number
of Shares
Purchased (1)
 
Average
Price Paid
per Share
 
Total Number  of
Shares  Purchased
as Part of  Publicly
Announced Plan
 
Dollar Value of Maximum Number of Shares that May Yet Be
Purchased Under the Plan
July 1 – 31, 2015
2,501

 
$
18.78

 

 
$
252,684,816

August 3 – 31, 2015
254,695

 
$
16.93

 
250,000

 
$
248,455,904

September 1 – 30, 2015
672

 
$
16.94

 

 
$
248,455,904

  

(1)
Shares repurchased in August include 4,695 shares at an average price of $17.48 acquired from employees in connection with the settlement of income tax and related benefit withholding obligations arising from issuance of share based equity awards under the KBR Stock and Incentive Plan. Total shares acquired from employees during the three months ended of September 30, 2015 was 7,868 shares at an average price of $17.85 per share.

53



Item 6. Exhibits
Exhibit
Number
 
Description
 
 
 
3.1
 
KBR Amended and Restated Certificate of Incorporation (incorporated by reference to Exhibit 3.1 to KBR’s current report on Form 8-K filed June 7, 2012; File No. 1-33146)
 
 
 
3.2
 
Amended and Restated Bylaws of KBR, Inc. (incorporated by reference to Exhibit 3.2 to KBR’s annual report on Form 10-K for the year ended December 31, 2013 filed on February 27, 2014; File No. 1-33146)
 
 
 
10.1
 
Amended and Restated Revolving Credit Agreement dated as of September 25, 2015 among KBR, Inc., the Banks party thereto, Citibank, N.A., as Administrative Agent, Bank of America, N.A., ING Bank, N.V., Dublin Branch, BNP Paribas, and The Bank of Nova Scotia as Syndication Agents, Citibank, N.A., BNP Paribas, ING Bank, N.V., Dublin Branch, The Bank of Nova Scotia, Bank of America, N.A., and Compass Bank as initial Issuing Banks, and Citigroup Global Markets Inc., BNP Paribas Securities Corp., Merrill Lynch, Pierce, Fenner & Smith Inc., ING Bank, N.V., Dublin Branch, and The Bank of Nova Scotia as Joint Lead Arrangers and Bookrunners (incorporated by reference to Exhibit 10.1 to KBR’s Form 8-K filed October 1, 2015; File No. 1-33146)
 
 
 
*10.2
 
Form of Amendment to Severance and Change in Control Agreement
 
 
 
*31.1
 
Certification of the Chief Executive Officer Pursuant to Section 302 of the Sarbanes-Oxley Act of 2002.
 
 
 
*31.2
 
Certification of the Chief Financial Officer Pursuant to Section 302 of the Sarbanes-Oxley Act of 2002.
 
 
 
**32.1
 
Certification Furnished Pursuant to 18 U.S.C. Section 1350 as Adopted Pursuant to Section 906 of the Sarbanes-Oxley Act of 2002.
 
 
 
**32.2
 
Certification Furnished Pursuant to 18 U.S.C. Section 1350 as Adopted Pursuant to Section 906 of the Sarbanes-Oxley Act of 2002.
 
 
 
***101
 
The following materials from the Company’s Quarterly Report on Form 10-Q for the period ended September 30, 2015, formatted in XBRL (Extensible Business Reporting Language): (i) Condensed Consolidated Statements of Operations (Unaudited), (ii) Condensed Consolidated Statements of Comprehensive Income (Loss) (Unaudited), (iii) Condensed Consolidated Balance Sheets (Unaudited), (iv) Condensed Consolidated Statements of Cash Flows (Unaudited), and (v) Notes to Condensed Consolidated Financial Statements (Unaudited)

*
Filed with this Form 10-Q
 
 
 
 
**
Furnished with this Form 10-Q
 
 
 
 
***
Interactive data files
 


54



Pursuant to the requirements of the Securities Exchange Act of 1934, this report has been signed below by the following persons on behalf of the registrant and in the capacities and on the dates indicated:
 
KBR, INC.
 
 
 
 
 
 
 
 
/s/ Brian K. Ferraioli
 
/s/ Nelson E. Rowe
Brian K. Ferraioli
 
Nelson E. Rowe
Executive Vice President and Chief Financial Officer
 
Vice President and Chief Accounting Officer

Dated: November 2, 2015


55



EXHIBIT INDEX
 
Exhibit
Number
 
Description
 
 
 
3.1
 
KBR Amended and Restated Certificate of Incorporation (incorporated by reference to Exhibit 3.1 to KBR’s current report on Form 8-K filed June 7, 2012; File No. 1-33146)
 
 
 
3.2
 
Amended and Restated Bylaws of KBR, Inc. (incorporated by reference to Exhibit 3.2 to KBR’s annual report on Form 10-K for the year ended December 31, 2013 filed on February 27, 2014; File No. 1-33146)
 
 
 
10.1
 
Amended and Restated Revolving Credit Agreement dated as of September 25, 2015 among KBR, Inc., the Banks party thereto, Citibank, N.A., as Administrative Agent, Bank of America, N.A., ING Bank, N.V., Dublin Branch, BNP Paribas, and The Bank of Nova Scotia as Syndication Agents, Citibank, N.A., BNP Paribas, ING Bank, N.V., Dublin Branch, The Bank of Nova Scotia, Bank of America, N.A., and Compass Bank as initial Issuing Banks, and Citigroup Global Markets Inc., BNP Paribas Securities Corp., Merrill Lynch, Pierce, Fenner & Smith Inc., ING Bank, N.V., Dublin Branch, and The Bank of Nova Scotia as Joint Lead Arrangers and Bookrunners (incorporated by reference to Exhibit 10.1 to KBR’s Form 8-K filed October 1, 2015; File No. 1-33146)
 
 
 
*10.2
 
Form of Amendment to Severance and Change in Control Agreement
 
 
 
*31.1
 
Certification of the Chief Executive Officer Pursuant to Section 302 of the Sarbanes-Oxley Act of 2002.
 
 
 
*31.2
 
Certification of the Chief Financial Officer Pursuant to Section 302 of the Sarbanes-Oxley Act of 2002.
 
 
 
**32.1
 
Certification Furnished Pursuant to 18 U.S.C. Section 1350 as Adopted Pursuant to Section 906 of the Sarbanes-Oxley Act of 2002.
 
 
 
**32.2
 
Certification Furnished Pursuant to 18 U.S.C. Section 1350 as Adopted Pursuant to Section 906 of the Sarbanes-Oxley Act of 2002.
 
 
 
***101
 
The following materials from the Company’s Quarterly Report on Form 10-Q for the period ended September 30, 2015, formatted in XBRL (Extensible Business Reporting Language): (i) Condensed Consolidated Statements of Operations (Unaudited), (ii) Condensed Consolidated Statements of Comprehensive Income (Loss) (Unaudited), (iii) Condensed Consolidated Balance Sheets (Unaudited), (iv) Condensed Consolidated Statements of Cash Flows (Unaudited), and (v) Notes to Condensed Consolidated Financial Statements (Unaudited)
*
Filed with this Form 10-Q
 
 
 
 
**
Furnished with this Form 10-Q
 
 
 
 
***
Interactive data files
 

56